With the deepening of the concept of legal system, the contract is more and more helpful to us, and it is also an important measure to reduce and prevent disputes. So what should we pay attention to when concluding a contract? The following is my 10 power of attorney contract, which is welcome for your reference and I hope it will help you.

Power of Attorney Contract 1 Client (hereinafter referred to as Party A)

Trustee (hereinafter referred to as Party B)

On the basis of friendly negotiation, equality and mutual benefit, Party A has reached the following agreement on entrusting Party B to purchase equipment on its behalf:

Article 1: Name, specification, unit price and country of origin of the equipment.

Article 2: Contract Amount

The total price of the equipment under this contract is RMB Yuan only.

Article 3: Payment Method

Within five days after the signing of the contract, Party A shall remit the total contract price in RMB to the account designated by Party B; The balance, namely RMB, shall be remitted to the account designated by Party B within days after the equipment installation, commissioning and acceptance.

Article 4: Place of delivery

Party B shall be responsible for transportation to the place designated by Party A, and relevant transportation expenses shall be paid by Party B..

Article 5: Delivery Date

After the first payment is recorded, the delivery will be made.

Article 6: Responsibilities and obligations of Party A and Party B:

(I) Responsibilities and obligations of Party A

1. Inform Party B of the details and relevant requirements of the required equipment, and notify Party B in time if the information of the required equipment changes; If the losses caused by Party A's failure to notify in time are borne by Party A itself;

2. If this contract cannot be continued due to irresistible natural disasters, Party A shall promptly notify Party B and provide corresponding supporting documents;

3. After the contract equipment arrives at Party A, Party A has the obligation to receive and take delivery. If it is found that the packaging is incomplete and the equipment does not meet the relevant requirements of the contract, Party A shall immediately notify Party B, so that Party B can negotiate with the supplier about relevant compensation matters.

(II) Responsibilities and obligations of Party B

1, responsible for signing relevant procurement contracts and ensuring that the relevant contents of the contracts comply with the relevant provisions of national laws and regulations;

2. After Party A accepts the goods, it shall go through relevant financial settlement procedures with Party A in time.

Article 7: Liability for breach of contract:

(1) Party B's liability for breach of contract: If the variety, specification, quality and technology of the equipment delivered by Party B do not conform to the relevant provisions of this contract, Party A has the right to demand the return of the goods and recover the paid amount, and Party B shall pay a penalty equivalent to the total contract price to Party A; If Party B fails to deliver the goods on time without special reasons, Party B shall pay Party A one thousandth of the total contract price as liquidated damages.

(II) Party A's liability for breach of contract: Party A refuses the equipment without justifiable reasons, and Party B charges Party A the total contract price as liquidated damages; If Party A fails to pay the equipment payment in time, Party A shall pay one thousandth of the total contract price to Party B as liquidated damages every day.

Article 8: Claims:

Party B shall be responsible for claiming compensation from the supplier on behalf of Party A..

Article 9: Settlement of Contract Disputes:

Any dispute arising from the execution of this contract shall be settled by both parties through consultation. If negotiation fails, it shall be settled by the court where the defendant is located.

Article 10: Other;

1. This contract shall come into effect after being signed and sealed;

2. All annexes to this contract have the same legal effect as this contract;

3. This contract is made in duplicate, one for each party, with the same legal effect.

Party A:

Party B;

Handler;

Handler:

Bank and account number:

Bank and account number:

date month year

date month year

Part II of Power of Attorney Contract This power of attorney states: I (name) am the legal representative of (name of the construction unit), and hereby authorize (name of the construction unit) to act as my agent to handle the filing of the construction contract of this project in the name of this unit. I acknowledge all documents signed by the authorized customer and all matters related to it. The agent has no right to delegate, and hereby entrusts.

Agent: gender: age: mobile phone:

Employer (official seal): Employer (official seal):

Legal Representative (Seal): Legal Representative (Seal):

Date, year and month

3 Xuzhou Wangyi Network Technology Co., Ltd. Power of Attorney Contract:

Our company is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

I am here to convey

Legal person:

Company seal:

Time:

Article 4 of the power of attorney contract Client: Name, gender, age and ID number Client: Name, gender, age and ID number.

I hereby entrust the trustee as my agent to handle the following matters on my behalf:

Pay down payment, down payment, sign a power of attorney for simple contract for commercial housing purchase, bank mortgage loan, and handle all relevant procedures when purchasing commercial housing.

I acknowledge all the relevant documents signed by the agent within the scope of its authorization, and the rights and obligations arising from it in law shall be enjoyed and borne by the principal. This power of attorney shall come into effect as of the date of signature by the client.

Client: (signature or seal)

Xxx year165438+1October 3rd.

Power of Attorney Contract Article 5 Cost Consultation Contract

Customer:

Consultant:

Party A (hereinafter referred to as the client) and Party B (hereinafter referred to as the consultant) of the construction project cost consultation contract signed this contract through mutual consultation.

1. The entrusting party entrusts the consultant to provide construction project cost consulting services for the following projects:

Service content refers to the following contents:

(1) project budget preparation

(2) the preparation of bill of quantities

(3) Budgeting of valuation method with bill of quantities.

④ Quota pricing budget

(5) Audit of Bill of Quantities and Bidding Control Price

⑥ Cost control in the project implementation stage.

⑦ Appraisal of engineering cost disputes

⑧ Prepare the final accounts of completion.

Pet-name ruby stop price assembly

2. The wording and terms of this contract are synonymous with the conditions of the construction project cost consultation contract and related annexes.

Three. The following documents are an integral part of this contract:

1. Standard clauses of construction project cost consultation contract;

2. Special terms and conditions of the construction project cost consultation contract;

3. Supplementary and modified documents signed by * * * during the execution of the construction project cost consultation contract.

Four. The consultant agrees to undertake the construction project cost consulting business within the scope agreed in the special terms and conditions of this contract in accordance with the provisions of this contract.

Verb (abbreviation of verb) The Client agrees to pay remuneration to the Consultant according to the time limit, method, currency and amount stipulated in this contract.

1, normal service fee: 20% according to Yunjiazong No.6 document; The charging standard is 65438+ 0.8‰ of the total cost.

2. Payment time: within seven days after submitting the work results.

The construction project cost consulting business of this contract shall be implemented from the date of signing this contract to the end of the day when the work results are issued and the client pays the consulting service fee.

7. This contract is made in quadruplicate, with the same legal effect, and the entrusting party holds two copies; The consultant holds two copies.

Principal (seal): Trustee (seal):

Legal representative (signature or seal): Legal representative (signature or seal): Authorized agent (signature or seal): Authorized agent (signature or seal): Address:

Account Name Account Name:

Bank of deposit: Bank of deposit:

Account number: Account number:

Tel: Tel:

Chuan Zhen: Chuan Zhen:

20xx Year Month Day 20xx Year Month Day

Power of attorney contract Article 6 Power of attorney entrusting unit:

Legal Representative: Position:

Authorized by: Position: Work Unit:

I hereby entrust XXX (ID number: XXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXX

The agent of Party A who signs this contract has the following agency matters and authority:

1. sign a contract with XXXXXXXXXX company;

2. Deal with settlement and other related matters.

(Blank below)

Entrusting unit:

Legal representative:

Release date:

Validity period:

Power of Attorney Contract After the market research project proposal submitted by 7 B Market Research Company was approved by A Company, both parties signed a research entrustment contract. Then, the project officially began to be implemented. The contents of the entrusted investigation contract signed by both parties are as follows.

Party A: Company A of XX.

Party B: XX B Market Research Company

In order to further master the relevant information of children's beverage market, better meet the market demand, improve the marketing effect and promote the development of enterprises, Party A entrusts Party B to investigate the children's beverage market in a province through negotiation, and hereby signs the following contract:

I. Purpose and specific requirements of the research project (see project proposal)

Two. Contents and methods of investigation (see project proposal)

Three. Research work schedule (see project proposal)

Four, research funds and payment methods

Party A * * * pays Party B the investigation funds of × 10,000 yuan, which is used for Party B's travel expenses, on-site investigation commission, consulting fees, communication fees, data fees, management fees and other expenses during the investigation. All funds will be paid in three installments:

(1) Within one week after the contract comes into effect, Party A shall pay Party B 40% of the expenses stipulated in the contract, totaling × 10,000 yuan.

(2) Party A shall pay less than 40% of the expenses stipulated in the contract to Party B within one week after the completion of Paragraph 2 of Article 3 of this contract.

X ten thousand yuan.

(3) Within one week after Party B submits the general survey report and Party A approves it, Party A shall pay Party B the expenses stipulated in the contract.

The remaining 20% is public, totaling × 10,000 yuan.

Verb (abbreviation of verb) the attribution of responsibilities and achievements of both parties

Party A shall provide necessary conditions and relevant materials for Party B's investigation. The contents, methods and time arrangement studied by Party B during the investigation shall be conducted in accordance with the requirements stipulated in the contract, and the final investigation report shall meet the requirements of the investigation purpose. Without the consent of Party A, Party B shall not disclose the investigation and results to a third party. ..

The research results are owned by both parties. With the consent of both parties, the information and results obtained from the investigation can be transferred with compensation. Without the consent of one party, the other party shall not develop or transfer the investigation results.

Six, the termination of the contract, breach of contract and dispute settlement

(1) This contract shall be terminated after Party B submits the final investigation report and Party A approves it.

(2) Where Party A unilaterally terminates the Contract, it shall pay the corresponding expenses.

(3) If Party B terminates the contract unilaterally, Party B shall refund all expenses to Party A. ..

(4) In case of any dispute during the execution of the contract, both parties shall negotiate in the spirit of friendly cooperation. If necessary, please

The relevant departments shall conduct coordination or arbitration.

Seven. others

(1) Matters not covered in this contract shall be settled by both parties through consultation.

(2) This contract is made in sextuplicate, with each party holding three copies.

(3) This contract shall be signed and sealed by representatives of both parties.

Representative of Party A (signature) Representative of Party B (signature)

(Seal) (Seal)

Year, month, sun, moon, sun.

Article 8 of the power of attorney contract Client: xxx

Gender: x

Date of birth:

ID number:

Address:

Consignee: xxx

Gender: x

Date of birth:

ID number:

Address:

Reasons and matters of entrustment: I am unable to handle xxxxx related formalities in person due to my busy work, so I hereby entrust _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Term of entrustment: from the date of signature to the date of completion of the above matters.

The client has (does not have) the power of entrustment.

Customer:

Xxxx year x month x day

Article 9 of the power of attorney contract Party A: Nanjing Runsheng Construction Group Co., Ltd. (hereinafter referred to as Party A)

Party B: Chixian Construction Engineering Quality Testing Center (hereinafter referred to as Party B's attached certificate and business license) signed the following liability agreement with the engineering testing unit on the principles of equality, voluntariness, fairness, honesty and credibility in order to successfully complete the TJ 1 civil engineering project of the widening and expansion project of Xuyi Toll Station of Ning Expressway undertaken by our company, improve the management level of our company and clarify the responsibilities of both parties:

1. Project name: civil engineering TJ 1 Contract of widening and expansion project of Xuyi Toll Station of Ningxu Expressway.

2. Project Location: Xuyi Toll Station

Three. Construction period: 20xx65438+February 9th to 265438+June 020xx 10.

Four. Scope of responsibility of the agreement: inspection of all items and raw materials to be inspected on the road.

5. Construction content: subgrade lime soil layer, cement stabilized macadam base, asphalt surface layer, reinforced concrete surface layer, reinforced concrete box culvert, roadside guardrail, isolation guardrail, road traffic sign, pavement marking, pipeline engineering, and lighting channel setting.

Quality standard of intransitive verbs: design requirements

Seven. Responsibilities and obligations of both parties

1, responsibilities and obligations of Party A.

(1): Party A voluntarily entrusts Party B as the entrusted laboratory for Party A's self-inspection and self-control, and is obliged to provide necessary information such as the items, frequency and sampling plan of the enterprise entrusted to Party B for testing, so as to ensure the smooth signing of the contract.

(2): In general, Party A is responsible for sampling. If it is necessary to entrust Party B with sampling, Party A shall apply to Party B in advance and pay a certain fee.

(3): Party A has the obligation to provide Party B with sufficient samples that are well sealed and meet the testing requirements.

(4): Party A is obliged to fill in the contact list of testing business in batches, and explain the testing items, sample status, name and identification on the contact list.

(5): Party A is obliged to pay the inspection fee in batches according to Party B's charging standard.

(6): Party A is obliged to receive the test report in time.

2. Party B's responsibilities and obligations

(1): Party B voluntarily serves as the self-inspection and self-control entrusted inspection laboratory of Party A, and has the obligation to equip qualified inspectors and corresponding inspection equipment to carry out entrusted inspection business according to corresponding inspection standards and procedures.

(2): Party B shall carry out all work in strict accordance with the requirements to ensure the fairness, scientificity, accuracy and traceability of the test data.

(3): The equipment used by Party B for testing must be within the validity period of verification, and the environment meets the standard testing requirements.

(4): Party B is only responsible for the sample. Party B must carry out the test according to the requirements of Party A's power of attorney, and issue a test report, which must be true and accurate, and ensure that it is consistent with the original data of the test.

(5): After the relevant test information provided by Party A is accurate, Party B shall issue an accurate and reliable test report within the external acceptance period. If the report cannot be issued within the time limit under special circumstances, Party A shall be informed in time.

(6): Party B is responsible for keeping the samples of Party A to ensure the traceability of the reinspection and test results, and the sample storage period is one month.

(7): Without Party A's permission, Party B shall not disclose the relevant information of the other party to a third party. ..

Eight. Expense settlement

1. Testing fee: The testing center implements a unified external charging standard.

2. Payment method: settlement in batches according to the charging standard.

Nine. Liability for breach of contract and compensation

Within the validity period of this contract, if Party A and Party B fail to perform the provisions of this contract, they shall bear certain liabilities for breach of contract in accordance with the provisions of the Contract Law and the General Principles of the Civil Law.

Nine. This agreement is made in duplicate, one for Party A and one for Party B, and shall come into force after being signed and sealed. Matters not covered in the construction process shall be settled by both parties through consultation. This agreement is valid until the end of construction.

Party A (seal) and Party B (seal)

Representative signature: Representative signature:

Year, month, sun, moon, sun.

Power of Attorney Contract 10 Party A:

Legal representative:

Address:

Telephone:

E-mail:

Party B:

Legal representative:

Address:

Telephone:

E-mail:

Party A and Party B hereby sign this entrustment contract (hereinafter referred to as the "Contract") in accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) on Party A entrusting Party B to purchase _ _ _ _ _ _ _.

I. Entrusting Contents

Party A entrusts Party B to purchase this Contract or Party A entrusts Party B to purchase _ _ _ _ _ _ _ _ _ _ _ _.

Two. (1) inquiry sheet

1. Party A entrusts Party B to purchase on its behalf. Specific products are:

serial number

product name

standard

brand

quality requirements

amount

unit price

total

Total price: RMB _ _ _ _ _ _ _ (in words: _ _ _ _ _ _ _).

2. Party A may also entrust Party B to purchase other products at any time orally or in writing.

(II) Party B's responsibilities

1. Party B shall supervise the procurement business required by Party A and report the progress to Party A at any time.

2. Find a qualified manufacturer for Party A and truthfully provide the production and operation status of the factory.

3. Find the required samples and articles for Party A, and conduct sampling, inspection and shipment for Party A. ..

Three. Scope of responsibility of Party B

1. Party A directly places an order with Party B, and Party B is solely responsible for a series of one-stop services from order taking to shipment (Party A has nothing to do with Party B's relationship with any third-party manufacturer). Party B will place an order with the factory for production.

2. After receiving the inquiry form specified by Party A in detail, Party B shall provide Party A with the product quotation within _ _ _ _ (except for special and force majeure factors).

3. Party B guarantees that the unit price of the goods it provides is the lowest in _ _ _ _ _ _ _ _.

Fourth, about delivery time and quality.

1, delivery date: each batch of goods shall be shipped within the time limit agreed in the purchase order. Party B has the responsibility to supervise the production progress of the products. If the delivery is delayed due to objective reasons, Party B shall explain the reasons in writing and hand them over to Party A before the delivery time is delayed, so as to obtain Party A's understanding and permission. If the delivery is delayed due to Party B's unauthorized changes, Party A's relevant economic losses and legal responsibilities shall be borne by Party B. ..

2. Quality: Party B shall organize the production and delivery in full accordance with the sample quality. (The samples shall be signed and sealed by both parties. )

Verb (abbreviation of verb) acceptance criteria and liability for breach of contract

1. Before the goods leave the warehouse, Party B must provide samples of finished products to Party A for confirmation. Party A can arrange shipment only after confirming that there is no quality problem, and at the same time, Party A shall provide Party B with the goods acceptance certificate. If the product sample does not meet the requirements of Party A, there are two responsibilities:

(1) If Party A fails to specify the quality requirements in the purchase order, it shall be borne by Party A. ..

(2) If quality problems occur because Party B informs the factory of loopholes, Party B shall bear the responsibilities.

2. When purchasing and inspecting goods, Party B shall fully comply with the instructions and requirements of Party A.. If strict product inspection is required, Party A shall pay the corresponding inspection service fee in advance. So as to completely guarantee the quality of products. If the quality of the delivered products is defective due to Party B's negligence in procurement and inspection, which causes economic losses to Party A, Party B shall bear corresponding responsibilities.

3. If one party's breach of contract brings economic losses to the other party, the other party can immediately terminate the contract and has the right to investigate the relevant legal and economic responsibilities of the breaching party.

Intransitive verb payment method

Party B shall provide invoices, inspection reports and official invoices. After being confirmed by Party A, Party A shall pay the money to Party B's company account within _ _ _ _ _ _ _ _.

Seven. Other expenses borne by Party A.

1. If the goods purchased by Party A need additional deep processing, such as bar code labeling, repackaging, sorting, etc. And the processing expenses incurred due to the decrease or increase of temporary staff, Party B may apply for subsidies from Party A after obtaining the consent of Party A. ..

2. If the goods need to be inspected directly in the factory, the accommodation fee shall be borne by Party B according to the standard of RMB, and the excess accommodation fee shall be borne by Party A. ..

3. If Party A's company personnel and customers come for business investigation and purchase, Party B will assist in sending cars to pick up and drop off personnel to participate in business activities and arrange transportation and accommodation, and the expenses incurred shall be borne by Party A. ..

4. Party A guarantees that _ _ _ _ _ _ will only accept all the goods provided by Party B within the validity period of the contract, and Party A shall not contact the manufacturers and agents of _ _ _ _ _ _. If Party A's breach of contract causes economic losses to Party B, Party A shall compensate Party B for the corresponding economic losses.

Eight. Confidentiality agreement

Party A and Party B are responsible for keeping confidential the cooperation materials and supply channels of both parties. Any personnel of the companies of Party A and Party B shall not disclose the cooperation information of both parties to any third party. If any leakage causes economic losses to Party A or Party B, the disclosing party shall compensate the disclosing party for the economic losses after Party A or Party B verifies and provides relevant evidence.

Nine. Cooperation clause

The term of cooperation between the two parties is _ _ _ _ _ _ _ _ _ _ _. After the expiration of this agreement, Party B has the priority to sign this agreement.

X. dispute resolution methods

If there is any dispute in the process of cooperation, both parties can settle it through consultation. If the dispute cannot be settled, bring a lawsuit to the people's court of _ _ _ _ _ _ _ _ _ _ _ _ _ _.

This agreement is made in duplicate, one for each party, and shall come into force after being signed and sealed by both parties.

Party A (seal):

Legal representative (signature):

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (seal):

Legal representative (signature):

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _