In today's developing world, contracts are more and more widely used in life, and it is also the link to realize professional cooperation. So how is the general contract drafted? The following is a sample contract for water conservancy projects (6 in total) that I have compiled for you. Welcome to share. Water conservancy project contract 1

Employer:

I. Project situation:

Project name:

Project location:

Project content:

Contract scope: all drawings

1. Commencement date:

Completion date:

2.

6. The date of drawing provision is the day when the contract is signed, and two sets of drawings are provided.

second, quality standard: according to the detailed drawings of the project provided by Party A, the construction requirements and the supplementary provisions of the State (Ministry of Water Resources and Ministry of Construction) on the construction and acceptance specifications of water conservancy projects, construction and installation projects and relevant superior departments. Do a good job in the acceptance of concealed works and sub-projects Those that do not meet the engineering quality standards shall be dealt with seriously, and Party B shall be responsible for the losses caused thereby.

iv. mode of payment: the budget and final accounts of this project, water conservancy projects are compiled according to the budget and final accounts quota of Jiangsu Province (94 dynamic

state) and related compilation methods, and construction projects are compiled according to the comprehensive quota of Jiangsu Province. When the project starts,% of the project payment will be paid in advance according to the project scale, and during the construction period,% of the contract price will be paid after the project is completed, and it will be paid in one lump sum after acceptance.

V. General responsibilities of both parties:

(1) Work of Party A

1. During the construction period, Party A appoints comrades as representatives on the construction site (responsible for the supervision of the construction unit).

2. The construction site has the starting conditions and completion time. Such as land acquisition, land occupation, demolition, cofferdam, power supply, communication and traffic roads. And provide the location of soil borrowing area, excavation area and drainage bearing area.

3, provide engineering geology and leveling points, construction layout.

4, organization design disclosure. According to the actual situation of the site layout, provide detailed construction plan.

5. On-site "three links and one leveling", Party A is responsible for contacting the required items and providing relevant information.

6. Coordinate and handle local relations.

7. Handle all kinds of certificates and wholesale during the construction.

(II) Work of Party B

1. Appoint the person in charge of the construction site.

2. Provide construction organization design and schedule.

3. provide the construction drawing and schedule at the request of party a.

4. Provide quarterly, monthly and ten-day progress statistics on a regular basis.

5. Abide by the regulations of local government and relevant departments on construction site management, and do a good job in construction protection and workshop cleaning.

6. Before delivery after completion, protect the project in good condition and clean up the construction site.

v. quality and acceptance

1. Party B shall accept the inspection and acceptance of Party A's representative and its appointed personnel at any time and provide convenient conditions.

2. After the concealed works are self-inspected by the contractor, fill in the Concealed Works Acceptance Sheet and notify the site supervisor (Party A's site representative) for inspection and acceptance. Party A's site representative should go to the site for inspection within 2 hours after receiving the notice, and the visa can be issued only after the inspection is confirmed to be qualified and recognized, and the next working procedure can be carried out. If any objection is raised, the employer shall be responsible for the expenses after passing the review; Unqualified, the contractor shall be responsible for; The responsible party shall be responsible for the loss of construction period caused by this.

3. After the equipment is installed, the representative of Party B will sign the record.

4. After acceptance and test run, representatives of both parties shall sign the record.

5. If the acceptance and test run are unqualified, Party B will rework it due to improper construction. For design reasons, Party A will be responsible for modifying the design and bear the cost of rework.

6. The power, fuel, oil, materials, instruments and special tools required in the trial run shall be borne by the Employer.

7. For the equipment installation project, the contractor shall, together with the employer, go through the intermediate handover procedures for the completed project (equipment foundation) to the installation unit, and take it as the basis for the completion acceptance.

VI. Supply of materials and equipment

1. The materials and equipment provided by Party A shall be submitted to Party B for acceptance according to the agreed time, place, specification, quantity and quality (certificate of conformity) and shall be kept by Party B after acceptance.

2. The materials purchased by Party B according to the agreement shall be accepted by Party A..

VII. Design changes

1. Design changes must be approved by the original examination department, and the original design unit shall provide corresponding drawings and explanations.

2. Discuss the project quality, cost and construction period after the design change. Both parties need to recalculate according to the changed drawings and sign a supplementary agreement.

VIII. Completion and settlement

1. The completion acceptance of the project shall be based on the construction drawings, descriptions, technical disclosure minutes, design change notices, construction acceptance specifications and quality inspection standards issued by the state.

2. after the completion of the project, the contractor shall provide complete technical data in accordance with the regulations, and issue a completion notice. The acceptance time shall be determined by both parties through consultation, and the employer shall organize relevant units to conduct the completion acceptance.

after the acceptance, both parties sign the completion acceptance certificate, and hand over the project to the employer for management. If the employer delays receiving it, the safekeeping fee and losses caused shall be borne by the employer.

if any project that does not meet the quality requirements and needs to be reworked is found during the completion acceptance, the responsibility shall be clearly defined. If it is caused by construction, the contractor shall be responsible for repairing it according to the time agreed upon by both parties during the acceptance. The completion date shall be the date when the final inspection is qualified.

3. The completed and unaccepted project shall be kept by the contractor before the completion of the project, and the employer shall not use it. If it has been used by the employer, it shall be deemed to be submitted. Due to the contractor's reasons, the project that should be handed over for acceptance but not inspected shall be treated according to the terms of delaying the construction period, and the economic losses caused thereby shall be compensated.

4. after the project is completed and accepted, the warranty period of civil works is 1 year, and the warranty period of water and electricity is half a year.

in case of engineering quality problems caused by construction, the employer shall notify the contractor in writing and fix the time. If the contractor refuses to repair during the warranty period, the employer may use the reserved warranty money to have it repaired, and the cost overrun shall be borne by the contractor.

5. if the project meets the completion acceptance conditions, party b shall provide complete completion data and completion acceptance report.

6. Both parties are jointly responsible for the performance of the contract. After the completion of the project, Party A will review and organize the acceptance meeting the acceptance conditions.

7. problems left over from acceptance shall be repaired by party b. The repair cost shall be borne by the wrong party according to the cause.

8. Party B shall solve the problems raised in the acceptance within a time limit.

9. Organize the acceptance. Party A and Party B shall, jointly with relevant departments, conduct the completion acceptance, receive the project experience, stamp the visa, and provide complete completion data and financial final accounts, then go through the completion settlement and pay the project payment in time.

VIII. Disputes, breach of contract and claims

1. After disputes occur, the settlement method is mediation by both parties. If the mediation fails, it can be arbitrated or prosecuted.

2. Matters not covered in the contract shall be settled by both parties through negotiation.

IX. This contract is made in quadruplicate, one for each party, and shall be terminated from the date of signature to the completion acceptance of the project and the settlement of the money.

party a: party b:

year month day water conservancy project contract 2

employer:

contractor:

in order to complete the village water conservancy construction project with good quality and quantity, the following agreements are reached through consultation between both parties:

1. Project overview:

1. Project name:

2. Project address:

.

6. Total project cost: RMB

2. Construction requirements

3. Payment method

4. Responsibility of Party A

After the completion of the project, Party A is responsible for the timely arrival of funds and has the right to assign special personnel to supervise the project quality.

V. Responsibility of Party B

1. Start the project in time, guarantee the construction period and be responsible for the project quality. If it cannot be completed on time or fails to meet the contract quality requirements without any reason, Party B shall be fully responsible for the losses caused.

2. Be responsible for the safety of construction personnel. In case of any safety accident during construction, Party B shall be responsible for everything.

3. Be responsible for the warranty for one year.

4. bear all expenses such as water and electricity during the construction period.

VI. Matters not covered in this contract shall be signed by both parties through consultation, and shall have the same legal effect as this contract as an annex to this contract.

VII. This contract is made in duplicate, with each party holding one copy. It will take effect as of the date of signature and seal by both parties.

party a (seal) person in charge of party a (signature)

party b (seal) person in charge of party b (signature)

date: water conservancy project contract 3

Employer: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of the People's Republic of China, _ _ _ _ _ _ _ _ (hereinafter referred to as the Employer) and _ _ _ _ _ _ _ _ _ (hereinafter referred to as the Contractor) have reached an agreement on _ _ _

1. the meanings of words in this contract are the same as those in the general terms and conditions listed in article 2 below.

II. The sequence of the constituent documents and interpretation of this contract is

1. Contract (including supplementary contracts and agreements)

2. Letter of acceptance

3. Bidding documents

4. Special contract terms

5. General contract terms

6. Technical terms

7. Other documents constituting the contract.

the above-mentioned contract documents are a whole, replacing all agreements, minutes of talks and all documents promised by both parties before the signing of this contract.

iii. the contractor promises to complete all the contracting work in an all-round way according to the contract, and bear all the obligations and responsibilities agreed in the contract.

iv. the employer guarantees to pay in accordance with the contract and bear all the obligations and responsibilities agreed in the contract.

5. this contract shall come into effect after being signed by the legal representatives or entrusted agents of both parties and stamped with the official seal of this unit.

six, the original of this contract is in duplicate, each party holds one copy, which has the same legal effect. _ _ _ _ _ _ copies, including _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

employer (official seal): _______

contractor (official seal): _ _ _ _ _ _

legal representative (signature): _ _ _ _ _

legal representative (signature) : _______

entrusted agent: _ _ _ _ _ _ _ _ _

entrusted agent: _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Fax: _________________

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Bank of deposit: _ _ _ _ _ _ _ _ _ _ _ _

Account number: _ _ _ _ _ _ _ _ _____________

_ _ _ _ _

Signing place: _ _ _ _ _ _ _ _ _ _

Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Water Conservancy Project Contract 4

Construction unit: (hereinafter referred to as Party A) <

1. project name: roof waterproofing project of teaching building of linhuaigang central school.

2. Project content: SBS IV waterproofing membrane is used for building roof waterproofing; Duration: from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

iii. contracting method: the general contracting method for contracting labor, materials and quality.

iv. project cost: SBS IV waterproof: 3 yuan× 32 square meters per square meter =96 yuan (including liquefied gas and salary). Settlement shall be made according to the actual surface area.

v. quality standard: party b shall ensure that the waterproof project of party a's office building meets the excellent standard, and carry out the construction in strict accordance with the specifications and standards of waterproof project, current relevant standards and party a's requirements, ensuring the quality and quantity.

VI. Safety: Wear safety protection equipment and strictly implement the national laws and regulations on safety.

VII. Responsibilities of both parties:

1. Responsibilities of Party A:

(1) The construction plan shall be put forward in advance, and the working face shall be arranged to meet the waterproof construction standards and submitted to Party B for construction.

(2) The construction period plan should be put forward, but the inevitable factors such as weather and manpower should be taken into account, and the construction period should be postponed.

(3) Party A has the right to supervise and inspect the engineering quality of Party B during the construction process, and submit the problems to Party B for timely rectification.

2. Party B's responsibilities:

(1) Upon Party A's notice, the waterproof materials will be put into the site immediately and used after being inspected by the person in charge of Party A's site.

(2) Cooperate with the overall progress of the project and carry out the construction according to the construction plan proposed by Party A. Except for inevitable factors, there shall be no artificial delay.

(3) Party B shall abide by the rules and regulations of the construction site, and shall not violate the rules, otherwise it shall be punished by Party A in various forms.

(4) Construction shall be carried out in strict accordance with waterproof engineering standards, and problems shall be found, and