Real stone paint is one of the most widely used materials for building finishes, so what should you pay attention to when signing a real stone paint construction contract? The following is a sample real stone paint construction contract that I compiled for you. Thank you for your appreciation.
Sample of real stone paint construction contract 1
Party A:
Party B:
According to "China In accordance with the principles of the Contract Law of the People's Republic of China and the Construction Law of the People's Republic of China, combined with the specific conditions of this project, both parties A and B have reached consensus through consultation and signed this contract, and *** agrees to abide by it.
Article 1 Project Overview
1. Project Name:
2. Project Location:
3. Contracting Scope:
p>
4. Contracting method:
5. Construction period: calendar days
6. Construction start date: Year, month, day
7. Completion date: Year, month, day
Article 2: Coating selection
1. Coating selection: The coating for this project uses Zhejiang University’s “Jinzhili” brand coating produced by Hangzhou Jinzhi Chemical Co., Ltd. .
2. Basic construction technology:
a. Wall cleaning and repair (including leveling);
b. Special putty batch for exterior walls;
p>
c. Water-based alkali-resistant sealing primer for exterior walls;
d. Elastic paint surface layer;
3. Party B must provide samples before construction, pending confirmation by Party A Construction can be done later.
Article 3 Payment and settlement method of contract price
1. Contract price:
1. Water-based flat fluorocarbon paint area (tentative) 800 square meters meter, unit price is 70 yuan/square meter, totaling ¥56,000.00 yuan;
2. Elastic flat coating area (tentative) 20_ square meters; unit price is 35 yuan/square meter, totaling ¥70,000.00 yuan; < /p>
3. The project cost (tentative estimate) is: RMB 126,000.00, capitalized (RMB): one hundred and twenty thousand six thousand yuan.
2. Project payment and settlement method:
1. After the approval of the base layer putty is completed, Party A pays Party B RMB 60,000;
2. After the project is completed and accepted, and the final settlement is completed, Party A will pay 95% of the total final settlement.
1. After the final settlement is completed, 95% of the total final settlement amount will be paid, leaving 5% as a warranty deposit, which will be paid to Party B within one week after the one-year warranty period expires.
2. Project final accounting area: based on the actual construction area on site.
Article 4 Project Duration
1. According to the actual situation of the project, the total project duration (conditions are met) will be agreed upon. The construction date will be 3 days. The specific entry date shall be subject to the commencement report.
2. In case of the following circumstances, the construction period will be postponed accordingly:
1. According to the requirements of construction preparation regulations, construction sites, water sources, power supplies, roads cannot be connected, and obstacles cannot be provided Failure to clear it affects on-site construction.
2. Other circumstances in which Party A’s representative agrees to grant an extension.
3. When the construction of the next process is affected due to Party A’s reasons.
4. Work stoppage due to force majeure and other unforeseen reasons.
3. If the construction period is postponed, Party B shall submit a report to Party A on the content of the delay and the resulting economic expenditure. Party A shall confirm and reply within 3 days after receiving the report. If Party B fails to reply within the time limit, Party B shall The report content is deemed to be confirmed.
Article 5 Project Quality, Safety and Acceptance
1. Project quality level: Project quality should meet national or relevant industry quality inspection and assessment standards.
2. Party B shall carry out exterior wall construction in accordance with the "Jin Zhi Li" construction technology and material instructions, combined with the characteristics and requirements of this project.
3. Acceptance after completion of project construction shall be subject to the comprehensive completion acceptance of the project.
4. During the construction process, the project must be subject to the unified management of the general contractor and the cooperation of other exterior wall decoration teams.
Article 6 Project Warranty
1. Party B’s quality warranty period for this project: The project construction quality is guaranteed for one year. If there is a quality problem during the project warranty period, Party B will repair it free of charge.
2. During the quality warranty period, Party B will provide free labor services for quality damage or repairs not caused by Party B.
Article 7 Dispute Resolution Methods
If a dispute occurs during the performance of this contract, Party A and Party B shall resolve it through negotiation; if the negotiation fails, mediation by the relevant departments will be invalid. It is agreed to file a lawsuit in the People's Court of the place where the contract is signed.
Article 8 Other Agreed Matters
1. Matters not covered in this contract shall be made in accordance with the relevant provisions of the Contract Law, and a supplementary agreement shall be made after mutual consultation by both parties to the contract. , the supplementary agreement has the same legal effect as this contract.
2. This contract will come into effect after being signed and stamped with official seals by Party A and Party B. The contract will be terminated after the project acceptance is qualified and the project payment is settled.
4. This agreement is made in duplicate, one for Party A and one for Party B. The contract becomes effective after being stamped by both parties and signed by the agent.
Party A: Authorized agent: Telephone: Signing place: Signing date:
Party B: Authorized agent: Telephone: Year, month, day
Real stone paint construction Contract Contract Sample 2
Party A:
Party B:
According to the provisions of the "Contract Law of the People's Republic of China" and relevant laws and regulations, Party B To undertake the construction of Party A's exterior wall real stone paint project, this contract was signed after friendly negotiation between both parties.
Article 1: Project Overview
1. Project Name:
2. Project Location:
3. Project Scope: Outside Wall real stone paint construction and maintenance, etc.;
4. Contracting method: contracting.
Article 2: Project Period
Party B entered the site on month, year, and completed the project on day, month, year, with a total construction period of days.
Article 3: Contract Price
1. Contract Pricing
Party B will contract work per square meter (including construction personnel insurance), and the estimated project volume is approximately square meters meters, and the final settlement will be based on the actual construction area.
2. Method of payment for the project
1. Payment is divided into four stages according to the construction process: ① The putty bottom layer is completed (price of this process/m2); ② Sandpaper is used for protection The primer painting is completed (the price of this process is / m2); ③ the elastic line is completed (the price of this process is RMB / m2); ④ the real stone paint is sprayed twice and is completed (the price of this process is RMB / m2). After each process is completed and accepted, 60% of the project amount will be allocated, and the remaining 40% of the project will be allocated at the same time when the next process is completed.
2. If Party B can complete the project tasks on time and with quality, Party A will use RMB/m2 as a one-time reward after the project is accepted and accepted.
Article 4: Project Quality
1. Quality level: Acceptance shall be carried out in accordance with relevant national specifications. Party B promises that all project projects will meet national acceptance standards.
2. Party B must carry out construction in strict accordance with construction drawings, explanatory documents and construction engineering specifications and standards issued by the state and local governments, and accept the supervision of Party A’s engineering department.
3. Party B should pay attention to the protection of finished products during the construction process. If there is any damage, fines and compensation will be imposed.
4. Eliminate material waste. If Party B’s construction personnel are found to be wasting materials, the cost of wasted materials will be deducted from Party B’s project payment.
Article 5: Safety Responsibility
1. Party B shall prepare safety equipment such as safety belts and safety ropes required for high-altitude operations.
2. Party B shall be responsible for any safety accidents during the construction process, and Party A shall not be held responsible.
Article 6: Responsibilities of both parties
Party A is responsible for: providing materials required for construction, allocating project funds according to the construction progress, water and electricity required for construction, and construction living quarters.
Party B’s responsibilities: provide all tools, safety facilities and safety measures required for construction, carry out safe and civilized construction, and assume all safety responsibilities.
Article 7: Liability for breach of contract
1. In case of suspension of work caused by heavy rain or force majeure factors, the construction period will be postponed.
2. If the project fails to pass the acceptance inspection, Party B will make rectifications until it passes the acceptance inspection within the time required by Party A, and the construction period will not be postponed; if the construction period is delayed as a result, the payment will be calculated at 5% of the tentative total price of the contract per day. Liquidated damages.
3. All costs for rework due to Party B’s unqualified construction quality shall be borne by Party B.
Article 8: Unfinished matters of this project shall be resolved through negotiation between the two parties
Article 9: This agreement is made in triplicate, two copies for Party A and one copy for Party B, signed and sealed by both parties It will take effect later and have the same legal effect.
Party A (chapter): Party B (chapter):
Representative: Representative:
Signing date: Signing date:
Real stone paint construction contract sample 3
Construction unit:
Construction unit:
In accordance with the "Contract Law of the People's Republic of China", "China In accordance with the Building Law of the People's Republic of China and other relevant laws, administrative regulations, provincial and municipal regulations, and following the principles of equality, voluntariness, fairness and good faith, the two parties contracted for the construction of the exterior wall real stone paint project of the Ruihe Washington Sales Department The following contract terms have been reached on the matter to clarify responsibilities and agree to abide by them.
Article 1 Project Overview
1.1 Project Name:
1.2 Project Location:
1.3 Contracting Scope:
< p> 1.4 Contracting method: Contracting work, materials, construction period, quality, safety and civilized construction.Article 2 Contract Duration
2.1 The contract duration is 25 days
2.2 Construction Start Date:
2.3 Completion Date:
2.4 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly: If the handover time of Party A’s on-site foundation wall is delayed and weather reasons cause a delay in the construction period, the completion date will be postponed.
Article 3 Quality requirements: Qualified
3.1. Exterior wall painting process standards: The exterior walls of this project adopt a single-color real stone paint coating process. Party B will make a prototype before construction. The construction technology and the effect of the prototype will be confirmed by Party A. After the prototype is completed, both parties will sign for confirmation. During construction, Party B requires that the entire surface be evenly coated without any leakage; the paint shall be applied strictly in accordance with the color effects set by Party A.
3.2. The real stone paint material of this project uses the Xiaguang brand real stone paint produced by Wuhan Xiaguang Building Materials Co., Ltd. If Party B is found to be using counterfeit and shoddy products, Party A has the right to order Party B to stop work, and Party B will compensate Party A for all damages. economic loss.
3.3. Project construction should be carried out in strict accordance with the current national construction industry quality specifications, obey the instructions of the general contractor, and the quality standards must be qualified.
3.4. The exterior wall real stone paint is guaranteed not to fade after 20_ years of use.
Article 4 Contracting Methods and Project Pricing
4.1 The contracting method of this project is to contract labor, materials, construction period, quality, safety and civilized construction. Pricing adopts a lump sum method of comprehensive unit price. The comprehensive lump sum unit price is RMB per square meter, and the measured area is calculated based on the actual developed area. In addition, the inner side of the parapet wall of the sales department is constructed with ordinary waterproof coating. The color is determined by Party A, and the comprehensive unit price is RMB per square meter.
4.2 All materials entering the site shall be inspected and accepted in accordance with relevant regulations. Party A and the supervision unit have the right to re-inspect various materials. Party B must actively cooperate. For example, if the re-inspection fails, the inspection fees and losses caused shall be borne by Party B.
4.3 The quantity of the exterior wall real stone paint project under this contract is tentatively estimated to be square meters, and the inner area of ??the parapet wall is approximately square meters. The total contract price is tentatively determined as: Yuan, capitalized in RMB: 70,000 Yuan. The final total price shall be settled based on the actual area.
4.4 Payment method:
4.4.1. After the contract is signed, the construction personnel will enter the site, and % of the total contract price will be paid after the putty layer construction is completed.
4.4.3. After the real stone paint construction is completed, % of the total contract price will be paid.
4.4.4. After the completion acceptance is passed, the construction technical data are complete and handed over to Party A for final settlement, 95% of the total final settlement price will be paid.
4.4.5. The remaining 5% will be reserved as warranty deposit. The warranty deposit will be paid in one lump sum after the warranty period expires. The warranty deposit does not include interest. The warranty period is one year, calculated from the date of completion acceptance and delivery. .
4.4.6 Party B must provide a valid tax invoice recognized by the Wuhan Jiangxia District State and Local Taxation Bureau each time it settles payment.
Article 5 Responsibilities and Obligations of Party A
5.1 Party A appoints a representative stationed at the construction site to be responsible for contract performance, supervision and inspection of project quality and work progress, and handling acceptance and changes, etc. matters.
5.2 This project is entrusted to Wuhan Engineering Construction Supervision Consulting Co., Ltd. for project supervision.
5.3 Provide Party B with construction drawings and on-site explanation within seven days before the start of construction.
5.4 Timely review and approve various plans, reports, detailed drawings and plans submitted by Party B.
5.5 Pay project fees on time according to the terms of the contract.
5.6 Issue instructions, instructions, design changes and negotiations related to this project to Party B in a timely manner.
5.7 Take the lead in the completion acceptance of the project.
Article 6 Responsibilities and Obligations of Party B
6.1 Party B shall appoint a representative stationed at the construction site. Party B must send a strong and sufficient project management team to the site. Before the start of construction, the quality of exterior wall painting must be comprehensively inspected and the intermediate handover and acceptance must be handled. If it is found that the pre-construction requirements are not met, Party A must be notified in a timely manner.
6.2 Enter the site on time. During construction, you should strictly follow the instructions issued by the representative of the contractor based on the contract, strictly abide by various laws and regulations of the country and Wuhan City, obey the on-site management system and various requirements, and Actively prepare all equipment, materials and personnel required for construction, and complete this contracted project on time and with quality.
6.3 In strict accordance with the overall project progress plan formulated by Party A, timely prepare and submit the construction organization design, progress plan and specific, targeted and operable construction plan (including drawings) , explain the construction process operation and node processing), and carry out construction in strict accordance with the construction organization design, schedule plan and construction plan approved by Party A.
6.4 According to the relevant regulations of the state and Wuhan City on project completion acceptance, complete completion information of the project, completion acceptance report and as-built drawings shall be provided to Party A within the time specified by Party A. (Submit completion documents in triplicate to Party A within ten days after passing the acceptance inspection)
6.5 Party B shall be responsible for the safety of the construction process: in accordance with relevant regulations, strict safety protection measures shall be adopted, and on-site personnel shall fully abide by all regulations. Safety construction provisions applicable to relevant laws or regulations applicable to the project. Any safety accidents, personal casualties, property losses, etc. caused by Party B during construction shall be borne by Party B.
6.6 Party B shall actively cooperate with the inspections of Party A and the supervisory party.
6.7 Obey the on-site management of Party A and the general contractor.
6.9 Except with the consent of Party A, Party B shall not allow its workers to live in the construction site, nor shall they illegally enter the restricted area of ??the construction site.
Article 7 Liability for breach of contract, rewards and penalties
7.1 Party B shall be fully responsible for the safety of the construction site (including expenses and third-party liability). If a project safety accident caused by Party B causes adverse effects on Party A at the same time, Party B will bear not only economic and construction period losses, but also a penalty of 5% of the contract price.
7.2 Party A shall make timely payment strictly in accordance with the payment method agreed in this contract, and shall not refuse or delay payment in any form or for any reason. And bear the relevant losses caused to Party B due to untimely payment.
7.3 If Party B fails to pay the wages of migrant workers in accordance with regulations, thereby causing adverse effects to Party A, Party A has the right to directly deduct relevant expenses from the project payment and pay them to the migrant workers, and Party B must also fully compensate and bear the consequences. The economic loss caused to Party A by its failure to pay the migrant workers in a timely manner.
Article 8 Settlement Method
1. Settlement information: complete in content, complete with signatures and seals of all parties, and the depth of the document meets the settlement requirements. Settlement information in 4 copies.
2. Settlement method: Based on the comprehensive lump sum unit price of the contract.
If the design changes due to Party A's reasons, the corresponding unit price will be set if there is a corresponding unit price in the contract. If there is no corresponding unit price, the cost will be negotiated by both parties.
Article 9 Other Agreements
10.1 Before the start of construction, both parties must jointly determine the on-site construction working surface and sign for approval.
10.2 The on-site layout shall be arranged by Party B, but must be approved by the supervisor and Party A. Party B shall be responsible for on-site management work.
10.3 The materials purchased by Party B shall strictly implement the commitments made in the bid and quotation, and shall not be replaced without Party A's permission.
Article 11 Contract Dispute Resolution
< p> If any disputes arise during the execution of this contract, the two parties can resolve them through friendly negotiation. If the negotiation fails, either party can submit it to the People's Court for ruling.Article 12 Number of copies and effectiveness of the contract
1. This contract shall take effect from the date of signature and seal by both parties.
2. This contract is made in four copies, with each party holding two copies.
Party A: Party B:
Year, month and day:
3 related articles on the sample contract for real stone paint construction:
★ Foreign 3 Sample Contract Contracts for Real Stone Paint for Walls
★ 3 Sample Contract Contracts for Real Stone Paint for Exterior Walls
★ 3 Sample Contract Contracts for Paint Construction
★ 2020 3 Sample Painting Construction Contract Contracts
★ 3 Latest Exterior Wall Paint Contracting Contracts
★ Exterior Wall Real Stone Paint Construction Contract
★ Exterior Wall Real Stone Paint Subcontract template
★ Exterior wall real stone paint subcontract template
★ Exterior wall real stone paint subcontract template (2)
★ Painter construction contract