5 Templates of House Waterproofing Construction Contracts

House Waterproofing Construction Contract Sample 1

Party A: _________

Party B: _____________

Party A All the work content of the steel bar work of ______ is entrusted to Party B for construction. After negotiation between Party A and Party B, the following agreement is reached:

1. Contracting method: In principle, the labor contract does not include materials, but the production of steel bars must be included. Mechanical equipment, steel bar flash butt welding equipment, steel bar straightening and stretching equipment, as well as various supporting welding rods, wire binding, lubricating oil and powder used for mechanical equipment, etc. In a word, in addition to the steel bar raw material department, other Party B is responsible for the mechanical equipment, tools, utensils, and scattered materials required for the production and binding of steel bars.

2. Steel bar contract content: Construction shall be carried out in accordance with the contents of the construction drawings. The specific construction content includes the production of steel bars, and the ingredients list shall be prepared in accordance with the drawings and specifications. (Party B must prepare two materials lists, one for construction materials. One copy is the final bill of materials). The production, straightening, welding, binding of steel bars, embedded iron parts, reserved steel bars and protective bars when pouring concrete, etc., and are responsible for checking the bill of materials with relevant departments.

3. Quality requirements for steel bar production and binding: Party B must strictly abide by the construction specifications and construction drawings for batching (the bill of materials must submit one copy of the construction and final accounts to Party A 10 days in advance), and batch the ingredients scientifically and rationally. Observe the operating procedures, use materials rationally, reduce waste, and make according to the material list; bind according to the construction drawings and material list. All debris must be cleaned after the steel bars on each floor are tied to ensure that the acceptance is passed at one time. During the construction process , Rebar replacement is not allowed without authorization. Problems found should be reported and dealt with in a timely manner. If losses are caused by quality problems, a fine of 1-2 times the project cost will be imposed. Materials must be used rationally during the construction process to reduce waste. The welding It means welding. If it is found to be obviously unreasonable, a fine of 1-5 times the price of the wasted raw materials will be imposed.

4. Contracting unit price: Each ton is calculated based on ______ yuan. The project quantity is calculated according to the approved final bill of materials. The settlement at the beginning of the settlement is temporarily based on the construction bill of materials. The hourly labor is subject to the visa. _____yuan/working day.

5. Wage settlement method: 1) The workload must be based on the concrete poured, and settlement can only be made after pouring; 2) The workload payment for the first phase of the project plus or minus zero and below will be based on the actual amount. After calculation, 100,000 yuan will be temporarily withheld as a deposit, and the remaining portion will be paid as normal; 3) For the portion of the first phase of the project that is plus or minus zero, 90% of the workload completed in the previous month will be settled in the first week of each month, and the remaining 10% As a project deposit; 4) The second phase of the project will be settled on the first week of each month, with 90% of the workload completed in the previous month; 50 The second phase of the project has completed 70% of the workload

6. Construction Period : Every month, each floor will be completed according to the construction schedule issued by the project department. If the construction period is delayed due to Party B's fault, a fine of 300 yuan will be imposed for each day of delay, and no advance is required.

7. Party B’s personnel must conduct civilized construction after entering the site, obey the instructions of Party A’s construction site management personnel, and actively cooperate with the construction workers. If Party B disobeys the management of Party A's management personnel, the construction staff has the right to fine Party B or expel Party B from work.

1. Party B’s personnel must abide by the laws and regulations and are not allowed to fight. If the above phenomenon occurs, Party A has the right to fine Party B or expel Party B from the game.

2. Party B’s personnel are not allowed to steal on site. Once discovered, the lighter case will be fined ______ yuan, and the serious case will be sent to the police.

3. Party B’s personnel are not allowed to defecate on the floor. If found, they will be fined ______ yuan. The feces must also be removed. If the defecation is not removed, an additional fine of 300 yuan will be imposed. If Party B's personnel find that someone from another team has defecated on the floor, and the evidence is indeed reported, they will receive 80% of the fine as a bonus.

8. Party B must pay attention to safety during construction. The team leader should strengthen safety education for the migrant workers in the class, strictly follow the safety operating procedures for construction, strictly implement Party A's rules and regulations and surrounding safety protection, and if any irregularities are found, Safety factors shall be raised to Party A in a timely manner.

1. Party B’s personnel must wear safety helmets when entering the construction site and are not allowed to wear slippers or go barefoot. Once found, each person will be fined 30 yuan each time. If a person does not wear a safety helmet and slippers at the same time, , consider one person to be fined twice.

2. During the construction process, Party B will be solely responsible for all economic losses and liabilities caused by any safety accidents caused by Party B. Party A will not bear any responsibility or economic losses; safety accidents caused by other reasons The accident shall be borne by the responsible party.

9. During the construction period, Party B must designate an on-site person in charge, and he must be on-site to direct every day. Anyone who is not on-site will be fined 100 yuan per day.

10. This agreement is made in five copies, four copies for Party A and one copy for Party B. This agreement will take effect from the date of signing and will automatically expire after Party A pays Party B the project payment upon completion of the project.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (signature): _________

_________year____month____day

House waterproofing construction contract template 2

Construction unit: Hereinafter referred to as Party A;

Construction unit: Hereinafter referred to as Party B;

Contract name:

< p> According to relevant laws and regulations such as the Labor Law of the People's Republic of China and the Contract Law of the People's Republic of China, in line with the attitude of being responsible to both parties, the principles of fairness, justice, mutual benefit and mutual benefit between Party A and Party B are , *** jointly drafted the contract for this project and implemented it strictly and conscientiously.

The content is as follows:

1. Contracting method: technical guidance and contracting of labor and materials; the price is shown in the quotation list of the construction plan.

2. Scope of contracting: roof expansion joint treatment, roof, yin and yang corner treatment and protective layer.

3. Total project cost (approximately 34,108.00 yuan, capital: 30,000,108.00 yuan): subject to the actual square footage on site;

4. Payment method:

1. Party A will pay Party B yuan for materials within one working day after Party B enters the construction site.

2. If the project is completed and accepted, Party A will pay Party B 92% of the total project price;

3. 8% of the total project price will be reserved for this project quality deposit for one year. At the end of the period, Party A shall allocate the full amount to Party B;

5. Project quality and construction safety

1. Party B must complete the project in accordance with the roof waterproofing maintenance construction plan of this project and ensure quality and quantity. Construction; the construction shall be unconditionally supervised by Party A’s construction representative and quality supervision person, otherwise Party B will be responsible for any rework losses caused.

2. Party B must achieve safe production, civilized construction, and respect the national customs of the local people during construction. Party B will be responsible for any work-related injuries and disputes caused thereby.

3. If quality problems are discovered during the project acceptance process, the contractor shall be responsible for rework and repairs and bear all rework and repair costs. If any economic losses are caused, the contractor shall be responsible for compensation.

6. Completion acceptance: Party B shall improve the pictures or text materials during the construction process, as well as the acceptance list, classify and archive them and hand them over to Party A.

7. Responsibilities of both parties

1. Party A is responsible for coordinating all matters in the project location.

2. Party A guarantees that the project will have water, electricity and road connections.

3. Party A provides convenience for Party B’s production and life, and Party B shall bear the expenses.

4. If Party B discovers a change in the construction plan during construction, it must obtain Party A’s consent before it can be implemented.

5. Party B must submit the prepared technical design and construction plan to Party A for record before construction, and provide Party A with construction memorabilia and construction records.

6. During the construction period of the project, Party A may send personnel to inspect and supervise the project progress and fund usage at any time. Party B shall report the project progress and fund usage to Party A on a monthly basis, and Party A shall regard it as Funds will be allocated based on the progress of project completion.

7. Within 3 working days after the completion of the project, Party B shall submit the application acceptance report and completion data to Party A. Party A will organize relevant departments to participate in the acceptance inspection. After the acceptance is passed, it will be handed over to Party A for management and use.

8. Contract term: , beginning on the day of the year and month - ending on the day of the year and the month of the year.

9. Party B does not assume any responsibility for quality problems caused by man-made or force majeure factors in this project. If Party A needs Party B to continue repairs, Party B has the right to charge additional fees.

10. Disputes and Resolution

If a dispute arises between Party A and Party B during the execution of the contract, they should resolve it through negotiation based on the principle of benefiting the implementation of the project, or apply for arbitration to the arbitration committee where the project is located. , or resolve through judicial procedures.

11. The matters covered by this contract shall be separately agreed upon by both parties.

12. This agreement will come into effect after being signed by the authorized representatives of both parties or their authorized agents and stamped with the official seal of the company. This Agreement is made in two copies, with each party holding one copy, and is equally valid.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): _________ Legal representative (signature): _________

_________year____month____day_________year____month____day

House waterproofing construction contract template 3

Contracting party: _________(hereinafter referred to as Party A)

Contractor: _____________ (hereinafter referred to as Party B)

Contracting method: _________

In accordance with the "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China" and other relevant laws and administrative regulations, regarding matters related to the construction of this project, following the principles of equality, voluntariness, fairness and good faith, the following agreement has been reached through negotiation between the two parties:

Article 1 Construction Period

1.1 The construction of this contract project is scheduled to start on the date; the number of calendar days in the year is ______ days. If the construction period needs to be advanced, the total number of days in the total contract period calculated based on the agreed start and completion dates will be ______ days.

1.2 The corresponding measures taken by the contractor to advance the construction period and the resulting increased economic expenditure:

1.3 The rewards and penalties for advancing or delaying the construction period shall be stipulated in the contract after negotiation between the two parties.

Article 2 The drawing issuer shall provide /set of drawings to the contractor on ______month_______year______.

Article 3 Representatives of the contract issuing party and the contractor at the construction site. Name of project manager of the contractor: _________; name of project leader of the contractor: _________.

Article 4 Contractor's Work

Complete the land acquisition, compensation for young crops and trees, relocation of cemeteries, demolition of houses and structures, and removal of above-ground, overhead and underground obstacles before the start of construction. Connect the water, electricity lines and roads required for construction to the construction site and ensure the needs during the construction period. Provide the contractor with the engineering geology and underground pipe network line information of the construction site, submit the legal procedures for relevant certificates and approvals, and set the standard Submit the location of the coordinate control points to the contractor in writing and submit them for inspection on site. Coordinate and deal with the protection of buildings, structures (including cultural relics protected buildings), ancient and valuable trees and underground pipelines around the construction site, and construction disturbance issues. , organize a joint review of drawings and design disclosures within ______ days after the contract is signed, and confirm it within ______ days after receiving the construction organization design (or construction plan) and progress plan provided by the contractor. When construction is carried out in a toxic and harmful environment, the contractor shall provide corresponding protective measures in accordance with relevant regulations and bear relevant economic expenditures.

Article 5 Contractor’s Work

5.1 Submit monthly construction plan and completed project progress statistical report to the contracting party every day.

5.2 Comply with the management regulations of the relevant national and municipal departments on traffic and construction noise at the construction site, be responsible for safety, cleanliness and sanitation and other work, and do a good job in keeping the buildings and structures around the construction site (including cultural relics) Protected buildings), ancient and valuable trees, and underground pipelines: When underground obstacles and cultural relics are discovered, report them to the relevant departments in a timely manner and take effective protective measures, and dispose of them in accordance with relevant specific regulations. The contractor shall bear the costs incurred and the delayed construction period shall be accordingly. postponed. Submit the construction organization design (or construction plan) and progress plan to the contractor within 5 days after joint review of drawings and design submission. If the contractor fails to complete various tasks as stipulated in the contract, he shall bear the resulting economic losses and the construction period will not be extended.

Article 6 Project Quality Inspection and Acceptance

6.1 When the project meets the coverage or cover conditions or reaches the intermediate acceptance position, the contractor shall conduct self-inspection and notify the contractor 48 hours in advance. After participating, passing the acceptance inspection, and the contractor signing the acceptance record, the concealment and construction can be continued. If the project quality meets the specification requirements and the contract-issuing party does not sign the acceptance record, it can be deemed that the contract-issuing party has approved it, and the contractor can proceed with concealment or continue construction. If the acceptance fails, the contractor will revise it within a limited time and re-accept it. The economic expenditure caused by incorrect correction by the contract-giving party or other reasons not caused by the contractor shall be borne by the contract-giving party. The inspection should not affect the normal progress of the construction. If it affects the normal progress of the construction and the inspection fails, the contractor will be responsible for the costs that affect the normal construction. In addition, the economic expenditure affecting normal construction shall be borne by the contractor. The construction period will be extended accordingly.

6.2 The project meets the conditions for completion acceptance. The contractor shall provide complete completion information and completion acceptance report to the contracting party in accordance with the relevant regulations of the country and this city on project completion, and the contracting party shall organize acceptance within 10 days. If the contract issuing party cannot organize acceptance on the agreed date, it shall bear the project custody responsibility and payable fees from the day after the last day of the agreed period. After the contract issuing party and the contractor have completed the project completion acceptance procedures, the contract issuing party shall report the quality record of the completed project to the quality supervision agency in accordance with relevant regulations within 5 days. This contract will be terminated. The contractor shall be responsible for the quality warranty of the project delivered to the contractor during the quality warranty period in accordance with laws, administrative regulations or relevant national regulations on project quality warranty.

Article 7 Design Changes and Contract Price Adjustments

7.1 During construction, the employer makes changes to the original design. After approval, the employer shall report to the contractor 10 days before the change. The contractor shall issue a written notice of change, otherwise, the contractor shall have the right to refuse the change. The contractor makes changes according to the notice and submits complete information on the change price report according to the agreed adjustable contracting method within 5 days. The economic expenses and losses of the contractor caused by the change shall be borne by the contract issuing party, and the contract issuing party receives the change price report. It must be signed within 5 days from the date of delivery. If it is not signed without justifiable reasons, it will automatically take effect 5 days from the date of delivery of the price change report, and the construction period delayed accordingly will be postponed accordingly.

7.2 The contracting cost of this project will be adjusted as follows according to the adjustable contracting method:

Article 8 Project Price and Settlement

8.1 Both parties shall adjust the contracting cost according to the national and local conditions. The relevant municipal authorities currently stipulate that after the contract takes effect, the contract issuing party advances or pays the project payment to the contractor in installments as stipulated in the table. If the contract issuing party fails to allocate the project payment on time, it will bear the interest on the payable from the date of payment.

Article 9 Supply of Materials and Equipment

9.1 The contractor shall supply materials and equipment in accordance with the "List of Materials and Equipment Supplied by the Contractor" (attached) agreed upon by both parties. If it is inconsistent with the "List" shall bear corresponding liability for breach of contract.

9.2 Both the contracting party and the contractor shall provide product qualification certificates for the materials and equipment they are responsible for supplying; if products do not meet the design and specification requirements, they shall re-purchase products that meet the requirements, and each party shall bear the resulting consequences. cost.

9.3 When the contractor needs to use substitute materials, they must be approved by the representative of the contracting party before they can be used. The increase or decrease in costs will be agreed upon by both parties.

Article 10 Disputes

When a dispute arises between the contract issuing party and the contractor, they may negotiate or apply for mediation by the construction contract management agency in conjunction with the relevant departments. If you are unwilling to mediate or the mediation fails, you can use one of the following methods to resolve the dispute:

The first dispute resolution method: apply to the _________ Arbitration Commission for arbitration;

The second dispute Solution: File a lawsuit in _________ People’s Court. Both parties agree to resolve the dispute in accordance with the ______ dispute resolution method.

Article 11 Breach of Contract

If the contracting party or the contractor fails to perform its various obligations in accordance with the terms of this agreement and engages in behavior that makes it impossible to perform the contract, it shall bear the corresponding breach of contract. Liability, including payment of liquidated damages and compensation for all economic losses caused to the other party by its breach of contract. Unless both parties agree to terminate the contract, or the contract cannot be performed due to one party's breach of contract, the defaulting party shall continue to perform the contract after assuming the above liability for breach of contract.

Article 12 Number of Contract Copies

This contract is in duplicate and is equally valid, and shall be kept separately by the contracting party and the contractor.

The supplementary provisions of Article 13 are as follows:

Construction materials. Before applying the topcoat, notify the contractor to determine the color of the topcoat. The maximum difference in raw material specifications is only allowed to be one level. ______The incoming materials are submitted to the contracting party for acceptance. Notify the contractor before discharging materials. The test should have water conservancy qualifications and be reported to the contractor for approval.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (signature): _________

_________year____month____day

House waterproofing construction contract template 4

Party A: Contact number:

Party B: Contact number:

Party A has a house located at No. 56, Xincheng Group 3 Building, in order to safeguard the common interests of both parties A and B and ensure construction quality and safety, this construction agreement has been signed by both parties after equal consultation.

1. After Party B enters the house, he should conduct on-site inspection and work with the construction personnel to make a safety production plan. Otherwise, construction should not be carried out if the conditions are not mature.

2. Safety protection equipment during construction must be in place, otherwise construction will not be allowed. Party B shall be responsible for accidental personal injuries and losses caused by accidents during construction operations.

3. Party B should ensure the quality of the project. (Refer to the local project level) Party A should not be too picky. If there is rework, the cost will be borne by Party B.

4. The total construction volume of the project is square meters, calculated in RMB. The cost will be paid in one lump sum after the project is completed, and Party A shall not default.

5. This agreement is made in two copies, with Party A and Party B each holding one copy. This contract will take effect from the date of signature. Any matters not covered shall be negotiated by Party A and Party B.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (signature): _________

_________year____month____day

________year____month____day

House Waterproofing Construction Contract Sample 5

Party A: Contact number:

Party B: Contact number:

1. After entering the house, Party B should conduct on-site inspection and work with the construction personnel to make a safety production plan. Otherwise, construction should not be carried out if the conditions are not mature.

3. Party B shall ensure the quality of the project. (Refer to the local project level) Party A shall not be too picky. If there is rework, the cost shall be borne by Party B.

4. The total construction volume of the project is square meters, calculated in RMB yuan. The cost will be paid in one lump sum after the project is completed, and Party A shall not default.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): _________ Legal representative (signature): _________

_________year____month____day______year____month____day

House waterproofing construction contract template 5 related articles:

★ Roof waterproofing Construction contract template

★ Roof waterproofing construction contract agreement

★ Simple waterproofing construction contract template

★ Waterproofing construction agreement

★ Waterproofing agreement template

★ 5 simple construction contract templates

★ Construction project waterproofing construction contract template

★ Roof waterproofing maintenance project construction contract template< /p>