Earthwork Backfill Project Agreement 1 Employer: (hereinafter referred to as "Party A")
Contractor: (hereinafter referred to as "Party B")
Based on the principles of honesty, credit, fairness and justice, Party A and Party B have reached the following agreement through friendly negotiation on Party B's contract for backfilling earthwork of Huilian Aluminum Industry in Ganyu Ocean Development Zone:
I. Name of the contracted project
xx
Second, the way and scope of contracting
1, contracting, materials, machinery, quality, safety and civilized construction.
2. Party B shall provide earthwork (small pieces of aeolian fossils), transportation (dump trucks) and bulldozers to Party A's construction site for backfilling. Backfill area provided by Party A: Huilian factory building is 300m* long * 170m wide, and the elevation after backfilling reaches 4m.
Third, the term of the contract.
The total time limit for earthwork backfilling of the whole project is *** 15 days, from (including legal holidays) to (since). In case of irresistible natural disasters such as rainstorm, the time limit will be postponed.
Four, backfill earthwork quality requirements
1. Soil: small pieces of eolian fossils.
2. The diameter of the backfilled wind fossil should not be greater than cm, and the amount of wind fossil greater than cm should not be greater than 0.5 ‰ of the total earthwork.
3. Backfill earthwork must be leveled and compacted by bulldozer, and the soil quality and backfill quality must be approved by Party A. ..
Verb (abbreviation of verb) contract price and payment method
1, the contract unit price is XXX yuan /m3 (including tax), and the comprehensive quotation includes earthwork cost, transportation cost and backfill, leveling and compaction cost as required, and the transportation distance is not taken as the measurement factor of the contract price.
2. Payment of project price: During the project period, Party A does not need to pay, and Party A will fully contribute to Party B. After the project is completed and accepted by Party A, Party A will pay the total price in one lump sum within days.
Six, the construction requirements
1. Party B shall backfill at the designated place provided by Party A, and the quality of backfilled earthwork shall be recognized by Party A's site management personnel before backfilling, and the continuity of earthwork transportation shall be ensured.
2. During backfilling, Party B must accept the supervision and inspection of Party A's management personnel.
3. Safe and civilized construction: Party B shall conduct safety education for its field workers and provide a full set of labor protection articles. If Party A suffers casualties (including third parties) or property losses due to Party B's reasons, Party B shall bear all responsibilities.
Seven. break a contract
1. During the performance of the contract, if either party unilaterally terminates the contract without justifiable reasons, it is a unilateral breach of contract, and the breaching party shall compensate the other party for the losses caused thereby.
2. The absolute elevation of Party B after backfilling the terrace shall meet the requirements of Party A. If the backfilling height cannot meet the requirements of Party A, Party A will deduct it according to the actual amount.
3. Party B shall complete the project on schedule, and pay a penalty of 5% of the total contract price for each day of delay.
Eight. This agreement is made in duplicate, one for each party. This contract shall come into effect after being signed and sealed by both parties, and shall become invalid after the payment of the settlement price for project completion is completed.
Party A:
Party B:
Legal representative or entrusted agent:
Telephone:
date month year
date month year
Article 2 of the Agreement on Earthwork Backfill Project: Employer (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
According to laws and regulations, in order to clarify the rights and obligations of both parties, Party A and Party B reached the following agreement on the earthwork backfilling project of Dingbian Base of Changqing Petroleum Exploration Bureau through consultation:
1. Project name: earthwork backfilling project of Dingbian production base of Changqing Petroleum Exploration Bureau.
2. Project content: Part of earthwork backfilling and site leveling of Dingbian production base of Changqing Petroleum Exploration Bureau. See the attached drawings for details.
3. Calculation and determination method of workload: Party A shall provide schematic grid diagram and earthwork volume of earthwork backfilling area, and Party B shall recheck it, and the workload signed by Party A's supervisor shall prevail.
IV. Contract Price:
1, settlement price of earthwork backfilling, 7 yuan per cubic meter (site price includes all expenses such as soil purchase fee, excavation fee, loading and unloading fee and transportation fee).
2. The backfill earthwork totals cubic meters, and the total cost is RMB.
Five, the time limit for a project requirements:
1, starting date: YY.
2. Completion date: MM DD YY.
Six, quality and construction requirements:
(1) Before the project starts, the construction unit and Party A's construction technicians shall make disclosure to Party B, and Party B shall sign it in writing.
(2) Party B must instruct the workers to carry out the construction according to the requirements of technical disclosure and construction specifications. Make a model first, and then start construction after reaching the standard.
(3) When filling the soil, it should reach the design elevation of the construction unit, so as to ensure the leveling of the site.
(IV) Soil quality requirements of backfill soil: Party B seeks the soil source, and the construction unit and Party A confirm it according to the soil quality on site.
(5) After backfilling, it must be accepted by Party A of the construction unit supervision company, and only after it meets the requirements can it be qualified; Otherwise, Party B shall carry out renovation and rework, and bear relevant expenses.
(6) Quality requirements: meet the design elevation requirements and ensure the site is flat.
Seven. Responsibilities of both parties:
1. Party A's responsibilities:
(1) Party A shall be responsible for the technical disclosure of site construction to Party B and provide Party B with relevant information. ..
(2) Be responsible for organizing the project acceptance and appointing on-site construction representatives to solve the problems involved in Party A's construction. ..
③ Point out the ditches, cables and obstacles in the site to Party B. ..
2. Party B's responsibilities:
(1) is responsible for providing construction land and going through relevant formalities for land use; Responsible for hauling, loading and unloading, backfilling and rolling.
(2) Do a good job in safety education for employees of this unit.
(3) Strictly implement the requirements of the agreement on project quality, safety and time limit for a project, allocate the machinery and workers needed by Party A, obey the arrangement of Party A's construction personnel, and carry out the construction according to the construction specifications.
(4) Abide by the rules and regulations of the site, obey the command of the site management personnel of Party A and the supervision and management of relevant departments of Party A..
⑤ When underground water is found or pipelines and cables are buried, report to the on-site person in charge of Party A in time, and take drainage and waterproof measures.
⑥ Prepare the construction materials according to the specifications, and do a good job of completion acceptance.
⑦ Carry out the construction in strict accordance with the safety measures in the technical operation procedures of earthwork construction, and be responsible for the safety management in the loading, unloading, transportation and backfilling of earth materials. In case of safety accidents, Party B shall be responsible.
Provide the engineering tax invoice when you settle the account today.
Eight, project acceptance:
1, engineering quality, in line with the requirements of the national engineering quality inspection and evaluation standards for excellent grades, with excellent subdivisional work to ensure that the division works well.
2. Acceptance is based on the visas of Party A's construction personnel, representatives of the construction unit and supervision engineer.
3. For quality problems caused by Party B, Party B shall bear all responsibilities and expenses for rework. ..
Nine. Settlement method: based on the completed workload recognized by Party A. ..
Ten, payment and settlement procedures within 30 days after the completion acceptance.
XI。 If the liability for breach of contract fails to pass the completion acceptance of Party A, RMB 20xx shall be paid as liquidated damages for each day of delay.
Twelve. others
1. Any dispute arising from the performance of this Agreement shall be settled through negotiation. If negotiation fails, a lawsuit may be brought to the people's court where the agreement is signed.
2. If Party B's construction force fails to meet Party A's requirements within 2 days (more than 20 earth-moving equipment and more than 3 loading equipment are guaranteed), the construction organization is weak, and the construction period is delayed without reason, Party A has the right to suspend the agreement.
3. This Agreement is made in quadruplicate, with each party holding two copies. It will take effect after being signed and sealed by both parties.
Party A: (Seal) Party B (Seal)
Domicile: domicile:
Legal representative:
Authorized Agent: Authorized Agent:
Tel: Tel:
Bank of deposit: Bank of deposit:
Account number: Account number:
Date of conclusion: year month day.
Article 3 of the Earthwork Backfill Project Agreement Party A:
Party B:
In order to clarify the rights and responsibilities of Party A and Party B, according to the Contract Law of People's Republic of China (PRC), Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and based on the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on the earthwork excavation of this project.
I. Project name:
Second, the project site selection:
Third, the work content:
Four. Scope of work:
Verb (abbreviation of verb) contract term: start date: year month day;
Completion date: year, month and day, and the contract period is days.
Contract price of intransitive verb: This contract is a lump-sum contract with unit price, that is, all expenses such as labor, materials, machinery (including the entrance and exit fees of machinery and equipment), management fees, insurance premiums, profits and taxes required by Party B to complete all the works within the scope of the contract, with the unit price of RMB per cubic meter and the total earthwork volume of RMB.
7. Quality guarantee: Party B shall pay the quality guarantee of RMB10,000.00 Yuan to Party A on the day when the contract is signed, and return it to Party B after the project is completed and accepted. During the construction period, Party B shall not terminate the contract under any excuse, otherwise Party A has the right to deduct the quality deposit of 10000 yuan.
Eight. Project settlement: after the project is completed and accepted, the settlement shall be made according to the measured grid and the actual receiving capacity of Party A and Party B. After the settlement, it shall be paid to% of the settlement price in one lump sum, and the balance shall be paid off.
Nine, engineering quality and technical requirements:
This project is constructed and accepted in strict accordance with the current national quality inspection and evaluation standards for construction projects and the Code for Acceptance of Construction Quality of Building Foundations and Foundation Projects. At the same time, the contract stipulates that:
1, after the completion of earthwork construction, the error between the acceptance elevation and the specified elevation is not greater than100 mm.
2. The fill in the site must be compacted by layers, and the compaction coefficient shall not be less than 95%.
X. Safe construction: Party B shall carry out the construction in strict accordance with relevant national safety construction specifications and take effective safety protection measures. In case of any personal injury, mechanical accident, etc. During the construction operation, Party B shall be responsible, and Party A shall not bear any responsibility.
XI。 Liability for breach of contract: subcontracting is not allowed in this contract. If Party A verifies that Party B has subcontracted, Party A has the right to terminate the contract unilaterally.
12. This contract is made in triplicate, with Party A holding two copies and Party B holding one copy. It will come into effect after being signed and sealed by both parties, and it will naturally become invalid after the project is qualified and the final payment is settled. Other matters not covered shall be settled by both parties through consultation.
Party A (signature and seal):
Party B (signature and seal):
date month year
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Bidding Law of People's Republic of China (PRC) and other relevant laws and regulations, both parties have reached the following contract terms on the construction of this project following the principles of equality, voluntariness, fairness and good faith:
I. Project name:
Subgrade Earthwork of Beiguan Center New Town
Second, the project site selection:
Beiguan Central New City, Yangdong County, Yangjiang City
Third, the project content:
Backfilling and tamping of subgrade earthwork. Backfill 1# road to 1.00 m and 4# road below the design elevation.
Four. Scope of project contracting:
The roads of Beiguan Central New Town 1#, 4# and 5# have reached the target range and belong to the municipal roads that can be implemented by the town government.
Six, the construction period:
This project will be constructed in stages, and Party A will notify the construction period of each stage in writing; Subgrade of residential area 1# and 4# roads is the main road. Backfill to below the design elevation1.3m.
Verb (abbreviation of verb) signing method:
contract for labour and materials
Seven. Start date:
Subject to Party A's written notice.
Eight. Settlement method:
Actual payee settlement
IX. Contract Amount:
The lump sum unit price is 32 yuan /m3 (including tax ticket), and the total price is calculated according to the actual number of recipients.
X. payment terms:
Payment according to the project image progress:
1, once every ten days, pay 70% of the actual earthwork project payment in the current period;
2. Pay to 90% of the total project cost within 10 days after all the projects are completed and accepted;
3. Party B shall pay 95% of the total project cost within 10 days after submitting the official completion drawings and settlement book and passing the examination by Party A (the examination period is 30 days);
4. The remaining 5% of the project funds shall be used as quality guarantee, and shall be paid without interest within 5 days after the expiration of one-year quality guarantee.
Eleven, quality standards:
Construction projects must conform to the technical specifications for highway subgrade construction.
Twelve. Quality and other requirements:
1. Party B must carry out the construction according to the drawings agreed by both parties.
2. The quality of all subdivisional works constructed by Party B must meet the requirements of construction specifications.
3. Party B's construction personnel must follow the correct procedures and shall not cut corners. If Party B is found to have cut corners, Party A will give a certain amount of fine according to the seriousness of the case, or even dismiss Party B without settlement.
4. Before Party B conceals the project, it must be accepted by Party A's on-site quality management personnel.
5. If Party B's construction quality does not meet the Technical Specification for Highway Subgrade Construction, Party B will unconditionally rework it until the construction quality is qualified.
6. Before earthwork backfilling, Party B shall be responsible for measuring the original ground elevation, but shall notify Party A's personnel to participate in the measurement.
7. Party B shall provide Party A with the measurement data signed and approved by both parties immediately after measurement, otherwise the measurement data will be invalid.
8. The earthwork backfilling of this project must be carried out in strict accordance with the slope coefficient of 1: 1.5.
9. Party B must provide a feasible construction plan and construction schedule before commencement.
Thirteen. Schedule requirements and penalties;
1. Party A is responsible for handing over the working face to Party B, and Party B must strictly abide by the progress agreed by both parties, actively arrange the construction and ensure the construction progress.
2. Party B must have sufficient manpower and material resources to ensure the construction progress every day, and shall not delay the construction period for various reasons. If the machinery and equipment are not in place or stop working halfway, Party A has the right to repel Party B and arrange other construction teams to enter the site, and the resulting increase and loss shall be borne by Party B.
14, safety and civilized construction requirements:
1. Every construction worker of Party B must operate in strict accordance with the operating rules, and illegal operation, blind operation, illegal command and risky operation are strictly prohibited. Party B has the obligation to conduct safety education and safety supervision for its workers, and urge its workers to abide by safety rules to ensure that safety accidents do not occur. If all injuries, diseases, disabilities and deaths occur during the construction period (including transshipment), Party A will not be responsible.
2. Party B's contractor shall not direct its own workers to take risks or operate illegally, otherwise it will take full responsibility.
3. Every construction worker of Party B must strictly abide by the safety rules and regulations.
4. Pay attention to safety when walking on the construction site, always pay attention to the steel mesh at the base of the base groove, and the cover plate shall not be moved or taken away.
5. Abide by the labor discipline on the construction site, obey the command of the leaders and safety inspectors, concentrate at work and stick to their posts.
6, without permission shall not be engaged in this type of work, shall not touch the mechanical equipment or electrical equipment, switch box, knife, leakage switch, etc.
7. Ensure safe production and civilized construction, and abide by national and local laws and regulations.
8. Be responsible for all necessary equipment in the construction process, such as labor, machinery and construction.
9. Party B must set up a project management team competent for the construction of this project and operators familiar with the operation. Party B shall attach a report to Party A before entering the site, and appoint it as the person in charge of Party B's on-site representative, responsible for the performance of the contract, and appoint it as a full-time quality controller to supervise the violations in the construction process.
Fifteen. Liability for breach of contract:
If Party B fails to complete the project within the contract period, the construction quality fails to meet the quality requirements agreed in this contract, or the contract cannot be performed due to other actions, Party B shall bear the liability for breach of contract and compensate all direct losses caused to Party A due to its breach of contract.
Sixteen. Supplementary terms:
Matters not covered in this agreement shall be settled by both parties through negotiation or a supplementary agreement shall be signed. This agreement is made in quintuplicate, with Party A holding three copies and Party B holding two copies. It shall come into effect after being signed by the representatives of both parties, and automatically become invalid after Party B settles the completion payment.
Employer: (Seal): Contractor: (Seal):
Legal representative:
Authorized Agent: Authorized Agent:
Year, month, sun, moon, sun.
Article 5 Party A's agreement on earthwork backfilling project:
Party B:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other national laws and regulations, and in accordance with the relevant provisions of the standard contract text formulated by the Ministry of Construction, Party A and Party B, in line with the principles of voluntariness, fairness, honesty and credit, combined with the specific conditions of this project, signed this contract through consultation to clarify the rights, obligations and responsibilities of both parties in the construction process.
A, the project name and contract way, content
1, Project Name: Mianxi Peninsula Residential Quarter
2. Project Address: Hengmian Town, Nanhui District, Shanghai
3. Scope of contract: excavation, backfilling and internal and external transportation of residential foundation, garage and civil air defense project.
4. Contracting method: contracted machinery and vehicles, contracted quality, contracted safety, contracted duration and contracted declaration fee.
Second, the construction period
The total construction period is 32 days, including 25 days of digging and 7 days of backfilling. The specific commencement time shall be subject to Party A's notice, and Party B shall carry out the construction according to Party A's overall schedule.
Third, the settlement unit price
1, the excavation and transportation of underground civil air defense and residential foundation shall be settled by 23 yuan per cubic meter, and the backfilling and transportation of foundation shall be settled by 12 yuan per cubic meter. If the civil air defense floor has a back beam, a small excavator is used, and the mechanical cost is within the unit price of the settlement contract.
2, underground civil air defense and residential foundation excavation, backfill excavation relay and backfill for many times, the mechanical costs are within the settlement contract unit price.
3. The calculation of excavation quantities shall be subject to the written visa of the actual elevation measured by both parties. Before excavation, the elevation shall be buried from the original elevation and foundation drawings, and the volume shall be settled according to the drawings.
4. Party A's settlement payment shall be paid in installments after the acceptance of the residential community structure until the end of February, 65438+20.
Four. Rights and responsibilities of Party A
1, responsible for coordinating construction, technology and quality related to the construction process, and organizing relevant departments to accept visas.
2. Before starting work, Party A shall equip the site electrical box according to the electricity utilization scheme on the construction site.
3. In the process of construction, if Party B delays the construction period due to machinery, unloading points and other reasons, Party A has the right to terminate the contract, impose economic penalties on the construction period and send others to dig backfill soil.
Verb (abbreviation of verb) Party B's responsibility
1. Party B shall send representatives to manage Party B, be fully responsible for construction, technology, quality and safety, be responsible for contacting with Party A, the supervisor and the owner, and handle all problems on site.
2. Party B is responsible for handling relevant formalities with relevant departments before earthwork excavation and backfilling, and doing a good job of cleaning up. The cleaning range is from the construction gate to the unloading point, and Party B will assign special personnel to clean it. If the road surface is untidy and polluted, which leads to the economic punishment of the higher authorities, Party B will be responsible for its expenses.
3. During the construction period, Party B shall be responsible for the pavement, small distribution box and sun lamp in this area.
4. If Party B fails to meet Party A's construction requirements during excavation and backfilling, and delays the construction period due to Party B's own reasons, such as machinery and unloading points, Party B will bear Party A's construction period fine, Party A will terminate the contract, and Party B will leave the construction site unconditionally, and the expenses and responsibilities arising therefrom will be borne by Party B. ..
Controversy of intransitive verbs
Disputes arising from the performance of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it may be submitted to other relevant higher authorities for mediation and arbitration.
Seven. others
1. The supplementary agreement has the same legal effect as this contract.
2. Matters not covered in this contract shall be settled by both parties through consultation.
3. This contract is made in quadruplicate, with each party holding two copies.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 6 Contract Issuing Party: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
Through negotiation, Party A and Party B reach the following agreement on Party A entrusting Party B to build Lanpu Garden Project:
First, the project content:
Including the construction and greening of Lanpu Garden designed by our company (see the drawings for details).
The above-mentioned projects are carried out according to the requirements of drawings jointly reviewed by both parties and the items, specifications, remarks, quantities and requirements listed in the attached budget summary table.
Second, the time limit for a project:
(1) commencement date: the construction period of this project is * * * calendar days, from * * in 2004 to * * in 2004.
(2) During the construction period, the construction period may be extended due to water stoppage, power failure, heavy rain, rainstorm days, etc. or confirmed by Party A in writing.
(3) If it cannot be handed over to the construction site in time due to Party A's reasons, the construction period will be postponed.
Third, the project contract price:
Through negotiation, the total contract price of this contract is RMB one million and eight thousand Yuan only. During the construction, if Party A needs to increase the project due to the change, the settlement shall be made according to the actual situation.
Fourth, the construction mode.
Party B contracts water, electricity and garden construction projects; Package quality, package acceptance, package safety, package construction period and package civilized construction.
(1) Party B is responsible for providing decorative patterns for the construction project, which can only be put into construction after being confirmed by both parties.
(2) During the construction period, Party A shall be responsible for the water and electricity expenses arising from Party B's construction.
V. Payment method of project funds
(1) Within 3 days after the signing of this contract, Party A shall pay Party B a deposit of 30% of the contract price, namely RMB three hundred and twenty-four thousand Yuan only. Party B will arrange personnel to enter the site for construction the next day after receiving the payment.
(2) After 80% of the total project amount is completed, Party A shall pay 30% of the project contract price to Party B within 3 days, namely RMB three hundred and twenty-four thousand Yuan only.
(3) After the project is completed, Party A shall pay Party B 20% of the contract price of the project, namely RMB two hundred and sixteen thousand Yuan only.
(4) Pay Party B 65,438+00% of the project contract price within one month after the completion acceptance, namely RMB one hundred and eighty-eight thousand Yuan only.
Six, process quality requirements:
(1) Party B must carry out the construction in strict accordance with the contents and requirements of the design and construction drawings approved by Party A and the relevant landscaping construction specifications. In the process of construction, Party B must obey the supervision and management of Party A. If Party B is found to have something that does not meet the requirements of the construction drawings and violates the operation specifications, Party A has the right to propose and require rework and modification, and all economic losses caused by its shutdown and rework shall be borne by Party B. ..
(two) the construction process must be recorded and concealed engineering acceptance visa.
Seven, project completion acceptance settlement:
Party B shall submit the completion data and acceptance report to Party A within five days after completion, and Party A shall organize relevant departments to conduct acceptance within five days after receiving the completion acceptance report, and give qualified recognition or put forward rectification opinions according to the design and construction drawings, contracts, supplementary contracts and relevant landscaping standards within five days after acceptance. Party B shall make rectification according to Party A's requirements and bear all expenses arising therefrom. After the acceptance, Party A shall make settlement according to this contract, supplementary contract and additional project visa list, and complete the settlement within 33 working days.
Eight. Liability for delayed breach of contract:
Party B must ensure the quality and quantity within the construction period and complete the project on schedule. If the project is delayed, a fine of 2000 yuan will be imposed for each day of delay; If the project is completed ahead of schedule, RMB 65,438+0,000 will be awarded for each day of completion ahead of schedule. If the project is delayed due to Party A's responsibility or force majeure, Party B shall make a written request, and Party A shall confirm in writing that the construction period can be extended within three days. If Party A fails to make payment according to the contract, and the payment is overdue for three days, Party B has the right to stop work or close the completed project, and Party A shall be responsible for the construction delay and economic losses caused thereby.
IX. Warranty Contents
The quality assurance content shall be implemented according to the relevant building construction acceptance standards.
X. warranty period
The warranty period of landscape architecture engineering and hydropower engineering is 12 months from the date of project completion acceptance. The greening maintenance period is twelve months, counting from the date of completion acceptance. After the maintenance period expires, Party B shall notify Party A in writing for acceptance.
Eleven, several provisions of the two sides in the construction:
(1) During the construction period, if Party A makes any modification or adjustment for any reason, it shall notify Party B two days in advance, and send Party B a modification letter or drawings ... If Party B finds anything inappropriate, it shall report to Party A in writing two days in advance, and the construction can only be started after it is handled by Party A and the design department.
(2) During the construction period, Party B must do a good job in the prevention of production safety, implement various safety measures, ensure the construction safety, assume the responsibility for safe construction, and educate the construction personnel to abide by the law.
(3) Party A is responsible for providing Party B with the construction site (which should meet the requirements of "three links and one leveling"), the location of water and electricity within the construction scope, the location of survey baseline and leveling points, and the underground pipe network map within the construction site. If Party A fails to provide the construction site in time, Party B has the right to postpone the construction period.
(4) Party A is responsible for coordinating the relationship between the construction site and the construction site to ensure the construction progress of Party B. ..
(5) Party B shall assign special personnel to keep in touch with Party A and coordinate the site construction. The civil works undertaken by Party B shall closely cooperate with the relevant installation procedures and require written contact.
(6) After the project is completed, Party B is responsible for cleaning up the garbage within the construction scope, so as to clean up the site after the project is completed.
Twelve. Entry into force and termination of the contract:
This contract shall come into effect after being signed and stamped by the legal representatives of both parties. Upon the expiration of the project warranty period, this contract shall be terminated after Party A settles the payment.
13. This contract is made in duplicate, with each party holding one copy, which has the same legal effect.
Matters not covered in the performance of the contract shall be settled through negotiation as far as possible. Relevant agreements can be countersigned, and the countersigned agreement has the same legal effect as this contract.
Entrusted representative: entrusted representative:
Signature: signature:
Date of signing: Date of signing: