Simple interior and exterior wall coating contract template

Coating, the traditional name in China is paint. So how much do you know about interior and exterior wall coating contracts? Do you know what to pay attention to? The following is the interior and exterior wall coating contract contract I compiled, welcome to read it for reference.

Interior and exterior wall coating contract template 1

Contractor: (hereinafter referred to as Party A) Contractor: (hereinafter referred to as Party B)

< p> Party A subcontracts the indoor putty, exterior wall insulation and coating sub-projects of Jinlubo Lecheng G1# residential building to Party B. In order to ensure safe production, civilized construction, and ensure the smooth progress of project quality and construction period, both parties shall Based on the principles of equality, integrity, and mutual benefit, and to better clarify the responsibilities, rights, and benefits of both parties, the following agreement was reached through friendly negotiation between the two parties:

1. Contracting Overview:

1 Paint sub-project

2 Contracting form: Contracted work and material package tested qualified

2. Contracting scope:

Jinlu Bo Le City G1# Residential Building Indoor putty, exterior wall insulation and coating and other sub-projects.

3. Contracting unit price:

1. Indoor putty: cement gypsum base and sweep, cement gypsum mortar plastering compaction and smoothing, hanging wire mesh at the junction, scraping water-resistant flexible putty II Road; unit price is 30 yuan/m2. (30 yuan per square meter) Calculated based on building area.

2. Exterior wall insulation: 90 thick polystyrene board insulation, bulk density 20kg/m3, fire resistance grade B1, 20 thick polymer anti-cracking mortar (pressed into alkali-resistant glass fiber mesh cloth); The unit price is 68 yuan/m2. (Eighteen yuan per square meter) Calculated based on actual area.

3. Exterior wall paint: one base and two coats of high-elastic acrylic paint; the unit price is 18 yuan/m2. (One hundred and eighty yuan per square meter) Calculated based on actual area.

4. Payment method:

Payment will be made according to the construction progress, with the roof project fee, and the house is a second to fifth-floor house of a multi-story residential building in the construction community, 3,900 yuan-- -4200 yuan/m2.

5. Construction period requirements:

Construction period: The project completion date is September 15th

If the construction period is delayed due to Party B’s reasons, every One day's delay will result in a fine of 1,000 yuan.

Note: The construction period can be postponed if the following circumstances occur: A. Open-air construction, postponed in case of rain; B. The civil contractor cannot submit a base surface that meets waterproofing requirements in time; C. Party A fails to pay in time according to the contract ;D. Changes in engineering design; E. Impact of cross-construction operations; F. Other circumstances stipulated in the contract or agreed to be postponed by representatives of the civil engineering party.

6. Quality requirements:

1. The construction of the project should be organized according to the drawing requirements and design, construction specifications and relevant technical standards, and must meet the requirements of the specifications. Project quality must meet qualified standards. After the local government quality supervision and management department conducts acceptance according to the current national specifications and acceptance assessment standards, if the quality is unqualified, Party B shall unconditionally repair it until it is qualified. Party B shall be responsible for compensation for the resulting economic losses and construction delay. If the final inspection fails, no settlement will be given.

2. The project implements a quality reward and punishment system. Every time a quality problem is found, Party B will be fined 100 yuan.

7. Responsibilities of both parties:

Party A’s responsibilities:

1. Provide Party B with free on-site material storage space, water and electricity supply, etc.;

2. Responsible for the coordination of each team in this project;

3. Supervise Party B’s construction quality, construction schedule, construction safety, and assist Party B in the protection of finished products;

4 , promptly notify Party B of any changes, additions or subtractions to drawings or site dimensions; Party B’s responsibilities:

1. Party B’s construction must comply with relevant safety requirements (1) Party B’s personnel must strictly follow the provisions of the waterproof construction specifications Construction, equipped with full-time technicians, (2) Party B shall abide by laws and regulations related to production safety, (3) Party B shall obey the unified coordination and management of production safety work; (4) Party B shall prepare safety technical measures or plans within the scope of the contract ( 5) Party B shall conscientiously implement safety technical measures or plans, establish and improve the safety production responsibility system, improve production conditions, and ensure safe production; (6) Party B shall strictly carry out construction in accordance with the relevant national, provincial and municipal safety production operating norms and procedures. If a safety accident occurs during this period, Party B shall bear all economic losses and legal liabilities by itself and has nothing to do with Party A.

2. Carry out construction in strict accordance with the design drawings and the requirements of the project department, so as to ensure quality and quantity, and complete tasks on schedule. Common quality defects and quality problems must be eliminated in the operation process. Quality problems caused by Party B's responsibility , Party B shall bear its economic losses.

3. After the completion of the project, Party B is responsible for providing the quality inspection report and retest report issued by the relevant national departments.

4. Responsible for the quality and safety technical briefing for the team members, the quality and safety acceptance quality standard briefing, and safety education before taking up the job.

5. If Party B causes harm to Party A or a third party during construction, Party B shall be liable for compensation.

6. While protecting the finished products of this profession, Party B should take preparatory measures to prevent fire contamination or damage to the finished and semi-finished products of other professions, and be responsible for promptly cleaning up the pollution caused by the construction projects within the contract scope.

7. Party B shall not subcontract this sub-project on its own. If Party A is found to have the right to terminate this agreement and subcontract construction to other units, Party B shall be responsible for compensation for the resulting economic losses.

8. Safe production and civilized construction:

1. After entering the site, Party B must strictly abide by the relevant requirements of the Construction Project Safety Production Management Regulations and consciously abide by Party A’s safety supervision and various regulations. kind of rules and regulations. During the construction process, safety operating regulations must be strictly followed. If Party B fails to carry out construction in accordance with regulations, Party B will be solely responsible for all accidents, injuries, disabilities, and deaths caused.

2. Party B’s staff must wear safety helmets correctly when entering the construction site, and should wear safety belts when working at high altitudes. If Party B’s workers are found to enter the construction site without wearing safety helmets and safety belts in accordance with relevant regulations, there will be no safety protection. As a measure, the team will be punished with a penalty of 50 yuan per person.

3. Temporary water and electricity for construction must be set up and connected by professionals. It is strictly prohibited to mess around without permission, and it is strictly prohibited for hotel staff to use indoors: "Three stoves" and other unusable electrical appliances stipulated by the construction site, such as cooking or boiling water, etc. will be confiscated and a fine of 200 yuan per person will be imposed.

4. During the construction, Party B shall cooperate closely with the team and management departments at all levels, obey the unified command and arrangements, and it is strictly prohibited to fight and gamble on the construction site, and to work under the influence of alcohol. Violators will be fined 1,000 for each time Yuan will be deducted from the salary, and Party B shall accept it unconditionally.

5. Safety Responsibility According to the relevant spirit, the principle of whoever is doing the work is responsible for safety shall be implemented. Party B must pay for safety protection. If safety problems occur, Party B shall be responsible for all legal responsibilities and economic expenses. .

6. Party B must do a good job in environmental sanitation at the construction site.

7. Various machinery and equipment, safety management, protective facilities and warning and safety signs must not be dismantled or moved at will.

8. In order to ensure safe and civilized construction on the construction site, Party B must keep its hands clean and is strictly prohibited from throwing debris downwards. Violators will be fined 500 yuan each time.

9. Party B shall be responsible for the cleaning of each floor after the completion of each process, maintaining civilized construction on site and sanitary cleaning of each floor before acceptance.

10. Consciously obey Party A’s management, strengthen its own team management, and closely cooperate with Party A to manage civilized construction.

9. Warranty method:

After the construction is completed, Party B's free warranty period is one year. If there is a quality problem during the warranty period, Party B shall provide free warranty. Party A shall notify Party B based on this contract. After receiving the warranty notice, Party B shall immediately organize manpower and material resources to rush to the site for repairs. Party B shall not shirk the responsibility for any reason.

10. Supplementary Provisions:

1. Matters not covered in this agreement shall be resolved through friendly negotiation between Party A and Party B based on the principle of seeking truth from facts. If negotiation fails, either party may apply to the local arbitration committee for an award. The arbitration result is final and both parties must obey it unconditionally.

2. This agreement will take effect from the date of signing and will automatically expire after the project is completed and the payment for the project is paid. This agreement is made in duplicate, and each Party A and Party B shall hold one copy as evidence.

Party A’s signature:

Signing date:

Party B’s signature:

Interior and exterior wall coating contract template 2

< p> Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

Party A now plans to outsource the interior decoration project of the Xiangqiao Jiayuan project to Party B. Based on the principles of fairness, impartiality and good faith, this contract has been signed by Party A and Party B through mutual consultation and in order to clarify the obligations and responsibilities of both parties.

The content stated in this contract is the result of unanimous recognition by both parties. The rights and obligations agreed upon are the standards that both parties should abide by. If either party breaches the contract or damages the legitimate interests of the other party, the other party will be liable. Each party has the right to pursue its liability for breach of contract in accordance with the law. The specific contract terms are as follows:

1. Project name: Buildings 1#~3# and basement of Xiangqiao Jiayuan Residential Community.

2. Project location: Huanghe Village, Yuelu District, Changsha City

3. Contract scope: Building

The paint and coating decoration project is based on Xiangqiao Jiayuan provided by Party A The project quantity described in the construction drawings shall prevail, including the transfer, stacking, cleaning of on-site materials, maintenance of the construction site, and labor and material fees incurred for civilized construction measures at the construction site. The specific contract scope is as follows:

1. Brush the exterior walls with waterproof white latex on all non-tiled parts such as the drip lines, gutter bottoms, sloped roof tops and bottoms, roof parapets, roof structures, elevator rooms, air-conditioning board bottoms, surfaces, etc. paint.

2. Apply cement glue to the ceilings of indoor halls, rooms, corridors, and indoor gardens.

3. Paint the balcony ceiling and beams with waterproof white latex paint on the exterior wall.

4. Paint the interior walls with white latex paint in the elevator front room, ceiling, corridors and ceiling in public areas.

5. Paint the stairwell walls and ceiling interior walls with white latex paint.

6. Paint the stair rests and steps with dark gray 505 latex paint.

7. Paint the basement walls and ceiling with 888 imitation porcelain paint.

8. Cooperate with the project department and superior leaders to inspect all labor at the construction site and bear the labor costs.

9. Party A is solely responsible for providing natural cement.

The above includes surface cleaning, joint chiseling and leveling, cleaning of steel bar heads, nails, etc., full putty, Yin and Yang corner trimming, sandpapering, construction scaffolding, repairs, finished product protection, sanitation work, etc. All processes are within the scope of the contract.

4. Contracting methods and construction period:

1. Contracting of work, materials, construction period, quality, safety, acceptance, etc. until acceptance, delivery, use and maintenance.

2. Construction period: It must be completed within 3 days from the date of entry. The delay period is within 7 days. Starting from the eighth day of the delay period, a fine of 5,000 yuan/day will be imposed for each day of delay until the project is completed. , if it is completed ahead of schedule, there will be no reward or penalty within 7 days in advance. If it exceeds 7 days, a reward of 5,000 yuan/day will be calculated from the eighth day in advance (taking into account the construction quality and construction investment cost, it is not recommended to be more than 15 days in advance, which means a bonus of 40,000 yuan) Capped. )

3. Party A is responsible for the required power tools, cables, lighting fixtures, etc. within the scope of the contract. Party A only provides the power switch box to the floor.

5. Contracting unit price and settlement method:

1. The lump sum unit price of this project shall include but not be limited to the following:

1.1. Related to this project For sporadic employment, material loading, unloading and stacking, safe and civilized construction employment, finished product protection employment, and secondary reuse of materials, no sporadic employment will be issued on site.

1.2. The unit price includes labor wages, auxiliary material fees, temporary lighting fees (except vertical transportation machinery), management fees, profits and other expenses for completing this work, as well as market risks and Party B’s After fully understanding the on-site conditions of this project, all expenses invested in achieving the construction period goals, safe and civilized construction, and quality levels agreed in the contract shall not be proposed to adjust the contract unit price under any circumstances.

2. Details of the lump sum unit price for physical quantities:

2.1. Drip lines on exterior walls, bottom of gutters, upper and lower surfaces of sloped roofs, roof parapets, roof frames, and balcony drips Wire. The non-tiled exterior parts such as cigarette hoods, elevator machine rooms, air-conditioning board bottoms, surfaces, window top lines, etc. are painted with exterior wall waterproof white latex paint at a cost of RMB/m2. (Calculated based on building area)

2.2. Cement mortar for ceilings in indoor halls, rooms, corridors, indoor gardens, etc. costs RMB/m2 (calculated based on actual area)

2.3. Balcony ceiling and beam exterior wall waterproof white latex paint yuan/m2. (Calculated based on the actual area)

2.4. Paint the interior walls with white latex paint in the elevator front room, ceiling, corridors, and ceiling in public areas at RMB/m2. (Calculated based on actual area)

2.5. Paint the stairwell walls and ceilings with white latex paint on the interior walls. RMB/m2. (Calculated based on actual area)

2.6. Stair rests and steps should be painted with dark gray 505 latex paint RMB/m2. (Calculated based on projected area)

2.7. Paint the basement walls and ceiling with 888 imitation porcelain paint RMB/m2. (Calculated based on actual area)

3. Project settlement:

3.1. Settlement method: This project adopts the lump sum method of unit price for physical quantity.

3.2. Settlement method: Approved project quantity × fixed lump sum comprehensive unit price ± project change negotiation - liquidated damages, etc.

3.3. On-site economic visa must be approved by the project estimator and the construction supervisor. It will take effect only after all three chief engineers have signed and approved it.

3.4. Party B shall submit settlement information in triplicate within 20 days after the completion of all projects undertaken by Party B. The settlement submitted by Party B (including calculation formula of project quantities, relevant on-site economic visa forms, etc.) shall be approved by the project leader It will take effect after approval, otherwise it will be returned as invalid. A copy will be returned to Party B after settlement becomes effective.

6. Payment method:

1. First payment: 70% of the exterior wall project volume is completed, and 70% of the contract unit price is paid based on the actual completed qualified project volume.

2. Second payment: When the outer frame begins to be dismantled, 70% of the contract unit price will be paid based on the actual completed qualified work quantity.

3. The third payment: All outer frames will be dismantled, and 80% of the contract unit price will be paid based on the actual completed qualified work quantity.

4. The fourth payment: 95% of the actual total project price will be paid upon completion of the completion acceptance (retain 5% of the total project price as a quality deposit, three months after the warranty period expires one year If there is no quality problem within the product, the full amount will be returned to Party B. If there is any quality problem, Party A will directly deduct the relevant fees until all deductions are made).

7. Safety management and civilized construction:

(1) Safety management

1. Party B has the right to reject Party A’s designation for violating safety regulations.

2. The person signing the contract is the first responsible person and has the responsibility to take all active safety measures, organize safe production, and conduct in-depth safety management at the construction site.

3. Safety indicators: zero deaths, zero serious injuries, and general safety accidents reduced to the lowest level.

4. (1) Party B shall strictly abide by the operating procedures during construction and shall not operate in violation of regulations. If a safety accident occurs, Party B will be responsible for all responsibilities and expenses.

(2) If a team causes a safety accident to another team, the project department will coordinate the incident, and all costs will be borne by the responsible team.

5. Comply with various safety systems and safety measures at the construction site. The responsible person must stay at the construction site 24 hours a day to assist in project management.

Under special circumstances, you need to ask for leave from the project department for permission, and you will be fined 1,000 yuan for each time you leave without reason.

(2) Civilized Construction

1. Operators must wear safety helmets when entering the construction site; dress cleanly.

2. After the work is completed, the power should be turned off and people should leave. The site should be cleared before lunch and dinner, and the remaining materials should be piled up and reused. Otherwise, they will be fined 200 yuan each time and ordered to make corrections. Those who do not correct will be fined double.

3. Civilized construction costs: 1% of the contract price. If the provincial civilized construction site standards cannot be met due to Party B’s reasons, Party A has the right to directly deduct it from the project payment.

4. Fighting or gathering to make trouble is strictly prohibited, otherwise, a fine of 20_ yuan per time will be imposed.

5. No additional stoves are allowed within the construction site. All meals must be eaten in the canteen. Children are not allowed to live on the construction site. Contractors must be persuaded to leave, otherwise they will be fined 200 yuan each time.

6. Party B’s materials are stacked in an orderly manner according to different specifications. The site should be kept clean at all times, with no loose dust or water accumulation, and the equipment should be kept clean. It should be cleaned at all times during each transportation. Otherwise, a fine of 200 yuan will be imposed for each time. , and make corrections immediately. Those who do not make corrections will be fined double.

7. Strictly abide by Party A's rules and regulations. Otherwise, in addition to being punished in accordance with the regulations, Party A has the right to terminate Party B's contract, and Party B will be responsible for any resulting losses.

8. Construction progress and construction quality:

1. Party B must obey the leadership and command of the project leader and chief engineer, organize and coordinate according to the construction schedule provided by the project department construction operations, otherwise they will be punished according to relevant systems.

2. Party B must carry out scientific management, reasonable construction, and ensure continuous and orderly operation in a fast, efficient, safe and civilized manner. Party B will receive 50% of the economic benefits resulting from the adoption of reasonable suggestions by Party A.

3. Party B must closely cooperate with Party A to ensure the construction progress of each node and the total construction period. At the same time, Party B must ensure that it cooperates with the fine decoration and landscape garden construction of the developer’s sales department and model rooms, and cooperates with other parties of the construction party. Contracting units must cooperate together, otherwise they will be punished according to relevant systems (see the construction progress reward and penalty system for details).

4. If Party B cannot meet the progress of the project, Party A can arrange another construction team to complete part or all of the project contracted by Party B, and the costs will be borne by Party B. Party A can also directly terminate the contract, thus Party A's losses shall be borne by Party B.

(2) Construction quality

1. The quality of the project must meet the requirements of the current national construction and acceptance specifications, construction, supervision and acceptance of model rooms and handover standards approved by Party A, otherwise it will be punished Penalty of 5% of the contract price.

2. Strengthen construction quality management and strictly prohibit quality problems such as hollowing, dry cracking, and peeling.

3. Construction should be carried out according to specifications to ensure that the surface of the wall is smooth, smooth, uniform in color, and free of peeling.

4. The paint brand used for the interior and exterior walls of this project must be China Resources or Nippon Paint. (The use of other brands is strictly prohibited)

9. Liability for breach of contract:

1. If Party B violates the above terms or fails to meet Party A’s requirements in terms of progress and quality, Party A will The company has the right to change the construction team, and the settlement will be based on 60% of the completed qualified project volume when clearing the site.

2. If Party B cannot complete the project on time, a fine of 1,000 yuan will be imposed for each day of delay.

3. If Party B has no obvious behavioral fault, Party A has no right to terminate the normal performance of the contract, otherwise it shall also be liable for breach of contract.

4. If either party breaches the contract and cannot negotiate, it can apply for arbitration to the arbitration committee where the contract is signed.

10. Other matters:

Any matters not covered shall be resolved through negotiation between the two parties. If during the performance of the contract, there are situations that are not agreed upon in this contract or there are areas that really need to be modified, the two parties will negotiate separately and form a written supplementary agreement. After signature and confirmation by both parties, it will be used as a supplementary clause of this contract and the content of this contract will be included. Equally effective.

This agreement is made in four copies, with Party A and Party B each holding two copies, and is legally binding.

Party A’s signature: Stamped phone number:

Party B’s signature: Stamped phone number:

ID number:

Family Address:

Year, month and day

Interior and exterior wall paint contract template 3

Contractor (full name): ____ Co., Ltd. (Party A)

Contractor (full name): _____ Operations Department (Party B)

According to the "Contract Law of the People's Republic of China" and "Construction and Installation Project Contract Regulations" and other relevant laws and administrative regulations According to the relevant provisions of the contract, following the principles of equality, voluntariness, fairness and good faith, combined with the actual situation of this project, and after consensus reached by both parties, this contract is signed so that both parties can abide by it.

1. Project overview:

1. Project name: ____ Project Section 1

2. Project location: _____ Development Zone

3. Construction unit: ____ Construction Co., Ltd.

2. Category, name, specification, quantity and project price of project materials:

1. Name, brand, specification, quantity of the goods , Unit price:

The unit price within the specified quantity is the comprehensive lump sum price. The lump sum price should include: production personnel fees, materials, machinery, tools, transportation, installation, construction schedule coordination, quality, profit, insurance, tax fees, necessary overtime fees, patent fees, packaging, air freight and local warehousing fees, transportation Expenses and all costs incurred due to late arrival of yourself or other equipment and materials to the construction site, all state fees and other customs fees, etc.

2. After the project is completed, Party A, together with the supervision unit, will organize relevant units and personnel to inspect and accept the project. After the inspection is passed, both parties will sign the delivery acceptance document and completion data, and hand over the project to Party A for management. The quality guarantee period is 2 years from the date of acceptance.

3. During the warranty period, Party B will provide free technical support and training, and bear all the costs of repairs and replacements caused by product quality problems; if the damage is caused by man-made damage, the cost will be charged.

4. Party B should ensure the timeliness of the warranty and respond promptly after receiving notices from Party A and the owner. The specific time is as follows:

5. Party B must The party and owner will respond immediately after being notified. If there is a problem that cannot be solved by phone, our personnel will rush to the scene within 24 hours and complete the warranty and maintenance projects related to quality problems within 7 days from the date of arriving at the scene. , otherwise, it will be deemed that Party A or the owner has approved the handling, and the cost will be deducted from the security deposit.

3. Settlement method:

1. Payment method

a. Advance payment: Starting from the day after the contract is signed, Party A shall pay within one calendar day ( Tentatively) 5% of the total payment amount will be given to Party B, totaling: RMB 100,000 as the deposit for the contract. When the materials arrive at the site, 70% of the payment will be paid. After all installations are completed, Party A must pay 10% of the total project payment within 3 calendar days, and 10% will be paid after the project is completed and accepted.

b. The warranty deposit is the contract settlement amount

2. Warranty deposit payment method: 3% will be paid after one year from the date of acceptance, and 2% will be paid within 15 calendar days after 2 years. Party A will pay Party B all the balance.

4. Construction preparation and obligations of both parties

(1) Party A’s work

1. Before construction, Party A should report the details related to the construction of wooden piles. The design documents or change documents and modified design drawings shall be provided to Party B, and Party B shall prepare the construction organization design and approve the drawing plan.

2. Party A shall organize relevant construction units to conduct handover inspections of ground engineering, pipeline engineering and other related projects within days before the start of construction.

3. Cooperate with Party B in the management and coordination of the construction site, and strictly prohibit cross construction and wet work with other projects. Provide three connections and one leveling construction conditions as well as the power supply and warehouse space required for construction.

4. Designated as Party A’s representative, responsible for contract performance, supervision and acceptance of project quality and progress, handling procedures such as changes, visas, project payment, and other related matters.

(2) Party B’s work:

1. Prepare the construction organization design based on the design documents provided by Party A and the actual conditions on site. Upon approval by Party A, the construction will be carried out strictly in accordance with the drawings.

2. Responsible for the materials necessary for the construction scope and content stipulated in this project contract and provide complete technical information, product certificates, inspection reports, etc.

3. Complete the work and deliver it for use on time and with guaranteed quality in strict accordance with the contract stipulations.

4. Appoint Party B as the representative responsible for the performance of the contract. Organize construction as required, ensure quality and quantity, complete construction tasks on schedule, and resolve various matters that Party B is responsible for.

5. The construction plan provided by Party B should include:

(1) Construction procedure description and detailed drawings;

(2) Technology and quality. Progress guarantee measures and safety and civility measures;

(3) Guarantee measures for the protection of finished products and other aspects deemed necessary to be explained in the relevant construction organization design. Party B's construction plans and construction progress plans for each stage shall comply with the general contractor's total construction period requirements.

6. Strictly implement regulations on construction site management, and must not disturb residents or pollute the environment.

5. Delivery time, delivery location, item stacking, contact person, contact information

1. Delivery time: The contractor must provide the required information in writing 3 days in advance The quantity is faxed to the contractor, who arranges production.

2. Delivery location:

3. Representative of Party A at the construction site: Representative of Party B at the construction site: 4. Contact information of Party A’s representative: Contact information of Party B’s representative: Both parties shall exercise the contract respectively The agreed power and the performance of the obligations stipulated in the contract.

5. Party A needs to designate relevant units to provide vertical transportation of materials to Party B. Party B must be responsible for unloading, short bargeing and stacking on site to the location designated by Party A and stacking them neatly.

6. Project Acceptance and Warranty

1. Both parties agree that the quality of the project will be checked in the following stages during the construction process:

(1) Construction Pre-acceptance: Party B will inspect the site

(2) Material arrival: Within 1 day after arriving at the site, Party A’s representatives, Party B’s representatives, the project supervisor, and the general decoration contractor will inspect the appearance quality of the goods. ;

Note: Party B shall notify Party A 3 days in advance for acceptance. After passing the stage acceptance, the project acceptance form shall be filled in.

2. In addition to meeting the standards listed in product samples and instructions and having corresponding functions, the product and installation quality must also meet national and local product specifications, industry quality, technical standards, and Party A’s technical standards. and acceptance criteria. Before completion acceptance, Party B shall provide relevant completion acceptance information required for the general contracting of decoration for each bid section (such as product certificate, green material mark authorization use certificate, etc.).

3. Party B shall promptly notify Party A to handle the inspection and acceptance procedures for concealed projects and intermediate projects. If Party A cannot participate in the inspection and acceptance on the scheduled date, Party B will organize personnel to conduct acceptance, and Party A shall acknowledge it in writing. 4. After the project is completed, Party A shall notify Party B for acceptance, and Party B shall organize acceptance within days after receiving the acceptance notice and fill out the project acceptance form. Handover procedures will be carried out after the project payment is settled. If Party A has no objection within 3 days after receiving the information, it will be deemed as agreement. Both parties should fill in the project settlement form and sign it. Party A should pay Party B when signing.

5. The warranty period for this project is to fill in the project warranty form from the date of acceptance by both parties.

7. Disputes, Breach of Contract and Claims

1. Dispute:

If a dispute arises between Party A and Party B due to the agreement, negotiation will be the main method, and consensus cannot be reached through negotiation. , both parties to the agreement have the right to file a lawsuit with the court having jurisdiction over the location of the project. After a dispute occurs, both parties should perform the contract, maintain continuous construction, and protect the completed project.

2. Breach of contract:

(1). When the contract cannot be continued to be performed due to one party’s reasons, the party shall promptly notify the other party and handle the termination procedures, and the responsible party shall Compensate the other party for corresponding economic losses.

(2) If Party A uses the finished product in advance or pulls it out for use without going through the acceptance procedures, Party A will be responsible for the loss.

(3). Due to Party B’s reasons, if the quality of the project fails to meet the quality standards agreed upon by both parties, Party B will be responsible for repairs and the construction period will not be extended.

3. Claim:

Party B failed to construct according to the provisions of the agreement, the quality did not meet the agreed standards, the construction period did not meet the agreed requirements, and the quality problems caused by Party B were not repaired in a timely manner during the warranty period. Problems, etc. and other breach of contract, Party A may claim compensation from Party B according to the following procedures.

(1). Send a notice of claim to the other party within fourteen days after the claim occurs.

(2). Party A (or Party B) shall respond within 30 days after receiving the claim notice or request Party B (or Party A) to further supplement the reasons and evidence for the claim. Party A (or Party B) shall If there is no reply within 30 days, the claim shall be deemed to have been approved by the other party.

8. Safety production

1. According to the principle of whoever is doing the construction is responsible for safety, Party B, as the contractor, must be fully responsible for safety production during the entire construction process, and Party A is responsible for supervision and inspection rights.

2. Party B shall strictly implement construction site safety standard management in accordance with relevant regulations, ensure a civilized construction site, adopt strict protective measures, and bear all responsibilities and expenses for accidents caused by inadequate safety measures.

3. In the event of a major equipment or personnel casualty accident, Party B shall immediately report it to the relevant departments and notify Party A’s representatives in accordance with relevant regulations. At the same time, it shall handle the matter in accordance with the requirements of relevant government departments. Party A shall provide necessary conditions for rescue. The expenses incurred shall be borne by Party B.

4. Party B shall implement the principle of civilized construction and must meet the requirements of environmental protection during the construction process.

5. If any injury is caused to a third party, Party B must bear all responsibilities and all costs.

9. Others

1. This contract will take effect after it is formally signed and sealed by Party A and Party B.

2. After the completion settlement and Party B delivers the project to Party A, Party A pays the money according to Article 6 of the contract. Except for the relevant warranty clauses which are still valid, other terms of the agreement will be terminated. After the warranty period expires, , the relevant warranty terms are terminated.

3. Number of copies of this contract: Two originals, one copy each held by Party A and Party B, signed and sealed by Party A and Party B and kept separately, two copies each by Party A and B, with the same legal effect.

4. Matters not covered in this contract will be resolved through negotiation between the two parties in a friendly and cooperative manner. If necessary, this agreement can be modified or supplemented in text form.

Party A: (seal) Party B: (seal) Legal representative (signature): Legal representative (signature):

Contact number: Contact number:

< p> Signing date: year month day Signing date: year month day

Simple interior and exterior wall coating contract template Related articles:

★ Interior and exterior walls Paint Contracting Contract Sample

★ Interior and exterior wall coating contract template (2)

★ Interior and exterior wall coating project contract template

★ Interior and exterior wall coating contract template 3 articles

★ 3 simple exterior wall coating construction contract contracts

★ Interior and exterior wall coating construction contract templates

★ Interior and exterior wall coating construction contract templates (2)

★ Interior and exterior wall paint construction contract template (2)