Cable Laying Labor Subcontract Final Edition 1 Employer: _ _ _ _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ _
In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Project Contract and relevant regulations, and in combination with the specific conditions of this project, this contract is hereby signed to clarify the rights and obligations of both parties.
First project
(1) Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(2) Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(3) Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(4) Contract scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2 The project cost (budget or estimate) is RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The third construction period
Article 4 Project Quality Standards and Warranty Period
Article 5 responsibilities of both parties
(1) Responsibility of the Employer: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(II) Liability of the Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 6 This contract is made in duplicate, one for each party, and shall come into effect as of the date of signing.
Party A (seal): Party B (seal): Party A (seal): Party B (seal): Party B.
Address: _ _ _ _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative of Party A (signature): _ _ _ _ _ _ _ _ Representative of Party B (signature): _ _ _ _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _
Fax: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Postal Code: _ _ _ _ _ _ _ _ _ Postal Code: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Cable Laying Service Subcontract, Final Version 2: Owner: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ _
Signature time: _ _ _ _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _ _
In order to ensure the quality of _ _ _ _ _ _ _ _ _
I. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Two. Building area (project form): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Three. Construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Four. Duration: _ _ _ _ _ _ _ _ _ (1) Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Completion status: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Verb (abbreviation of verb) Contract form: _ _ _ _ _ _ _ _ _ _ _ _ _
The quality standard of intransitive verbs: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
7. Project price: _ _ _ _ _ _ _ _ _ * * RMB.
Eight. Payment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The quality guarantee fee is RMB _ _ _ _ _ _ _ _ Yuan, which shall be paid after the warranty period expires.
Nine. Warranty period: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
X. Responsibilities and obligations of both parties
(A) the responsibilities and obligations of the employer
1. Provide the contractor with good construction site, roads, water and electricity supply, and meet the starting conditions. Solve the adjacent relations and disputes that need to be solved by the employer in the construction;
2. Supervise and manage the project quality and material quality in the construction process, and supervise the project progress;
3. Provide the contractor with construction drawings, coordinate points and elevation points;
4, timely disbursement of funds to the contractor and acceptance settlement;
(II) Responsibilities and obligations of the contractor
1, according to the requirements of the owner and drawings for construction; 2. Complete the construction task as scheduled;
3. Accept the technical guidance and quality standard requirements of the Employer; 4. Responsible for the protection of materials and equipment provided by the owner;
5. Educate the construction personnel to take good care of Party A's materials and not steal or damage them; 6. Take responsibility and expenses for all safety accidents in the construction process;
XI。 others
(1) This contract shall come into effect after being signed and sealed by both parties, and shall be valid until the warranty period expires.
(II) Matters not covered in this contract can be settled by both parties through negotiation, and a written supplementary agreement is signed, which has the same legal effect as this contract. If negotiation fails, it shall be submitted to the people's court of Cao County, Shandong Province for litigation.
(3) The annex to the contract is an integral part of the terms of this contract. This contract and its annexes are made in duplicate, one for each party, with the same effect.
Employer: _ _ _ _ _ _ _ _ _ _ Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Authorized Agent: _ _ _ _ _ _ _ _ _ _ Authorized Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The Employer (hereinafter referred to as Party A) Cable Laying Labor Subcontract Final Edition 3 _ _ _ _ _ _ _ _ _
The Contractor (hereinafter referred to as Party B) _ _ _ _ _ _ _ _ _ _ _ _
According to the Economic Contract Law of the People's Republic of China, the Construction Law of People's Republic of China (PRC), the Regulations on the Quality Management of Construction Projects and other relevant laws and administrative regulations, as well as the relevant construction project quality standards, norms and regulations, and the laws and regulations promulgated by _ _ _.
I. Overview of the Project
1. Project name: _ _ _ _ _ _ _ _ _ _.
2. Project location: _ _ _ _ _ _ _ _ _ _ _.
Second, the scope of project contracting
Safety maintenance and rectification.
Third, the term of the contract.
_ _ _ _ _ days.
Fourth, the project cost
The project cost is: _ _ _ _ _ _ _ _ _ _ _ Yuan only.
Verb (abbreviation of verb) quality standard
1. quality standard: in line with the current national or industrial quality evaluation standards.
2. Use standards and specifications (including but not limited to the following)
(1) The technical standards and specifications of this project shall conform to the national, ministerial and local construction technology (acceptance) regulations and specifications.
(2) The local standards and regulations applicable to this project must conform to the provincial standards and regulations.
Six, the way of contracting
Contract work, materials, quality, time limit for a project and safety according to the work contents listed in the scope of contract in Article 2 of this contract.
Seven. Project valuation
1. Compilation principle of this project: according to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. Determination of labor and material prices: Labor wages are calculated according to _ _ _ _ _ _ _ _ _ _ _ _ _.
3. The specific quantity shall be subject to the visa form of Party A. ..
Eight, time limit for a project
In any of the following circumstances, the construction period can be extended after the visa is verified.
1. Work stoppage caused by force majeure factors, including: national policy adjustment, war, unrest, falling objects in the air or other explosions and fires not discovered by Party A and Party B, as well as natural disasters such as floods and earthquakes. If the hourly rainfall of the project site is more than 200mm (subject to the report of the Municipal Meteorological Bureau), water and electricity will be cut off once.
2. If the construction period of key working procedures of Party B is delayed due to reasons other than Party B, the construction period may be extended according to the actual situation.
3. If the construction period is delayed due to Party B, the contract construction period cannot be postponed, and the expenses shall be borne by Party B. ..
4. If the project is delayed due to Party A's reasons, the contract period will be postponed and the expenses will be borne by Party A. ..
Nine. Payment of project funds
1. After the project is completed, Party A shall pay 80% of the project budget price to Party B within 10.
2. After the project settlement is completed, Party A shall pay 97% of the total settlement price and reserve 3% of the total settlement price as the project warranty fund. If there is no quality problem within one year 15 days after the acceptance of the project, the warranty money will be returned in full without interest.
X. liability for breach of contract
1. Default scheme: Party B shall bear the liability for breach of contract in the form agreed in this contract. If there is no agreement in the contract, the case contract law and relevant laws and regulations shall prevail.
2. If the breaching party's breach of contract causes losses to the other party, if the breaching party's liability for breach of contract is still insufficient to make up for the other party's losses, it shall also be liable for compensation.
XI。 Safe production and civilized construction
Conscientiously implement the national and local laws and regulations on construction safety production and the relevant management requirements of the construction unit, do a good job in safety management, put an end to major safety accidents, and do a good job in comprehensive social management.
Twelve. Settlement of disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation or mediated by the local construction administrative department. If mediation fails, both parties agree to settle it by the people's court where the plaintiff is located, but the construction shall not be interrupted during the litigation.
Thirteen. others
Party B shall pay the wages of migrant workers in time according to relevant national regulations. If the project undertaken by Party B is delayed in the construction process, it will be handled by the government, and Party A has the right to pay the wages of migrant workers directly from the project funds. This contract is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (official seal) _ _ _ _ _ _ _ _ _ _ _ _
Party B (official seal) _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The Employer of Final Version 4 of the Cable Laying Labor Subcontract (hereinafter referred to as "Party A"):
Contact information:
Legal representative:
Contractor (hereinafter referred to as "Party B"):
Legal representative:
Contact telephone number:
According to the provisions of "_ _" and relevant laws and regulations, combined with the characteristics of family room decoration project construction, on the basis of equality, voluntariness and consensus, both parties have reached the following terms and conditions on matters related to Party A's family room decoration project (hereinafter referred to as the project):
Article 1 General situation of the project
1. 1 Project location and area:
Location: _ _ _ _ _ _.
Area: _ _ _ _ _ _ _ square meters.
1.2 project cost: ￥ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1.3 project contracting method: both parties agree to adopt the following _ _ _ contracting method.
(1) Party B contracts all materials;
(2) Party B contracts some materials and Party A provides some materials;
(3) Party B undertakes the work and Party A undertakes all the materials.
1.4 The construction period is _ _ _ _ _ _ _ _ days.
Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _:
Completion date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 2 Project supervision
If it is a supervision project, Party A (or Party B) shall sign a project supervision contract with the supervision company separately, and notify Party B (or Party A) of the name, unit, contact information and responsibilities of the supervision engineer.
Article 3 Construction drawings
Both parties agree to provide the construction drawings in the following _ _ _ _ way:
3. 1 Party A shall design and provide the construction drawings by itself, with the delivery date of _ _ _ _ _ _ _ _ _ _ _ _ _, and the drawings shall be in triplicate, one for Party A, Party B and the construction team respectively;
3.2 Party A entrusts Party B to design the construction drawing in triplicate, with Party A, Party B and the construction team holding one copy respectively, and the design fee shall be paid by Party A (this fee is not included in the project price);
3.3 The construction drawings shall take effect after being signed by both parties.
Article 4 Obligations of Party A
4. 1 Create conditions for Party B to enter the site for construction _ _ days before commencement. Empty all or part of the house and remove obstacles that affect the construction; Protective measures should be taken for furniture and furnishings that can only be partially vacated, so as not to affect the construction. Party B's construction personnel shall carefully check and protect the animals on Party A's construction site, and both parties shall sign the "List of Articles";
4.2 Dismantle the original telephone equipment before construction; Provide water and electricity during construction, and explain the matters needing attention in use;
4.3 Responsible for coordinating the relationship between the construction team and the neighborhood;
4.4 It is forbidden to dismantle the indoor load-bearing structure. Need to dismantle, change the load-bearing and non-load-bearing structure of the building, or move the kitchen, bathroom, equipment and pipeline, shall be responsible for the relevant departments to handle the corresponding examination and approval procedures; According to the regulations of relevant departments, Party A has no right to ask Party B to move or change the heating and gas pipelines;
4.5 Participate in the supervision of project quality and construction progress, and participate in the acceptance of materials entering the site and project completion;
4.6 The construction deposit and various property management fees collected by the property management department where the project is located shall be paid by Party A (except for the pass), and Party B shall assist in providing relevant information required for property management.
Article 5 Obligations of Party B
5. 1 Strictly implement the National Code for Construction of Residential Decoration Engineering during construction to ensure the project quality and complete the project on schedule;
5.2 Before Party A formally provides the approval documents of relevant departments, it is strictly forbidden to change the main building, load-bearing structure, heating and gas pipelines. , otherwise it shall bear corresponding responsibilities;
5.3 Strictly implement the regulations on the management of the construction site in this Municipality, so as not to disturb the people and pollute the environment;
5.4 Protect the furniture and furnishings of the original bedroom, and ensure that the upper and lower pipes of the bedroom are unblocked;
5.5 Ensure the cleanliness of the construction site and be responsible for the cleaning of the construction site after the project is completed;
5.6 Party B shall be responsible for the fines and compensation caused by Party B's violation of property management regulations during the construction period;
5.7 The designer of Party B is responsible for providing consulting, design, quotation and other related services to Party A. After the contract is signed, the representative of Party B to implement the project construction is the project manager appointed by Party B. Party A shall contact the project manager of Party B about the project to ensure the unified command and management of the project.
Article 6 Engineering changes
6. 1 In order to ensure Party A's engineering quality, construction period and warranty service, if there is any change in the engineering project or construction method after the signing of the contract, both parties shall sign a written agreement, Decoration Engineering Change Order, and adjust the related engineering cost and construction period at the same time, and the oral commitment or oral agreement shall be deemed invalid; Party A directly negotiates with Party B's on-site personnel to change the construction content, and all consequences arising therefrom shall be borne by Party A;
6.2 After the signing of the contract, if the deduction of project payment by Party A exceeds 5% of the total project payment, Party A shall pay Party B a change fee of 8% of the total deduction. If Party B has ordered or transported the materials used for Party A's deduction to the site, Party A shall pay extra for the round-trip consignment, loss and return of the materials; If the construction project requested by Party A has been started, Party A shall pay Party B the construction fee, material fee, management fee and demolition fee of the project;
6.3 For the additional project after Party A pays the project payment for the second time, Party B shall carry out the construction after receiving the project payment of 100% of the additional project from Party A. ..
Article 7 Provision of materials
7. 1 The specifications and quality of materials and equipment provided by Party A shall meet the design requirements. Party A shall deliver the materials and equipment to the construction site on time and notify Party B, and both parties shall accept and handle the handover procedures; If Party A fails to provide materials on time or the specifications and quality of materials do not meet the design requirements, thus delaying the construction period or affecting the project quality, Party A shall bear the responsibilities;
7.2 For the materials and equipment provided by Party B, Party B shall inform Party A in advance of the time when the materials and equipment will arrive at the construction site, and both parties shall jointly accept them; If the brand, specification and quality of the materials provided by Party B are inconsistent with the quotation, Party A has the right to refuse to use them, thus delaying the construction period or affecting the project quality, and Party B shall bear the responsibilities;
7.3 Party A shall determine the brand, specification, model or price standard of the materials, and Party B shall be responsible for purchasing them for Party A. The materials shall be transported to the construction site and can only be used after Party A's acceptance. The material purchase fee charged by Party B from Party A is material collection management fee (_ _% of the material payment)+material transportation fee (determined according to the actual situation); If the construction period is delayed due to material quality problems, Party A shall bear the responsibility;
7.4 Unless otherwise stipulated in the contract, hardware (door locks, handles, faucets, etc. ), stone, ceramic tile, equipment, sanitary ware and lamps are purchased by Party A and delivered to the site on time; If Party B is required to purchase materials, it will increase the purchase fee and transportation fee of% of the purchased materials.
Article 8 Time limit for a project is delayed
8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A:
(1) engineering quantity change and design change;
(2) Force majeure;
(3) Work stoppage caused by Party A's failure to attend the stage acceptance on time;
(4) Other circumstances in which Party A agrees to postpone the construction period.
8.2 If the time limit for a project is affected by Party A's failure to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the unqualified materials and equipment provided by Party A affect the project quality, the cost of rework shall be borne by Party A, and the construction period shall be postponed;
8.3 If Party A fails to pay the project payment on schedule, the contract period shall be postponed accordingly;
8.4 If the project cannot be completed on schedule due to Party B's material supply or construction reasons, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.
Article 9 Quality standards
9. 1 Both parties agree that the construction quality of this project shall be accepted according to the following standards:
(1) GB 50210-_ _ _ _ _ Code for Quality Acceptance of Building Decoration Engineering;
(2) the provisions of Article _ _ _ _ on quality acceptance of family residential decoration engineering;
(3) Other acceptance criteria: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
9.2 In the process of construction, when both parties have disputes over the project quality:
(1) You can complain to _ _ _ _ _ _ _ _ _ Family Decoration Complaint Center.
(2) If mediation is not accepted, it shall be appraised by an engineering quality inspection agency agreed by both parties, and the expenses and losses arising therefrom shall be borne by the responsible party. Both parties have responsibilities, which shall be borne by both parties according to their respective responsibilities.
Article 10 Project Acceptance and Warranty
10. 1 Both parties agree to check and accept the project quality in the following three stages during the construction process:
(1) Acceptance of concealed works such as hydropower pipeline, waterproof layer and suspended ceiling base;
(2) Acceptance of paint and surface coating before construction;
(3) Completion acceptance.
Party B shall notify Party A two days in advance to carry out the acceptance of each stage, and fill in the project acceptance form after the acceptance of each stage is qualified. If Party A fails to attend the acceptance on time after receiving the notice, Party B has the right to stop work and wait, and all delays and other losses caused to Party B shall be borne by Party A;
10.2 After the project is completed and accepted, and the balance of the project is settled, Party B shall go through the handover procedures with Party A and fill in the project warranty form.
Article 11 Method of payment for project funds
1 1. 1 Both parties agree to pay the project payment according to the following method:
(1) After the contract comes into effect, Party A shall directly pay the project payment to Party B's finance according to the following table:
Payment times, payment time, payment proportion and payment amount:
The date of signing the first contract;
Within _ _ _ _ days after the acceptance of the second concealed work;
Within _ _ _ _ days after the third completion acceptance.
(3) Other payment methods: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1 1.2 Within 2 days after the acceptance of the project, Party B shall propose the project settlement to Party A and send relevant materials to Party A. If Party A has no objection within 2 days after receiving the materials, both parties shall sign the project settlement form, and Party A shall settle the final payment of the project to Party B at the same time.
1 1.3 Party A pays the project funds directly to the finance department of Party B. After all the project funds are settled, Party B only needs to issue a formal unified invoice to Party A. If losses are caused by Party A directly handing over the project funds to Party B's construction personnel, Party A shall bear the responsibilities.
Article 12 Liability for breach of contract
12. 1 After the contract is signed, if either party proposes to terminate the contract or cannot perform the contract for any reason, it shall notify the other party in time. This contract may be terminated or postponed upon mutual agreement, and the breaching party shall pay the defaulting party _ _ _% of the project cost as penalty. If losses are caused, the breaching party shall compensate;
12.2 If the project fails to pass the acceptance or the final payment is not settled and handed over, if Party A uses or uses the finished product of the project without authorization, it shall be deemed that the project is qualified, and the losses caused thereby shall be borne by Party A, and it shall be deemed that Party A has automatically waived its warranty and maintenance rights, and Party B still has the right to recover the final payment;
12.3 If Party A fails to pay the second (third) project payment on schedule, Party B has the right to stop work and pay Party B a penalty of 2‰ of the total project cost for each day of delay;
12.4 If the project quality fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the required repair expenses shall be borne by Party B, and the construction period shall not be postponed.
12.5 If the construction period is delayed due to Party A or Party B, the responsible party shall pay 2‰ of the total project cost to the other party as liquidated damages for each day of delay.
Article 13 Settlement of Contract Disputes
In case any dispute between the two parties cannot be settled through negotiation, the following option shall be adopted:
(1) is applicable to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;
(2) to _ _ _ _ _ _ _ personnel court.
Some specific provisions of Article 14
14. 1 For the renovation project outside the urban area, Party B will charge 3% of the total project cost-10% for the construction in different places;
14.2 the garbage generated by the project construction shall be removed by party b to the garbage dump designated by the government, and party a shall pay the garbage removal fee (RMB) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
14.3 During the construction period, Party A will give _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
14.4 During the construction period, Party B's daily working hours are:
From _ _ _ _ _ _ _ _ to _ _ _ _ _ _ _
From _ _ _ _ _ _ _ _ to _ _ _ _ _ _ in the afternoon.
Article 15 Supplementary Provisions
15. 1 The project shall not be subcontracted after the signing of this contract;
15.2 if party a and party b sign this contract directly, this contract shall be signed on _ _ _ _ _ _ _ _ _ _ _.
Party A (signature):
Legal representative (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (seal):
Legal representative (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Owner of 5th Edition of Cable Laying Service Subcontract: _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
In order to clarify the rights and obligations of Party A and Party B in the construction process, promote good cooperation and collaboration between the two parties, and ensure that the project can complete the construction task on time with good quality and quantity. According to the relevant provisions of the Contract Law of People's Republic of China (PRC), Party A and Party B sign the construction contract of this project through consultation for mutual compliance.
The first general rule
1. Project name: _ _ _ _ _ _ _ _ _ _ _
2. Project location: _ _ _ _ _ _ _
3. Scope and content of project construction: _ _ _ _ _ _ _ _
4. Project cost: _ _ _ _ _ _ _ _ _
This contract stipulates that Party B shall contract and contract materials by contract.
The second time limit for a project and shutdown
1. All engineering projects in this contract started on September 14, 20xx, and were completed on February 3 1 20xx.
2. During the construction process, in case of any of the following circumstances, the construction period shall be extended, and both parties shall negotiate in time to determine the extended period in writing.
3. Forced to stop work due to irresistible natural disasters;
4. Party B needs to stop work due to the adjustment of Party A's project plan;
5. Those who are forced to stop work due to difficulties in purchasing materials.
Article 3 Land occupation and material supply of the project
1. Materials and templates required for the project shall be processed and purchased by Party B..
2. Qualified cement products shall be purchased by Party B in the county.
3. The blasting materials shall be purchased by Party B in principle. In case of difficulties, Party A can assist in handling relevant formalities.
Article 4 Engineering Quality Requirements and Design Changes
1. When organizing the construction, Party B must strictly implement the current relevant national and industrial technical regulations, specifications and quality evaluation standards. Establish and improve the construction quality assurance system, and fill in the unit project quality evaluation form carefully. Strengthen the construction quality management, so that the project quality can reach the qualified standard.
2. The relevant technical data of various projects must be in strict accordance with the design and construction, and the standards shall not be lowered.
3. Quality requirements of building materials: All building materials of this contract project must meet the requirements of relevant codes and regulations, and materials that do not meet the quality requirements shall not be used. In case of violation, Party A has the right to demand Party B to compensate all losses and terminate the contract.
Article 5 Project Payment
1. Advance payment for the project: After the project starts, Party A will not pay the progress payment, and all expenses will be paid by Party B. After the completion, both parties shall timely accept and settle accounts.
2. Party B shall not default on the wages of migrant workers.
Article 6 Project completion acceptance, settlement and warranty
1. Project completion acceptance: After the project is completed, Party B shall submit completion acceptance materials (i.e. completion drawings, construction technology summary, relevant forms for project quality inspection and evaluation, etc.). ) Give it to Party A as soon as possible. After receiving the completion data, Party A shall organize relevant units and departments to conduct acceptance within one month.
2. Project settlement: Party B shall settle the actual engineering quantity approved by Party A according to the project accepted by Party A. Party B shall issue Jian 'an invoice to Party A's financial personnel based on the acceptance settlement list issued by Party A's engineering technical director for settlement.
Article 7 Work-related accidents
Party B must strictly implement the laws, regulations, rules and policies of the state concerning production safety. In the construction, we should put safety first and strictly abide by the operating rules to prevent safety accidents. In case of safety accidents, Party B shall be responsible.
Article 8 Liability for breach of contract
1. construction period: after the completion time exceeds the time stipulated in the contract, Party A has the right to impose a fine of 5% of the project settlement price every day from the tenth day.
2. According to the provisions of this contract, if Party B breaches the contract, Party A has the right to demand compensation from Party B in any way according to relevant laws, regulations and rules. On the contrary, Party B has the right to demand compensation from Party A. ..
Article 9 Number of copies and validity period of the contract
1. This contract is made in quadruplicate, one for Party B and three for Party A. ..
2. This contract shall come into effect as of the date of signature by both parties, and shall become invalid after the payment of the final payment of the project is completed.
Article 10 Supplementary Provisions
1. Matters not covered in this contract shall be settled by both parties through consultation.
2. All annexes to this contract have the same effect as this contract.
Employer (Party A): (signature) _ _ _ _ _ _ _
Authorized representative of legal person: (signature) _ _ _ _ _ _ _
Project leader: (signature) _ _ _ _ _ _ _
Contractor (Party B): (official seal) _ _ _ _ _ _ _ _ _ _ _
Authorized representative of legal person: (signature) _ _ _ _ _ _ _
Project leader: (signature) _ _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _