With the strengthening of people’s legal awareness, contracts appear more and more often. Signing a contract can ensure that our legitimate rights and interests are protected by law. What kind of contracts have you seen? The following are real estate earthwork contract templates (selected 6 articles) that I have compiled for you. You are welcome to share them. Real Estate Earthwork Contract 1
Party A: (contractor)
Party B: (contractor)
According to the "Contract Law of the People's Republic of China and the People's Republic of China" 》 and relevant laws and regulations, in order to clarify the rights, obligations and responsibilities of both parties in the project contracting and ensure the comprehensive completion of the project tasks, under the principles of voluntariness, equality and mutual benefit, Party A and Party B agree to sign this contract after negotiation.
Article 1 Project Overview
(1) Project Name:
(2) Project Location:
(3) Project Scope : According to Party A’s request, Party B will transport the soil to the site designated by Party A (i.e. in R&F Bay) for dumping. Party A is responsible for the excavators, bulldozers and other machinery needed to level the earth and clean up the site. However, we are not responsible for the earthwork work volume of this contract, which is about 35,000 cubic meters and about 2,000 horse-drawn trucks.
(4) Total project cost: The comprehensive unit price of this contract, as determined by both parties, is: RMB 230 per horse-loaded vehicle (the earth volume of each horse-loaded vehicle shall not be less than 20 cubic meters (the amount of loosened earth), Otherwise, Party A may not charge it to Party B), and the total project cost is tentatively set at RMB 500,000.
Article 2 Project Period
According to the negotiation between the two parties, the project period will start from xx, month xx, xx, and end on xx, month xx, xx. If unforeseen or force majeure occurs, The construction period has been postponed.
Article 3 Project Quality
The amount of earth transported by Party B to Party A is original mountain loess, which can meet the requirements for backfill compaction. It will be dumped at the place designated by Party A. Party B guarantees The amount of earthwork per horse load shall not be less than 20 cubic meters (the amount of loosened earth), otherwise Party A may not measure it to Party B.
Article 4 Project Price Settlement and Project Payment Appropriation
(1) The earthwork transported by Party B shall be measured by truck. The measurement shall be valid only if signed by the staff appointed by Party A. This contract All project costs are settled based on the actual completed project volume.
(2) Project payment allocation: Party A pays Party B 80% of the project progress payment based on the monthly construction volume.
Article 5 Responsibilities of both parties
(1) Responsibilities of Party A
1. Ensure that the road section entering R&F Bay site can be driven by Party B’s vehicles, and that the road sections traveled are Party A is responsible for any damage to the concrete road surface.
2. Party A will send representatives to carry out technical and quality supervision, measurement signatures and acceptance procedures at the construction site to solve problems that should be solved by Party A.
3. If Party B’s transportation vehicles are delayed or stopped due to Party A’s reasons, the construction period will be postponed accordingly.
4. Project changes: Party A should notify Party B three days in advance and sign a supplementary contract or apply for a construction visa separately.
5. After the project is completed, Party A should organize specialized personnel to conduct acceptance inspection.
6. (Supplement)
(2) Responsibilities of Party B
1. According to Party A’s request, Party B will transport the earthwork to the site designated by Party A for dumping. Unload. Ensure that there is no fraud in measurement, otherwise Party A has the right to punish Party B.
2. Party B shall strictly organize the construction in accordance with the prepared construction plan.
3. Party B shall formulate safety measures and strengthen safety education for on-site construction personnel. If a life safety accident occurs, Party B shall be fully responsible for it.
4. Party B shall reasonably organize the construction and deployment of machinery and vehicles to ensure that the project is completed on schedule.
5. Party B shall obey the unified command of Party A’s construction site representative.
Article 6 Contract Disputes
All disputes arising from the performance of this contract shall be resolved by negotiation or mediation between the parties. If negotiation or mediation fails, choose one of the following two methods. (Tick √ under the selected option. If you choose arbitration method, please indicate the specific arbitration committee).
1. Submit
2. Proceed to the People’s Court in accordance with the law ( )
Article 7 Supplementary Provisions
(1) This contract begins It will come into effect after being stamped and signed by both parties, and will become invalid upon completion of the performance of the contract.
(2) If there are any matters not covered in this contract, both parties can agree on additional terms based on the specific circumstances so that both parties can abide by them.
(3) This contract is made in two copies, with Party A and Party B each holding one copy.
Article 8 Additional Clauses
If the earthworks are not completed as scheduled within the specified construction period (the construction period is two months, excluding rainy days), resulting in project delays and resulting losses Party B is responsible.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
_________year____month__________year____month____real estate earthwork contract 2
Party A (full name): (hereinafter referred to as Party A).
Party B (full name): (hereinafter referred to as Party B).
In accordance with the "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China" and other relevant laws and administrative regulations, we follow the principles of equality, voluntariness, fairness and good faith. , this contract is concluded by consensus between Party A and Party B.
1. Project overview.
Project name:
2. Construction period.
Commencement date: The project is scheduled to start on xx; Completion date: The project is scheduled to be completed on xx, xx; The total number of calendar days in the contract period is: days.
3. Project quantity and project price.
The quantity of this project is cubic meters, and the unit price (fixed unit price) is/cubic meter. The total project price is RMB, and the actual project price shall be implemented in accordance with paragraphs 8 and 9 of this contract.
4. Party A’s responsibilities and obligations.
1. Party A shall delineate the specific construction scope for Party B.
2. Party A provides Party B with access to the construction site to ensure that Party B’s vehicles enter the construction site.
3. Party A provides Party B with a water source for washing vehicles, and Party B is responsible for water pipes and other equipment.
5. Party B’s responsibilities and obligations.
1. Party B is responsible for the earthwork construction within the scope designated by Party A in this community. Party B shall strictly carry out construction within the scope designated by Party A. Any construction carried out by Party B without Party A's consent will not be measured by Party A.
2. Party B shall strictly abide by the various management rules and regulations of Party A’s construction site.
3. The soil used by Party B for construction must meet the requirements of Category I and II soil, and must not be mixed with branches, weeds, construction waste and other debris that are not suitable for planting and greening.
4. Party B is responsible for the entire process of earthwork purchase, transportation, filling, leveling, rolling, etc., and is responsible for all safety, civilization, environmental protection, traffic and other accidents that may occur during the entire process. Full responsibility.
5. Party B’s vehicles shall be flushed when entering and leaving the construction site area, and shall not affect Party A’s sanitation work.
6. Party B decides where to purchase the earthwork and how to transport the earthwork. Party A will not interfere, but Party B shall abide by relevant national and local laws and regulations, and shall not engage in work in the name of Party A. other activities, otherwise Party A will hold Party B accountable.
7. Party B shall arrange full-time personnel to be responsible for on-site construction and issue a letter of entrustment and corresponding identity certificates.
8. Party B shall pay a one-time performance deposit of RMB 10,000 to Party A. Party A will return it to Party B after all payments for the project are completed. This performance deposit shall not accrue interest.
6. Quality and safety.
1. During the construction process, Party B shall strictly implement the construction plan formulated by Party A to ensure construction quality.
2. Party A will arrange dedicated personnel to supervise and manage Party B’s construction. Party B shall unconditionally obey the instructions of Party A’s on-site management personnel.
3. Party B shall abide by the relevant management regulations on production safety in engineering construction and Party A’s various safety rules and regulations in the construction site, and organize construction in strict accordance with safety standards.
7. Project acceptance.
After Party B completes the project, it shall first conduct a self-inspection. After passing the self-inspection, it shall notify Party A in writing. Party A will organize personnel to conduct acceptance inspection. After Party A passes the inspection and acceptance, Party B shall deliver it to Party A.
8. Confirmation of project quantities.
Engineering measurement is based on the actual amount of work, and the amount of earthwork is measured according to the volume after compaction. Before the start of construction, Party A and Party B measure the elevation of the site. After Party B completes the work, both parties re-measure the elevation of the filling soil, so that Calculate the amount of filling work.
9. Contract price and payment.
This project is contracted in the form of unit price. The unit price (fixed unit price) is determined by both parties as yuan/cubic meter, and the contract price is determined based on the actual amount of work completed. If the total contract price is paid to Party B within one month after the project is inspected and accepted by Party A, the remaining price will be paid in full after the overall project is completed and delivered.
10. Resolution of disputes.
If a dispute arises between Party A and Party B during the performance of this contract, it shall be settled through friendly negotiation between Party A and Party B. If the negotiation fails, the Party may apply for arbitration to the Shijiazhuang Arbitration Commission. If the dispute still cannot be resolved, the Party may apply to the Shijiazhuang City Arbitration Commission for arbitration. The People's Court filed a lawsuit.
11. Effectiveness and termination of the contract.
This contract will come into effect after being signed and sealed by both parties. The project will be terminated after Party A has accepted it and paid the full price.
12. This contract is made in two copies. Party A and Party B each hold one copy. It will take effect after being signed and sealed by both parties.
Party A: (official seal)
Legal representative:
Authorized agent:
Telephone:
Fax:
Date: XX, XX, month XX
Party B: (official seal)
Legal representative:
Authorized agent Person:
Telephone:
Fax:
Date: XX, XX, XX, XX. Real Estate Earthwork Contract 3
Contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
According to consensus reached by both parties , regarding Party A entrusting Party B to build the Lanpu Garden project, the following agreement is signed:
1. Project content:
Including our company’s design of Lanpu Garden construction, greening, and others Part of the project (see drawings for details).
The above projects are constructed in accordance with the requirements of the drawings jointly reviewed by both parties and the items, specifications, remarks, quantities, and requirements listed in the attached budget summary.
2. Construction period:
1. Construction start date: The construction period of this project starts from the month and day of 20__ and ends on the month and day of 20__, *** calendar days.
2. During the construction period, if there are water outages, power outages, heavy rains, rainstorms, etc. or due to Party A’s written confirmation, the construction period may be postponed.
3. If Party A cannot hand over the construction site in time due to Party A’s reasons, the construction period will be postponed.
3. Project contract price:
After negotiation, the general contract price of this contract is RMB: 1,080,000 yuan. If Party A makes changes during the construction process and needs to add additional work, the settlement will be based on actual settlement.
4. Construction Method
Party B shall contract the work and materials for the water, electricity and garden construction projects; it shall guarantee the quality, acceptance, safety, construction period and civilized construction.
1. Party B is responsible for providing decorative samples of the project to be constructed, which must be confirmed by both parties before materials can be input for construction.
2. During the construction period, Party A is responsible for the water and electricity expenses incurred by Party B during the construction.
5. Project payment method
1. Within 3 days after the signing of this contract by Party A and Party B, Party A will pay a deposit of 30, the contract price, which is RMB 320,000. Four thousand yuan. Party B will arrange for personnel to enter the site for construction the next day after receiving payment.
2. After 80% of the total project is completed, Party A shall pay Party B the contract price of 30% of the project within 3 days, which is RMB: 324,000 yuan.
3. After the project is completed, Party A shall pay Party B the project contract price of RMB 20,000, i.e., RMB 211,000, within one week.
4. Within one month after the completion acceptance is passed, the project contract price of 10, that is, RMB: one hundred and eighty thousand yuan shall be paid to Party B.
6. Project quality requirements:
1. Party B must strictly carry out construction in accordance with the content and requirements of the design and construction drawings approved by Party A and the relevant landscaping construction specifications. During the construction process, Party B must obey Party A's supervision and management. If Party B is found to have performed construction matters that do not meet the requirements of the construction drawings or violate operating specifications, Party A has the right to propose and require rework and modification, and all economic losses caused by the stoppage and rework All are borne by Party B.
2. The construction process must be well recorded and a concealed project acceptance visa issued.
7. Project Completion Acceptance Settlement:
Party B shall submit the completion information and acceptance report to Party A within five days after completion, and Party A shall organize relevant matters within five days after receiving the completion acceptance report. The department will conduct acceptance inspection and give qualified approval or put forward rectification opinions based on the design and construction drawings, contracts, supplementary contracts and "Relevant Landscaping Standards" within five days after acceptance. Party B must make rectifications as required by Party A and bear all costs incurred thereby. After passing the acceptance inspection, Party A will make settlement based on the contract, supplementary contract and additional project visa list, and the settlement will be completed within thirty-three working days.
8. Liability for delayed breach of contract:
Party B must complete the project according to quality, quantity and schedule during the construction period. If the project is delayed, a penalty of RMB 2,000 will be imposed for each day of delay; if the project is completed ahead of schedule, a reward of RMB 1,000 will be awarded for each day completed ahead of schedule. If the project is delayed due to Party A's responsibility or force majeure factors, Party B makes a written request, and Party A confirms in writing within three days that the construction period can be extended. If Party A fails to pay as stipulated in the contract and is overdue for three days, Party B has the right to stop work or enclose the completed project. Party A will be responsible for the delay in construction and economic losses caused by this.
9. Warranty content
The quality assurance content shall be implemented in accordance with the relevant construction acceptance standards.
10. Warranty period
The warranty period for garden construction projects and hydropower projects is twelve months from the date when the project is completed and accepted. The greening maintenance period is twelve months, and the maintenance period starts from the date of completion and acceptance. After the maintenance period expires, Party B will notify Party A in writing to accept it.
11. Several stipulations between the two parties during the construction:
1. During the construction period, if Party A makes modifications or adjustments for any reason, Party A shall notify Party B two days in advance and issue a modification letter or Modify drawings. If Party B finds anything inappropriate, it shall report it to Party A in writing two days in advance, and the construction will begin after Party A and the design department handle it.
2. During the construction period, Party B must do a good job in safety production prevention, implement various safety measures, ensure construction safety, assume the responsibility for safe construction, and educate construction personnel to abide by the law.
3. Three days before the start of construction, Party A is responsible for providing Party B with a construction site (which should comply with the requirements of "three connections and one leveling"), the location of water and electricity within the construction scope, the location of measurement baselines and leveling points, and providing the construction site Map of the underground pipe network within the area.
If Party A fails to provide the construction site in time, Party B has the right to postpone the construction period.
4. Party A is responsible for on-site construction site relationship coordination to ensure Party B’s construction progress.
5. Party B will send a dedicated person to keep in contact with Party A and coordinate the on-site construction. When Party B undertakes a civil construction project, it shall closely cooperate with the relevant installation procedures and requires written communication.
6. After the completion of the project, Party B is responsible for cleaning up the garbage within the construction area to ensure that the site is clean after the completion of the project.
12. Effectiveness and termination of the contract:
This contract will take effect after being signed by the legal representatives of both parties and stamped with official seals. When the project warranty period expires and Party A settles the payment, the contract will be terminated.
13. There are two copies of this contract. Party A and Party B each hold one copy, which has the same legal effect.
Unfinished matters in the performance of the contract should be resolved through negotiation as much as possible. The relevant agreement can be re-signed, and the re-signing of the relevant agreement will have the same legal effect as this contract.
Authorized representative: Authorized representative:
Signature: Signature:
Signing date: Signing date: Real estate earthworks contract 4
A Party:
Party B:
In order to meet the relevant needs of the national agricultural comprehensive development project, Party A, after inviting bids, will now move, accumulate and level the earthwork of the national agricultural development project in Dawei, the landlord. Party B was contracted to be responsible for the construction, and after consensus reached by both parties, the following agreement was reached:
1. Party B’s transportation and leveling of earth shall be calculated based on the actual pond area. The price of transporting and excavating flat soil is RMB/m3, and the price of dumping cubic meters within the bidding section is RMB/m3. (Including cleaning up debris within the construction section)
2. Party B must transport and level the earthwork within 20 clear days after signing the contract. The earthwork at the bridge head will be added according to the requirements of the village committee after the bridge is completed.
3. The 10,000 yuan project deposit paid by Party B will be returned after the project is completed and the village committee accepts it.
4. Payment method: Party A will pay Party B 25% of the total project payment when the project is halfway through, 25% at the end of the year, and the balance will be settled at the end of XX.
5. During the implementation of the project, Party B must collect soil from the area designated by Party A. All safety responsibilities are the responsibility of Party B and have nothing to do with Party A.
6. Unfinished matters shall be resolved through negotiation between the two parties.
7. This agreement is made in triplicate, with each party holding one copy and witnessing one copy from Fangyuduo Economic and Management Station. It will take effect after being signed and sealed by the three parties.
Party A: Party B:
Witness:
_________year____month____real estate earthwork contract 5
Shipper (Party A): _________
Carrier (Party B): _________
Both parties to the contract, on the basis of equality, voluntariness and consensus through consultation, agree on Zhangzhou City Longwen The following agreement has been reached regarding the transportation operations of the T-shaped port dredging and construction project on the Jiujiuwan tributary of the District:
The first transportation task
Party B is responsible for ________ dredging and renovation construction For project earthwork transportation operations, the transportation volume undertaken by Party B shall be calculated based on the actual transportation volume during the performance of the contract.
Party A will uniformly allocate, manage, schedule and direct Party B’s transportation tasks according to the requirements of the operation time, operation location, working surface, project progress and transportation quantity determined by the project. Party B must obey .
Article 2 Contract Period
According to the construction contract period, it shall be from the start date required by the contract to the completion date of project construction.
Article 3 Transportation starting and ending places
Starting point: Construction site Arrival place: Arranged by Party B
Article 4 Freight settlement
The freight is calculated based on ___ yuan per cubic meter without a truck.
Article 5 Transportation Quality and Safety
Party B must complete various transportation tasks in accordance with the work progress, operation time, working surface, transportation starting and ending places, and transportation quantity specified by Party A.
Party B must bear all costs and traffic police penalties during the performance of the contract. Party B will be responsible for all types of personal or vehicle transportation accidents.
Article 6 Fuel Supply
The fuel costs required by Party B for transporting vehicles shall be borne by Party B.
Article 7 Transportation Management
1. Party B’s transportation vehicles must obey Party A’s unified management, dispatch and command, strictly abide by the traffic rules at the construction site, and actively maintain the traffic order at the construction site. Ensure the smooth flow of roads and transportation safety at the construction site. No random parking, random leaning, random loading or unloading, no fighting for the right of way, no speeding or overloading. During transportation, transportation vehicles must not cause dust pollution, road pollution and noise pollution to the surrounding area.
2. Party B shall complete various transportation tasks on time, with good quality and quantity.
3. Party B is responsible for Party B’s food, accommodation and vehicle parking space at its own expense.
4. The transportation operation time of Party B’s transportation vehicles shall be uniformly arranged by Party A, and an on-time operation system shall be established, and no late arrival or early departure shall be allowed. If the transportation operation really needs to be suspended due to vehicle maintenance or other special reasons, a written application should be submitted to Party A one day in advance, and the transportation operation can be suspended only with Party A's approval. (Party A has the right to arrange for the inland transportation of earth)
For matters not covered in this contract, a written supplementary agreement may be signed after both parties reach an agreement through negotiation. This contract will come into effect after being signed by both parties or their signing representatives. It is made in two copies, with each party holding one copy.
Party A (official seal): _________
Party B (official seal): _________
Legal representative (signature): _________
Legal Representative (Signature): _________
_______year____month____day
_______year____month____day Real Estate Earthwork Contract 6
p>Party A: _________
Party B: _________
According to the "Contract Law of the People's Republic of China" and relevant regulations, Party A and Party B shall act on the basis of mutual advantage and mutual benefit. In accordance with the principle, regarding the transportation matters of the earthwork reclamation project contracted by Party B to Party A, the two parties reached the following contract terms through friendly negotiation, and both parties agree to strictly abide by them.
1. Project Overview
1. Project Name: _________
2. Project Location: ______
3. Total Project Quantity: ________.
2. Project transportation distance and price
The project period is one year (sunny working days)
Content: Party A will be the legal contractor The earthwork loading and transportation project of the earthwork engineering project is contracted to Party B to transport the earthwork to the location designated by Party A.
1. The vehicle is designated as a _____ cubic rear eight-wheel model (specifications: length, width and height are _____m, _____m, _____m or _____m, _____m, _____m respectively). When Party B's vehicle is being loaded, if the carriage is damaged to _____ centimeters, the loading party shall compensate it. When dumping earth and rocks, if there are stones that exceed the size of the truck and cannot be dumped, they will stop there. Party A will pay 400 yuan per hour.
2. The distance of the transportation route is _____ kilometers. The starting unit price of each truck of earth and stone (which is zero kilometers) is RMB _____ yuan, and an additional RMB _____ yuan is added for each kilometer.
3. The vehicle transportation fee does not include any taxes, and any taxes will be borne by Party A.
4. If the vehicle tilts and sinks dangerously when loading earth and stone, Party A shall provide a forklift to assist in solving the problem.
Party A should provide sufficient loading machinery. If insufficient machinery causes Party B's vehicles to be idle, each vehicle will be replenished with _____ yuan per hour.
3. Rights and obligations of Party A and Party B
1. Payment method: One day is a billing cycle, that is, settlement is made once a day, and the settlement receipt is provided at noon the next day If paid in cash, Party A shall not default on Party B for the project payment for any reason. Otherwise, Party B has the right to stop the operation and hold Party A responsible for the economic losses caused to Party B. The supplement is _____ yuan per vehicle per day.
2. After Party B’s vehicles enter the site, they must obey Party A’s management. Party B shall not stop work or leave the site midway without justifiable reasons. Otherwise, Party B must compensate Party A for all economic losses caused thereby.
3. Party B will enter the site and start construction according to Party A’s arrangements. Party A will assist Party B in renting accommodation for the drivers and staff, and Party A will be responsible for the water and electricity. Party B's fleet entry procedures will be completed and Party A will supply fuel first and deduct it from the project payment.
4. Party A is responsible for the road construction and maintenance of the transportation roads to ensure smooth traffic. From the time Party B’s vehicles enter the site to the end of _____, Party A will arrange _____ hours of transportation time every day. After _____ months, Party A Arrange construction for _____ hours throughout the day. Construction can be stopped in case of force majeure natural disasters (rain, typhoon, earthquake).
5. Party A must ensure that the local traffic police, operations, road administration, environmental protection, streets, local villagers and other relevant departments will not arrest or impound the vehicle. If the vehicle is impounded, Party A will be responsible for all fines , because the above-mentioned vehicle detention for more than 24 hours will be punished as lost work, and each vehicle will be compensated _____ yuan according to the contract.
6. The oil price will fluctuate according to the current market price by _____ yuan/liter provided by Party A or otherwise exceed the guaranteed minimum price of _____ yuan/liter, and Party A will be responsible for compensation for the excess.
7. Under normal circumstances, if Party B’s vehicles are stopped for one day without special reasons, Party A will compensate Party B _____ yuan per vehicle per day. The daily living expenses of each staff member shall be _____ yuan as compensation to Party B
8. Party A is responsible for stone blasting (each stone cannot exceed _____ to _____ kilograms), which will not affect the loading. In addition, Party A is responsible for the Hutoushan (Tutou) floor material management fee and any expenses required by the villagers.
9. During the construction period, Party B will be responsible for safety accidents during transportation and have nothing to do with Party A. Party A is only responsible for mediation.
10. After each vehicle of Party B enters the site (after the formalities are completed), Party A must borrow an entry fee of 1,000 yuan for each vehicle, which will be deducted in proportion _____ days after entering the site.
4. For matters not covered in this contract, a supplementary agreement shall be signed after negotiation between the two parties. This agreement shall be in quadruplicate from the date of commencement to the completion of the project and Party A must pay Party B's project transportation charges. Party A and Party B each hold two copies, which have the same legal effect. This contract becomes effective upon signature.
5. If there is a dispute between the two parties due to the performance of this contract, the two parties shall resolve it through negotiation. If the negotiation fails, the dispute shall be submitted to labor arbitration in the place where the construction is performed or a public prosecution shall be filed in the local people's court for resolution.
6. Special agreement:
Party B will first deduct _____ from the total cost of settlement for the first ten days of the project as a deposit for the project payment in the first ten days, which will be refunded in one lump sum after the project is completed.
Party A (official seal): _________
Party B (official seal): _________
Legal representative (signature): _________
Legal Representative (signature): _________
_________month____day
_________month____day