Contract 1 (full name): hereinafter referred to as Party A)
Contractor (full name): (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this construction project and conclude this contract.
I. Overview of the Project:
Project name:
Project location:
Project content: The construction area of the residential area is about square meters (calculated according to the actual income after completion).
Second, the project contracting scope:
Scope of contract:
1, all construction projects in the design scheme;
2. The toilet and balcony are cast-in-place. The first floor is 2.5m high and is a precast slab, while the second, third and fourth floors are 3m high. The whole cast-in-place floor is covered with red tiles.
3. Exterior walls are painted with exterior wall paint, and side wall columns are made of cultural stone wall bricks.
4. The interior wall of the room is pink.
III. Term of the contract:
Start date:
Date of completion:
Fourth, the quality standard:
Engineering quality standard: design and construct strictly according to the drawings, and Party B shall not cut corners in any form or method. If it is necessary to modify the building scheme, Party A and Party B shall apply to the design department for issuing a notice of modification after consultation.
Verb (abbreviation for verb) contract cost:
Total project cost: After completion, calculate the total construction cost according to the acceptance measurement area.
Project unit price: RMB/m2, excluding deed tax.
Terms of payment for intransitive verbs:
1. The construction area will be paid in four phases, that is, the first floor storage room cover will pay 50% (Yuan/m2) according to the square of the actual construction area, and the first, second and third floors will be covered with roofs, and so on.
2. The internal powder shall be paid 20% according to the image progress of the construction area.
3. The external powder shall be paid 10% according to the image progress of the construction area.
4. The balance shall be paid after acceptance.
VII. Form of contract:
Form of contract: no material contract.
Eight. Work of Party A:
Party A shall complete the following work according to the agreed time and requirements:
1. Connect the water, electricity and communication lines needed for the construction to the construction site, so that the water, electricity and roads are accessible and the site is leveled (i.e. three links and one leveling).
2. Other work agreed by both parties that Party A should do: Before Party B carries out the house acceptance, Party A shall not allow the owner to interfere with the construction, except the house wiring. When the owner and guests enter, the owner shall take full responsibility for the safety problems, and Party B shall not take any responsibility.
Nine, construction and design changes:
1. The design drawings, descriptions and relevant technical data delivered by Party A are effective basis for construction, and Party A and Party B shall not change them without authorization.
2. In the process of construction, if there is any mistake or serious irrationality in the design, Party B shall promptly notify Party A in writing, and Party A shall promptly study and determine the revision opinions or change the design documents together with the design department and other relevant units. Party B shall carry out the construction according to the revised or changed design documents, which is beyond the scope of the original design drawings and belongs to additional work. After the additional items are approved by both parties, they shall be settled with Party B according to the original budget standard.
3. If Party A needs to change the design, the original design unit must issue a formal notice of change and modify the drawings before Party B can implement it.
4. On behalf of the comrades, Party A is responsible for the acceptance visa of the construction site, and its visa serves as the basis for project settlement.
Ten, project acceptance and settlement:
1, the acceptance of the completed project is based on the completion acceptance regulations issued by the state and formulated by relevant departments, as well as construction drawings, specifications and construction technical documents.
2. During the construction period, structural engineering and underground engineering must have concealed acceptance visas. After the quality of the completed project has passed the inspection by the local quality supervision department, Party A shall go through the visa formalities in time.
3. During the specified warranty period, Party B shall provide free warranty for all quality accidents and quality defects caused by construction. The warranty conditions, scope and duration shall be implemented in accordance with the Regulations on Quality Management of Construction Projects.
XI。 Dispute resolution method:
If either party violates the provisions of the contract and both parties fail to negotiate, it shall be settled in the following ways:
1. Apply to the contract arbitration authority for arbitration;
2, to the people's court.
Twelve. Others:
Party B shall follow the principle of safe production, formulate safety construction measures to prevent the occurrence of safety accidents, and bear all safety responsibilities in the construction process, including all safety responsibilities in the material transportation process, and all safety accidents shall be borne by Party B. ..
Thirteen. Supplementary terms:
1. This contract is made in quadruplicate. Party A and Party B each hold one copy.
2. For matters not covered in this contract, a supplementary agreement can be signed after both parties reach an agreement through consultation, and the supplementary agreement has the same legal effect as this contract.
Fourteen Entry into force of the contract:
This contract shall come into effect after being signed by the representatives of both parties and stamped with the official seals of both parties. The project completion acceptance meets the requirements and will be terminated after the project payment is settled.
Signature of Party A:
Signature of Party B:
Time:
Contract II of Single Package Project: (Party A)
Contractor: (Party B)
I. Project name:
Second, the scope of contracting:
All construction contents of the project
Third, the way of contracting:
contract for labour and materials
Fourth, the opening and completion time:
Completion time:
Five, quality requirements:
Six, acceptance criteria:
According to the current corresponding engineering construction specifications, the acceptance of both parties shall prevail.
Seven. Warranty date:
One year, that is, from the date of completion acceptance.
Eight. Responsibilities of both parties:
Party A:
1, responsible for providing water and electricity within 50 meters of the site.
2, responsible for timely disbursement of project funds according to the image progress.
3. Be responsible for ensuring that the site meets the construction requirements.
4, responsible for the coordination work in engineering construction, etc.
Party B:
1, responsible for the safety of construction personnel, and all economic losses due to unsafe accidents caused by illegal construction.
2, do a good job in project management, construction process, all the current relevant specifications, to ensure the time limit for a project, to ensure the engineering quality requirements.
3. Take good care of Party A's original facilities and compensate the losses according to the price.
Nine, the settlement method:
1, the settlement of this project shall be carried out according to Zibo Price List of Consumption Quota of Installation (Construction) Project in Shandong Province issued on April 1 day of 20xx.
2. Construction enterprises charge according to three categories.
3, the construction unit pricing, pricing and settlement.
4. Contract pricing part:
X. Allocation method:
1, the project starts at% of the budget;
2, after the completion of the project acceptance, according to% of the budget;
3. After the project is completed and accepted, xx% of the settlement amount will be paid, and the balance xx% will be paid within one year (within one month).
1 1. Disputes between the two parties: in case of disputes, arbitration shall be conducted by the statutory arbitration department of Zibo.
This contract is made in duplicate, which shall come into effect after being signed by both parties, and shall become invalid after the project payment is paid.
Signature of Party A:
Time:
Signature of Party B:
Time:
Contract awarding unit of project general contract 3: _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ _ _ _ _ _ _
In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on project contracting and signed this contract.
I. Article 1: Overview of the Project
The contracted project of lakeside slope protection project is contracted to Party B, and the construction is contracted with materials. The total length of lakeside slope protection is calculated in meters.
Two. Article 2: Construction Scheme
1, slope protection
(1), the base is meters wide, meters thick and meters high from bottom to top. Cold-drawn brick belts are needed for the stressed parts, and sand grinding is needed for the external walls (cement numbers 42 and 5, and the bricks are blue bricks or red bricks with good quality).
(2) Demolition of three houses next to the toilet for access.
(3) After completion, the fence is about10m.
(4) The gap between the wall and the bank should be tamped with soil, and an appropriate amount of leaking pipes should be added to the wall.
Three. Article 3: Term of Contract
1. The construction period is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. In case of force majeure during construction, or Party A requests Party B to stop work, the construction period will be postponed accordingly.
Four. Article 4: Price and Payment Method
1, and the total contract price of the project is _ _ _ _ _ _ _ yuan.
2. The above-mentioned total contract price is lump sum price, including all work contents, labor and materials contracting and all other expenses (including house demolition and fence) of this contract, and Party A does not need to pay any more expenses to Party B. ..
3. Payment method: RMB will be paid after the completion acceptance, and the rest will be paid after one year (counting from the date of acceptance) except for 5% of the total amount.
Verb (abbreviation of verb) Article 5: Obligations of Party A.
1. Allocate the project payment to Party B according to the contract.
2. Assist in coordinating matters such as temporary water and electricity use on the construction site.
Article 6 of intransitive verb: Party B's obligations
1. The contractor is responsible for supervising and inspecting the quality, progress and safety of the project, handling daily related matters and ensuring the safety and stability of the project construction.
2. The contractor must complete the contracted project and shall not subcontract it to others.
Seven. Article 7: Construction Safety
The contractor shall abide by the relevant provisions of the project construction safety production management, organize the construction in strict accordance with the safety standards, and take necessary safety protection measures to eliminate the hidden dangers of accidents.
Party B shall bear all responsibilities and expenses caused by accidents in the construction process.
Eight. Article 8: Acceptance
The project completion acceptance shall be based on the construction scheme and quality acceptance standard. If the acceptance is unqualified, Party B shall be responsible for rework for free.
Nine. Article 9: Liability for breach of contract
1. Party A shall pay the project payment in time as agreed in this contract. In case of overdue, Party A shall pay liquidated damages to Party B (the interest shall be calculated according to the bank loan interest rate of the payable amount for the same period).
2. If Party B fails to complete the project on schedule due to reasons other than Party A's or force majeure, Party B shall pay liquidated damages of 1% of the total project amount to Party A for each day overdue;
If the overdue period exceeds ten days, Party A has the right to unilaterally terminate the contract.
X article 10: others
This contract was signed by both parties on.
Employer (Party A) (Seal) _ _ _ _ _ _ _ _ _ _ _ _
Authorized agent (signature or seal): _ _ _ _ _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ _ _ _ _ _ _
Contractor (signature or seal): _ _ _ _ _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project Single Subcontract 4 Party A: _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Through negotiation between both parties, the new hydropower project of Building 8- 14, Phase I and Phase II of Yiliang Century Liangcheng is contracted out to Party B for installation in the form of single package, as follows:
1. Install all joints of brick wall and all secondary conduits on brick wall, and the labor cost for installation and piping is RMB.
2, play all trough and sink, with each _ _ _ yuan labor cost calculation.
3. The labor cost for installing the strong and weak current boxes and pipes shall be calculated at RMB _ _ _ _ _ _ _ _ _ _
4. The above dimensions are subject to the horizontal line.
1. Jintong socket is 65 points below the horizontal line 1 meter.
Second, the switch is at 45 o'clock on the horizontal line.
Three, lighting control box to the horizontal line 55 points.
Fourth, the weak box is 45 points below the horizontal line.
5. If the above installation fails to meet the size requirements and goes out of the wall, Party B shall bear all the responsibilities due to reasons such as inadequate secondary piping and pipeline blockage. If the project quality is not up to standard or the wasted materials are compensated.
6. Tools shall be brought by Party B. ..
7. During the installation period, only the living expenses will be about 1000 yuan. After the installation is completed, Party B shall pay 70% of the labor cost after the supervision and acceptance, and all labor costs shall be paid within 60 days after the completion of the project.
8. Party B shall be responsible for safety. Party A does not undertake any safety responsibilities. Do not drink, fight, make trouble when entering the construction site, and do not take things home from the construction site. Party B shall be responsible for any of the above safety accidents.
9. In case of shutdown or waiting for work due to shortage of personnel and technicians, Party A has the right to take back the project without paying all the expenses.
10. This contract is made in duplicate, with each party holding one copy. The contract held by both parties has the same legal effect, and it will take effect from the date of signing by both parties, and will automatically become invalid after all the project funds are paid.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A: (hereinafter referred to as Party A) _ _ _ _ _ _
Party B: (hereinafter referred to as Party B) _ _ _ _ _ _ _
Party A contracted 750㎡ interior decoration on the second floor of Building B in Phoenix to Party B. In order to clarify their respective responsibilities, both parties reached the following terms through negotiation.
Article 1 Project Name: Decoration Project of Finnish Exploratory Early Education Institution
Article 2 Project Location: Floor 2, Block B, Phoenix Mall
Article 3 Project Content: Interior Decoration of Early Education Center (see internal list for details)
Article 4 Contracting methods: contracting labor, materials and everything.
Article 5 Project cost: Budget price: six hundred and seventy-eight thousand four hundred and fifty-six Yuan only (678,456.0 Yuan). After verification by both parties, the final total project price is six hundred and twenty thousand yuan only (620,000.0 yuan only). If the drawings remain unchanged or Party A does not increase the total project price of other projects, it will remain unchanged.
Article 6 Contract term: Commencement date 1 year, April 20xx, and completion date, June 20, 20xx, with 80 working days. Both parties shall confirm whether the construction can be carried out every day. If there are other objective factors affecting the progress of the project, the construction period can be postponed accordingly.
Article 7 Payment method: Party A shall pay 20% of the total price, about RMB one hundred and twenty-four thousand Yuan only (65,438+024,000 Yuan only) within 65,438+00 days after Party B's personnel enter the site for construction; When more than 40% of the total engineering quantity is completed, Party A shall pay 30% of the second total price, which is about RMB one hundred and eighty-six thousand Yuan only (65,438+086,000 Yuan only); When more than 90% of the total engineering quantity is completed, Party A shall pay 30% of the total price, namely RMB one hundred and eighty-six thousand Yuan only (65,438+086,000 Yuan only). Party A shall pay the remaining amount within 20 working days after the completion and acceptance of all projects.
Article 8 Design change: If it is necessary to change the drawings and projects during the construction, both parties shall reach an agreement through consultation, and Party A shall bear the increased cost of the change.
Article 9 Project quality: Party B must strictly follow the drawings, strive for perfection, strive for excellent projects, and do not cut corners and shoddy products, which will affect the project quality.
Article 10 Responsibilities of Party A and Party B:
Party A's responsibilities:
(1) Party A shall provide power facilities at the construction site free of charge.
(2) Party A shall pay the project payment on time and shall not delay the payment, so as not to delay the construction period.
Responsibility of Party B: Party B must complete the project on time within the specified time, and Party B shall be responsible for the safety accidents caused by improper construction operation.
Article 11 Liability for breach of contract: Party A fails to pay the decoration payment on time, and is fined 1 000 yuan, and delays the construction period, and is fined 1 000 yuan.
Article 12 Contract disputes: Matters not covered in the above terms shall be settled by both parties through consultation. In case of dispute, it shall be decided by the local people's courts of both parties.
Article 13 This contract is made in duplicate, with each party holding one copy, and shall come into effect after being signed by both parties.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party 6 (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
After friendly negotiation, Party A decided to entrust Party B with the decoration. In order to protect the legitimate rights and interests of both parties, combined with the specific conditions of this project, the two parties reached the following agreement for common compliance.
1, project overview
(1) Decoration construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(2) Decoration construction content: See the attachment for details.
(3) Contracting method: quantity contracting.
(4) Construction period: starting from: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. Overdue completion, according to the daily compensation of RMB yuan.
2, the project price and settlement agreement
(1) Total project price: _ _ _ _ _ _ _ Yuan, in words (RMB): _ _ _ _ _ _ _ _ _ _ _ _ _.
(2) The payment method of project funds is as follows:
1) When the budget design is approved for the first time, 30% of the total project cost will be paid, totaling _ _ _ _ _ _ _ _ yuan.
2) Pay 70% of the total project cost on the day of the second completion acceptance, totaling RMB _ _ _ _ _ _.
3) The project quality warranty period is 1 year. The warranty period is calculated from the date of signing the completion acceptance.
3. Material supply and decoration process agreement
(1) If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If there are quality problems or specification differences in the materials and equipment provided by Party B, resulting in engineering losses, Party B shall bear the responsibilities.
(2) During the construction, Party A shall contact Party B in advance when proposing design modification opinions and adding or subtracting engineering projects. The construction of this project can only be carried out with the consent of both parties, thus affecting the completion date, and both parties agree.
(3) In the process of construction, Party B shall take necessary safety protection and fire control measures to ensure the safety of operators and nearby residents, and prevent accidents such as pipeline blockage, water leakage, power failure and destruction of articles. In case of the above situation, it shall be the responsibility of Party A, and Party A shall be responsible for and compensate; Where Party B is responsible, Party B shall be responsible for repair and compensation.
(4) Party B shall participate in the on-site disclosure of the construction drawings or work instructions organized by Party A, organize the construction as required, complete the construction tasks with good quality and quantity on schedule, and solve all matters for which Party B is responsible, and Party B shall recognize its actions. Without the consent of Party A and the approval of the local housing management or property management department, the original building load-bearing structure, various equipment and pipelines shall not be dismantled and modified at will.
4. Dispute handling methods
Any dispute arising from the execution of the contract between the two parties shall be settled through friendly negotiation. If negotiation fails, a lawsuit may be brought to the people's court.
After this contract is signed by both parties, both parties must strictly abide by it.
Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.