With the strengthening of people's legal awareness, people use contracts more and more, and signing contracts is also one of the best ways to avoid disputes. So how to write the relevant contract? The following is the project contract template I compiled (5 copies in total). Welcome to reading. I hope you will like it.
General project contracting1:_ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Subcontractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
According to the Contract Law of People's Republic of China (PRC), the Ministry of Construction's Implementation Measures for General Subcontracting of Construction and Installation Projects and the relevant provisions of the Implementation Measures for General Subcontracting of Construction Projects.
First project
1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. Project number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4. Construction PermitNo.: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. Business license number: _ _ _ _ _ _ _ _ _ _ _ _
6, the scope of the subcontract works and quantities (with budget)
7. The subcontract works shall be started on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
8, the subcontract works labor costs _ _ _ _ _ yuan.
9. The type of work and the number of people engaged by Party B are _ _ _ _ _ _.
Article 2 Project Settlement
According to the subcontracted project, the living expenses paid in advance in the first month shall be calculated according to the contract number _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 3 Project Quality
Party A shall make technical disclosure and organize acceptance according to the national quality acceptance specifications and evaluation standards, and Party B shall carefully organize construction according to the requirements of construction drawings and specifications to ensure the project quality. If the quality is unqualified, it must be reworked and repaired, and the materials and material losses shall be borne by Party B; If the quality of the project is poor and cannot be saved, Party B shall be responsible for compensating all the material losses.
Article 4 Safety in production
1. Party A shall make safety disclosure for the project undertaken by Party B, put forward clear safety requirements, and conduct supervision and inspection. Party B must conscientiously implement the rules and regulations for safe construction and strictly abide by the safety operation rules. The safety production facilities provided by Party A can only be used after passing the inspection. In case of casualty accidents due to violation of the above regulations during construction, Party B shall be responsible for the losses.
2. During the construction process, Party B shall be responsible for solving the personal live working tools such as labor protection articles, insulating gloves and rubber boots. If Party B really has difficulties, it can put forward a demand plan, and Party A will help solve it.
3. In the process of construction, Party B shall be responsible for the fire accident caused by violation of fire laws and regulations.
Article 5 Life management
1. After Party B's workers enter the site, Party A shall provide accommodation and keep the main cooking utensils (cauldron, steamer, hair dryer and large panel). If there is any damage or loss, Party B shall compensate the price. Small and sporadic appliances shall be provided by Party B, and domestic coal shall be provided by Party A according to the quantity.
2. Party B shall take care of the food and oil needed for daily life, and Party A shall provide convenience in medical treatment and hygiene. If Party B's workers have diseases, they can seek medical treatment in Party A with the consent of the person in charge, and the medical expenses will be paid by Party B on a monthly basis.
Article 6 The unit price of labor cost for subcontracted projects
1, unit engineering subcontracting, each budget man-day is _ _ _ _ _ _ _ yuan. The implementation of unilateral square meters of labor costs, _ _ _ _ _ yuan per square meter.
2. Subcontract cornice plastering to achieve high quality, and the man-days per budget are _ _ _ _ _ _ _ _ yuan. The qualified budget man-days are _ _ _ _ _ _ _ _ yuan. Sub-item labor costs are _ _ _ _ _ yuan per square meter.
3, single subcontract stone, earthwork each budget man-days for _ _ _ _ _.
4. Each working day of liquidation work is _ _ _ _ _ _ _ _ _ _ yuan.
5. The working days for full-time shutdown, material waiting, water supply, power failure and clearing the field are RMB _ _ _ _ _ _ _ _.
6, water, electricity, heating, sanitation engineering, each budget man-days (according to the number of buildings) _ _ _ _ _ _ yuan.
7. During the winter construction period (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
8. Subcontract project cost schedule (any item can be _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 7 Management of Material Supply
Party B shall designate a special person to go through the quota purchase procedures with Party A for cement, steel, commodity components, hardware, linoleum, asphalt, water, electricity, heating, sanitation and other special materials .. Party B shall carry out the construction in strict accordance with the quality requirements and materials provided by Party A. Party B shall bear the waste of materials and unreasonable parts exceeding the quota during the construction. In the process of construction, Party B shall use materials in stacks (piles) to keep the daily materials clean and the site clean.
Article 8 Construction machines and tools
1. Party A shall be responsible for the large-scale tools to ensure the use needs.
2. Party B is responsible for the manual operation of tools.
3. Party B shall take good care of the machines and tools supplied by Party A.. In case of loss or damage, Party B shall be responsible for compensation.
4. The medium and small-sized machinery required for construction shall be equipped by Party A according to the construction plan, with one machine and one driver to ensure the normal construction of Party B, and Party B shall not operate the equipment without authorization (its own machinery shall be handled according to relevant regulations).
Article 9 Site management
1. Party B's personnel shall strictly abide by various management systems on site, organize construction under the unified leadership of Party A's site leader, and both parties shall closely cooperate in planning, progress and material supply to ensure smooth construction.
2. Party B shall educate the constructors about obeying the laws and regulations, safe production and caring for property, and designate a special person to be responsible for the on-site safety work. It is forbidden to steal materials from the construction site. If there is any illegal act in violation of the site management system, Party A has the right to take necessary measures, and Party B shall bear legal responsibilities and compensate economic losses.
3. Subcontractors shall remain relatively stable, wear work signs when entering or leaving the construction site, and personnel outside the contract shall not enter or leave the site or stay.
Article 10 Liability for breach of contract
1. The project subcontracted by Party B shall not be subcontracted again. In the process of construction, if the inspection does not meet the requirements of national acceptance standards and the quality of the project cannot be guaranteed, Party A has the right to terminate the contract and Party B shall compensate for the losses caused by rework.
2. After the signing of this contract, neither party may change or terminate it at will without the consent of both parties. If Party B unilaterally terminates the contract without Party A's consent, Party B shall compensate Party A for the economic losses caused by affecting the construction plan; If Party A terminates the contract midway, Party A shall compensate Party B for the economic losses caused thereby.
3. Party B must complete the project according to the time limit and quality requirements stipulated in the contract, otherwise, for each day overdue, Party B shall pay _ _ _ _% of the labor cost of the subcontracted project to Party A as overdue penalty.
4. Party A and Party B shall not make an excuse to default on various payables. If they fail to pay, they will pay the other party a penalty for overdue payment according to the bank's short-term loan interest rate.
Article 11 Supplementary Provisions
1. In case of any dispute arising from this contract, both parties shall negotiate in time, and negotiation fails. If it cannot be solved, it can be solved according to the following item ():
(1) Apply to the Economic Contract Arbitration Commission where the building is located for arbitration;
(2) to the people's court.
2. This contract is signed in the form of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. If certification (notarization) is required, you can go to the district or county administration for industry and commerce where the building is located, and the notary office will conduct certification or notarization.
4. Other terms agreed by both parties:
①______________________________
②______________________________
Article 12 The validity period of the contract
This contract shall come into effect as of the date when both parties seal it, and shall become invalid after the project is completely completed and settled.
General contractor (seal): _ _ _ _ _ _ _ _ _ Subcontractor (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Entrusting party of Project Contract II (hereinafter referred to as Party A): _ _ _ _ _ _ _ _
Trustee (hereinafter referred to as Party B): _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and the Administrative Measures for Non-operating Government Investment Projects (Trial), Party A agrees to entrust the construction project to Party B for construction. Based on the principles of equality, voluntariness, honesty and credit, and in order to clarify the rights and responsibilities of all parties, this contract is concluded on the agent construction.
I. Overview of the Project
1, project name: _ _ _ _ _ _ _
2. Project location: _ _ _ _ _ _ _
3. Project (budgetary estimate) investment: _ _ _ _ _ _ _
4. Project approval number: _ _ _ _ _ _ _
II. Project Construction Period The total construction period of this project is _ _ _ _ _ _ (from the date of signing the contract):
Third, the quality standard:
Four. Contract price
Party A shall take _ _ _ _ _% of the planned investment of Project No.9 Document of the Construction Committee as the construction fee of Party B.. RMB _ _ _ _ _ _ ten thousand Yuan.
Verb (abbreviation of verb) constitutes the document of the contract.
1, contract agreement and contract conditions;
2, the project construction power of attorney;
3. Supplementary and revised texts signed by both parties during the project implementation.
Party A agrees to pay the construction agency fee to Party B according to the time limit, method and currency specified in this contract.
Seven. Party B agrees to undertake the project construction work within the scope agreed in the contract documents of this project according to the provisions of this contract.
The original of this contract is in duplicate, one for each party; Four copies, two for each party. It shall come into effect after being signed and sealed by both parties, with the same legal effect.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project Contract 3 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Construction Law and other relevant laws, regulations and rules. Based on the principles of equality, voluntariness, fairness, honesty and credit, both parties have reached an agreement on this project and will abide by it together.
Article 1: Project name:
Article 3: Scope of Work: See Annex.
Article 4: Total Project Price:
Rmb (this item is the bid price, which is paid according to the actual engineering quantity, and is the after-tax price), and Party B will contract the work and materials.
Article 5:
5. 1 completion date: (subject to the completion report) delivery date.
5.2 Total term of the contract: RMB.
5.3 Party A's payment is not based on the invoice provided by Party B..
Article 6: Engineering Quality Standards
According to the standards stipulated in the design documents and relevant codes, the construction shall conform to the relevant national acceptance standards.
Article 7: Representatives
Party A shall designate one or two persons as the representatives of Party A, and the documents signed by them shall be regarded as the official documents of Party A, and the power of attorney of these persons shall be a part of this contract. If there is any change, Party A shall notify Party B in writing immediately after the change, and the losses caused by Party A's delay in notification shall be borne by Party A. ..
Article 8: Site Management
8. 1 Party B must strengthen the safety and vocational skills education of construction personnel to ensure safety, eliminate hidden dangers and put an end to all accidents in construction.
8.2 Strictly implement the management systems of the construction site, and the construction site must be civilized, so that the site will be cleared after work, and the garbage will be piled up and transported to the designated place.
8.3 Party B shall not fight or make trouble after entering the construction site. If the circumstances are serious, it shall be handed over to the judicial department for handling.
Article 9: Equipment, Materials, Access and Auxiliary Facilities
9. 1 Party A shall provide temporary places and temporary or permanent equipment for Party B to complete and maintain the subcontracted project.
9.2 Materials used in this project: See the annex.
9.3 The place where Party B stacks the equipment shall be within the scope permitted by Party A, and shall not hinder the progress of the project and the smooth flow of streets. In order to enable Party B to carry out the construction smoothly according to the subcontract, Party A shall provide Party B with convenient measures to enable its equipment to enter part or part of its construction site.
9.4 During the construction of this project, Party A shall be responsible for providing temporary water and electricity facilities at the construction site and related places, and always pay attention to maintaining the safety and normal operation of transportation, electricity, communication, water supply, gas or other facilities.
Article 10: Engineering Insurance
Party B shall purchase insurance for its employees.
10.2 The insurance policy handled by Party A is the general principle for performing the general contract. If Party B should enjoy the benefits in the insurance policy, Party A should indicate or list the benefits enjoyed by Party B in the insurance policy and the schedule in this part.
10.3 Both parties must keep its validity until the subcontracted project is completely completed.
10.4 In addition to proving that the construction period is prolonged due to force majeure or intentional or gross negligence of Party B, Party A shall pay the renewal fee.
Article 11: Change the design
1 1. 1 Both parties may change their subcontracted projects according to the following conditions:
1 1.2 Matters to be reduced by both parties hereto through consultation.
1 1.3 For the benefit of Party A, Party B may notify Party A in writing of any change, increase or decrease 10 days in advance.
1 1.4, Party B can set the price according to the relatively high price from signing to changing. For the reduction project of 1 1.5, Party A shall not only bear the loss of materials purchased by Party B, but also pay reasonable expenses to Party B..
Article 12: Project Extension
12. 1 If the completion date needs to be postponed, Party B may truthfully notify Party A of the project delay notice in writing within 3 days after the cause occurs, unless it can be proved that Party B intentionally caused the delay.
12.2 During the construction of this project, Party A may notify Party B to stop all or part of the work of this project.
Article 13: Acceptance
When the 13. 1 project is covered or concealed or reaches the intermediate acceptance position, Party A shall conduct acceptance within 24 hours after receiving the notice from Party B. ..
13.2 when the progress of this project reaches the completion or phased acceptance standard, Party B shall submit a written completion acceptance report. After being approved by the supervision engineer, it shall be accepted by Party A. ..
13.3 party b shall notify party a of the acceptance date in writing three days before the acceptance. If Party A cannot attend on time, it shall notify Party B in writing two days in advance, and the delay caused thereby shall be compensated according to Article 13 of this contract. 13.4 If Party A fails to conduct acceptance or propose an extension within 3 days after receiving Party B's notice, the quantities listed in the bid-winning notice submitted by Party B shall be deemed as accepted, and the notified acceptance date shall be regarded as the acceptance date, which shall be used as the basis for paying the contract price.
13.5 After the project is completed and accepted by Party A, Party B shall hand it over to Party A within 10 days. The date of acceptance is regarded as the transfer of ownership and related rights and obligations.
Article 14: Liability for breach of contract and damages
14. 1 If one party is under any of the following circumstances, the other party may terminate or dissolve this contract, and one party shall pay liquidated damages to the other party at 10% of the total project price.
14.2 One party requests to reduce the engineering quantity by 20% of the original contract amount.
14.3 one party requests to stop work 15 days, unless it can be proved that it is force majeure or the other party's intentional or gross negligence.
14.4 one party is in danger of bankruptcy, bankruptcy or financial difficulties, or one party is obviously unable to pay the project payment.
14.5 when this contract is terminated or dissolved due to the above reasons, or other compensation events occur due to other reasons, one party can still claim compensation from the other party according to law.
14.6 In addition to proving that Party B intentionally fails to enter the site for construction on time, Party A shall also compensate Party B for the liquidated damages of150,000 yuan.
14.7 in addition to proving that the shutdown or delay is caused by force majeure or party b's intention, party a shall pay compensation to party b at the rate of 100 yuan/day per person, and pay the expenses incurred by party b due to shutdown or delay, including but not limited to depreciation expenses of construction tools, site fees and management fees. Party A shall take the initiative to compensate Party B within 10 days after the suspension notice.
14.8 If Party A fails to pay the project payment, liquidated damages, compensation, etc. 3% of the total project price shall be paid as liquidated damages for each day overdue according to the time agreed in the contract.
Article 15: Settlement of disputes
If there is any dispute between Party A and Party B on the terms of this contract, both parties shall negotiate on an equal footing; If negotiation fails, the people's court shall have jurisdiction.
Article 16: Other
16. 1 term of the contract: this contract shall come into effect after being sealed by both parties, and shall be terminated after the final payment is paid.
16.2 ContractNo.: This contract is made in quadruplicate, with Party A and Party B holding two copies respectively.
16.3 the original of this contract shall be sealed by both parties.
16.4 The address provided by one party is a deliverable address. If there is any change, it shall be notified in time; Otherwise, delivery at the address agreed in the contract shall be deemed as delivery.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project Contract 4: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
1. Project name: Building _ _ _ _ _ _ in Teacher Garden Community, Chang 'an District
2. Project location: Qingnian South Street, Chang 'an District, Xi City
III. Contracting Method: Only contract materials (including all construction machines and tools).
Four. Contract content: indoor and outdoor filling and compaction.
5. Contract unit price: _ _ _ _ _ _ _ yuan /m3 for indoor fill and _ _ _ _ _ _ _ _ yuan /m3 for outdoor fill (including lime soil).
Payment by intransitive verbs: After Party B completes all the work within the scope of the contract and is accepted by Party A, Party A pays all the project funds to Party B..
Seven, quality and time limit for a project requirements:
1, the backfill thickness shall not be greater than 300mm, the compaction coefficient shall not be less than 0.94, and the technical indicators such as high surface smoothness must meet the requirements of national acceptance specifications. Party B who fails to meet the requirements must rework and bear the losses caused to Party A by the delay in construction period.
2. All losses caused by Party B's shutdown or exit shall be borne by Party B, and shall be settled according to 60% of the completed project. The remaining 40% will not be settled.
Eight, safety requirements:
1. Party B must abide by all rules and regulations of Party A's site, and Party A has the right to order those who do not obey Party A's management to leave the site.
2. Party B shall check whether the state of its electrical equipment is normal at any time. If problems are found, Party B shall immediately cut off the power supply for maintenance, and shall not work with illness.
3. Party B should always educate employees to pay attention to safety during the construction process, and Party A will not be responsible for casualties or property losses caused by Party B's illegal operation.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project Contract 5: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this construction project and conclude this contract.
I. Project name:
Second, the project site selection:
Three. Term of the contract: the commencement date of this contract project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Four. Project quality standard: The contractor shall strengthen the quality management of the excellent quality grade project in this contract, and earnestly perform all measures stipulated in this contract to ensure that the standard is reached.
5. Contract price: amount (in words) RMB Yuan only (in figures). During the implementation, the geological conditions have not changed much. When the engineering quantity does not exceed 10% of the bidding engineering quantity, the total price will not be adjusted, and the excess part will be increased or decreased according to the owner's unit price (the bill of quantities and the owner's unit price table are attached).
Documents constituting the contract by intransitive verbs: The documents constituting the contract include:
1. Agreement in this contract
2, the bid-winning notice
3, the book of tender and its attachments
4, the terms of the contract
5. Standards, specifications and related technical documents
6. Cartography
7, bill of quantities
The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this contract.
Seven. The meanings of related words in this agreement are the same as those given to them in the contract terms of the bidding documents.
Eight, the contractor promises to the employer to carry out construction and completion in accordance with the contract, and undertake the quality warranty responsibility of the contracted project during the quality warranty period.
Nine. Payment method: After X is accepted by Party A, if Party A fails to pay% of the total contract price to Party B on schedule, Party A shall be liable for breach of contract.
X. quality deposit: the quality deposit of this project is 10%, and the warranty period is _ _ _ _ _ _ _ _ _ years from the date when the project is completed and accepted, and it will be returned after the acceptance period.
XI。 Entry into force of contract
This agreement shall come into effect after being signed by the legal representatives or entrusted agents of both parties and stamped with the official seals of the unit respectively. This contract is made in quadruplicate, with two originals, one for each party.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
;