General version of the construction site labor contract model 1
Party A (the Employer): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (contractor): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Labor Contract Law of People's Republic of China (PRC), General Principles of Civil Law of People's Republic of China (PRC) and Civil Law of People's Republic of China (PRC), combined with the specific conditions of this project, and based on the principles of voluntariness, fairness, mutual benefit and good faith, Party A is willing to contract the office building located in Songmutang to Party B. Through consultation, both parties hereby sign this contract and reach the following unanimous terms:
First, the contracting method.
Party A contracts the equipment and turnover materials to Party B. ..
Second, the contract unit price
According to the actual construction area, regardless of the increase or decrease of materials, the price per square meter shall prevail.
III. Contents of the Contract
The specific content of this project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1, foundation earthwork excavation and backfilling, pile head chiseling, construction drawing, all civil works, internal powder pasting, column wall reinforcement, welding, drainage ditch, apron, indoor floor, maintenance, septic tank, external drainage ditch, casual workers.
2 large mechanical equipment (including inspection fees), tools, appliances, water pipes, etc. What the project needs.
3. Party B shall be responsible for all expenses required for the project in the blueprint, such as trees, boards, templates, square materials, big trees, safety nets, iron wires, nails, binding wires, cutting pieces, on-site electricity wires and cables, canteen cookers, staff accommodation appliances, chef's salary, etc.
4, according to the figure construction, erection of peripheral protection, mixer safety shed, pedestrian safety passage and stairwell safety protection. Hard protection is set every second floor in the elevator shaft, and all safety protection facilities around the project entrance, woodworking mold making and steel bar processing shed are set up according to the safety construction specifications.
Four. mode of payment
The subject pays _ _% of the total price on the first floor, and _ _% of the total price for each completed floor in the future, and _ _% of the total price for the subject. For interior and exterior decoration works, all floors shall be painted at _ _ _% of the total price upon completion, and _ _ _% of the total price upon completion of the works. After completion acceptance, a quality deposit of _ _ _% shall be reserved, and the balance shall be paid one month after settlement. The warranty period is one year.
Five, the time limit for a project and quality requirements
This project must be completed and accepted within days from the date of signing the contract, and the time is-days without delay. Party B must seriously organize and obey the management of Party A's construction personnel and management personnel from the date of commencement, and Party B must carry out the construction according to the drawings. In case of quality problems, Party B shall be responsible for all rework wages and materials. During the construction process, Party A shall not waste any materials and pay compensation according to the price. Team leaders must be stationed at the construction site, and must ask for leave if something happens. Those who leave the site without leave or approval will be fined 200 yuan/day each time.
Project management and safety of intransitive verbs
L, goal: put an end to industrial accidents.
2. Specific requirements and measures:
(1), in strict accordance with the requirements of safety regulations, organize team members to learn safety regulations and common sense on a regular basis, and enhance the safety awareness of team members.
(2), shall not touch the mechanical and electrical, temporary power lines and scaffolding, who dismantled scaffolding without contact with the project department, offenders fined _ _ _ _ _ _ _.
(3) When using the "three treasures" of safety according to the actual situation, you must wear the safety helmet correctly (those who don't wear the safety helmet on the construction site will be fined _ _ _ _ yuan each time, and the monitor will be fined _ _ _ _ _ yuan each time).
(4), it is forbidden to take the hoist, every time found a fine monitor _ _ _ _.
(5), it is forbidden to go to work after drinking, offenders fined _ _ _ _ yuan each time, and then leave the construction site; It is forbidden to wear slippers, hard shoes and go to work barefoot, and offenders will be fined _ _ _ _ yuan each time.
6. It is forbidden to pile up materials on the shelf. If the above situation is found and Party A fails to rectify it in time after pointing it out, it will be fined RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _.
⑦ If a safety accident is caused by Party B's failure to observe the safety operation rules, Party B shall bear the economic losses within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
If Party B stops work halfway and the stoppage time exceeds _ _ _ days, Party A has the right to invite another construction team to enter the site, and all losses caused thereby shall be borne by Party B and fully compensated.
Seven. responsibility for breach of contract
1. In case of shutdown due to Party A's reasons, Party A shall bear the actual losses of Party B. ..
Once both parties sign this contract, it will take effect. Both sides need it
Keep it, don't break it. If Party A breaches the contract, it shall compensate Party B for all economic losses during the construction period; If Party B breaches the contract, Party A has the right to terminate the contract, and the losses caused thereby shall be borne by Party B. ..
Other matters not covered shall be settled by both parties through consultation.
This contract shall come into effect after being signed by both parties and shall have legal effect. This contract is made in duplicate, one for each party, and will automatically become invalid after completion and settlement.
Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Model labor contract on construction site II General Edition
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A's _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
I. Term of the Contract
Party A employs Party B to work in _ _ _ _ _ _ _ _ (post); The term of the labor service contract is _ _ _ _ _ months. The probation period is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Second, the basic rights and obligations
Party A:
1. Manage Party B according to production (work) needs, unit rules and regulations and contract provisions;
2. In order to protect the legitimate rights and interests of Party B, Party B shall be paid wages, bonuses, allowances, insurance benefits and other policy subsidies according to relevant regulations.
3. Do a good job in safety education before Party B takes up his post, and provide working conditions that meet the safety and health requirements.
4. Reward and punish Party B according to relevant national regulations.
Party B:
1, workers under labor contract enjoy the rights, obligations and various treatments of permanent workers in their own units. The rights, obligations and welfare benefits of contract workers, seasonal workers and farmers' rotation workers shall be agreed upon separately.
2. Abide by national policies and laws, and abide by the rules, regulations and disciplines formulated by Party A according to law.
3, strictly abide by the operating rules, to ensure safety in production.
4. Complete the production (work) tasks and economic indicators assigned by Party A. ..
Three, the two sides should be clear about specific matters.
1. Salary: _ _ _ _ _ _ yuan/month.
2. Labor insurance benefits: including accommodation.
3, according to the characteristics of unemployment agreement labor contract deposit and personal insurance.
4. Others: According to the IOU, Party A will settle all wages for Party B at the end of the year (in addition, all wages for this year will be settled after the acceptance of this project), and pay in full within _ _ _ _ days after Party A receives the labor wages from the developer or general contractor.
Fourth, the termination of the contract
After the Contract comes into effect, Party A and Party B shall not terminate the Contract in advance without justifiable reasons. Either party must notify the other party to terminate the contract _ _ _ days in advance before it can terminate the contract and go through the relevant formalities.
5. If one party violates this contract and causes economic losses to the other party, the breaching party shall be responsible for compensating the losses according to the size of the responsibility.
Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Construction site labor contract model 3 general edition
Party A (the Employer): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (contractor): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, based on the principles of voluntariness, equality and consensus, combined with the actual situation of the project, and in order to ensure the interests of all parties, the following agreement is reached through consultation:
I. Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Second, the project site _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Third, the project cycle
The total term of this contract is _ _ _ _ _ _ _ _ _ years.
Fourth, the project price
Total project price: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Yuan only.
Verb (abbreviation of verb) payment terms
_________________________。
VI. Project Acceptance
1. After the project is completed, Party B shall submit a written application for completion acceptance to Party A, and Party A shall arrange the acceptance within 7 days. After Party A signs in writing, it shall be deemed as qualified.
2. If the whole project is accepted, the completion acceptance date is the completion date.
Seven. Acceptance criteria This project is based on relevant design schemes and drawings, and is accepted according to national standards; If there is no national standard, it shall be accepted according to the industry standard.
Eight. Rights and obligations of both parties
1. Rights and obligations of Party A: Appointed as the on-site representative, responsible for coordinating Party A's related matters. During the execution of the project, the signatures of all designated personnel shall be regarded as the behavior of Party A..
(1) is responsible for the supervision of this project and actively coordinates the construction cooperation.
(2) Review the project progress.
(3) Be responsible for the review and confirmation of drawings and schemes, and supervise and inspect the project progress, project quality, concealed works, supporting works and contract implementation, design drawings change visas, intermediate acceptance of projects and other necessary visas.
(4) Be responsible for the completion acceptance, and organize the acceptance within one week after receiving all the completion data submitted by Party B. ..
(5) Pay the price stipulated in this contract to Party B according to the contract.
2. Rights and obligations of Party B
(1) The construction shall be carried out in strict accordance with the design drawings, and the quality and technical indicators shall meet the requirements of various standards and specifications of the project.
(2) Report the problems found in the construction to Party A in time and propose solutions.
(3) Prepare the construction organization plan, general construction schedule plan, material mobilization plan and completion notice, and send them to Party A in time.
(4) Provide technical data for completion acceptance, prepare technical drawings for completion, handle project completion settlement and participate in completion acceptance. The completion data shall meet the requirements of Party A..
(5) Organize the construction team with technical level by itself, and define the on-site technical and construction leaders and main management personnel, and the technical personnel shall not change at will.
(6) Responsible for site construction safety.
X. liability for breach of contract
1. If the completion of the project is delayed due to Party B's reasons, it shall be regarded as Party B's breach of contract, and Party B shall pay liquidated damages to Party A. The liquidated damages shall be calculated according to the total contract price ×0.5% of the days of delay;
2. If Party B's illegal operation is found in the construction process, and the construction drawings are inconsistent with the on-site construction situation and have not been confirmed by Party B, it will be regarded as Party B's breach of contract, and Party A has the right to unilaterally terminate the contract and require Party B to bear 30% of the contract price as liquidated damages;
XI。 Alteration and termination of the contract
1. After this contract comes into effect, except for force majeure (war, serious flood, fire, typhoon, earthquake, accidents agreed by both parties as force majeure), Party A and Party B shall not change or terminate this contract without reason.
2. During the performance of the contract, in case of force majeure, both parties shall take effective measures to reduce the losses and prevent the losses from expanding. If it is really necessary to change or terminate the contract, the party requesting the change shall notify the other party in time, and the other party shall give a reply within 3 days after receiving the notice. If no reply is made within the time limit, it shall be deemed as consent.
3. If Party B fails to complete the project as scheduled and the extension period reaches 60 days, Party A has the right to suspend its obligations under this contract; If the extension period of the whole project reaches 120 days, Party A has the right to terminate this contract and demand Party B to pay corresponding compensation.
4. If this contract is modified or terminated, the losses caused thereby shall be settled by both parties through consultation.
Twelve. Dispute Settlement Any dispute arising from or related to the signing, performance, dissolution or termination of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, both parties agree to bring a lawsuit to Qingpu District People's Court where the plaintiff is located.
Thirteen. other terms
1. During the construction, all construction personnel are Party B's personnel, and Party B is responsible for their personal safety, which has nothing to do with Party A. ..
2. During the performance of this contract, both parties can determine the matters not covered in this contract through consultation according to the actual situation.
Fourteen Text and effect of contract
This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed by the representatives of both parties. The annex is an integral part of this contract and has the same legal effect as the text of the contract. Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Articles related to the general version of the construction site labor contract model;
★ Universal Construction Contract Template
★ General Edition 3 labor contract templates
Taken on-site construction personal labor contract template
★ Model labor contract for construction site
★ Model labor contract for construction site
★ Model labor service contract for construction industry
★ Model construction labor service contract
★ Model construction labor service contract
★ Model construction labor contract
★ Model labor contract for construction site workers