How to write a contract contract? Let us learn about it together:

The main contents of the contract contract include: 1. The names of the issuing party and the contractor should be written clearly. and residence; 2. State clearly the contents of the contracted project; 3. State clearly the time limit and specific requirements for the performance of the contract; 4. State clearly the amount of the price and method of payment; 5. State clearly the liability for breach of contract, etc.

Contracting operation contract sample 1

Party A:

Party B:

In order to strengthen project management and implement the project contracting responsibility system, Ensure scientific management, standardized work, standardization of site, and professional division of labor, fully mobilize the enthusiasm of both parties, and improve project operating efficiency. In accordance with the provisions of relevant laws and administrative regulations, Party B recognizes the project construction contract signed by Party A and the contractor (hereinafter referred to as On the basis of the "Construction Contract" (including supplementary agreements and attachments), in accordance with the requirements of Party A's relevant project management measures, and after negotiation by both parties, they agree to sign this "Internal Contracting and Operation Contract of the Engineering Project" (hereinafter referred to as the contract).

Article 1 Project Overview

1. Project name:

2. Project location:

3. Project duration: A The construction contract signed between the party and the contractor shall prevail.

4. Project quality standards: Subject to the construction contract signed between Party A and the contractor.

The second principle and method

1. Implement the project leader responsibility system: Party A appoints the project leader (Party B). During the implementation of project construction management, On behalf of Party A, we have the first responsibility to fully perform the "Construction Contract" and assume full responsibility for the profits and losses of the project.

2. Implement the principle of ensuring submission and being responsible for profits and losses. Party A shall conduct unified accounting and project costs shall be listed separately. Ensure that business tax, income tax, management fees and other taxes are paid.

3. Party B shall, in accordance with the principle of “dynamic management and optimized combination”, equip a capable project management team (the members of the project management team and the implementation of division of labor responsibilities provided by Party B must be reported to Party A for review and filing before the start of construction) ) to meet the requirements of project quality, safety, construction period, civilized construction, and reduction of project costs.

4. Based on the needs of the project, Party A will send professional technical management personnel to provide technical guidance on technical issues involving project settlement, cost accounting and other technical issues.

5. According to the situation of this project, Party A appoints a comrade as the person in charge of the on-site project, and has full authority to supervise and manage the quality, safety, progress and civilized construction of the site and the performance of the contract, and regularly report to The company reports on on-site construction status.

Article 3 The scope of project contracting and contract workload

Subject to the full content signed between Party A and the contract issuing party on the year, month and day.

The fourth indicator

1. Project contracting handover coefficient: Party B will hand over management fees to Party A based on the total project settlement cost or yuan/m. Business tax, income tax, local or industry-mandated taxes, salaries of Party A’s stationed management personnel, travel expenses, social insurance premiums, housing provident funds and other taxes shall be withheld and paid by Party A to Party B at the prescribed tax (fee) rate. All taxes and fees are paid at the time of each invoice.

2. Construction period: The construction period and start date of the contract signed between Party A and the contractor shall prevail. Party B shall ensure that the construction period is completed according to the construction period stipulated in the "Construction Contract". If Party B causes a delay in the construction period, in addition to complying with the provisions of the Construction Contract, a fine of 1,000 yuan will be imposed for each day of delay; if the delay exceeds 30 days, Party B will not be able to perform the contract or change the status quo, which will cause damage to Party A's image and reputation. In the event of loss, Party A has the right to terminate the contract and assign another project leader to organize the construction and management work.

3. Project quality: Strictly implement the national construction quality acceptance specifications for construction projects to ensure that the project quality meets the national acceptance grade standards. If a quality accident occurs, all responsibilities and economic losses shall be borne by Party B.

4. Safety production: Construction shall be carried out in strict accordance with national safety operating regulations and standards to prevent the occurrence of any safety accidents (such as personal injury accidents, equipment accidents, traffic accidents, fire accidents, etc.). If a safety accident occurs, all responsibilities and economic losses will be borne by Party B.

5. Civilized construction: In accordance with the relevant requirements of the construction administrative department where the project is located and Party A’s relevant documents on safe and civilized construction, the corporate image project will be implemented, and the costs required will be borne by Party B.

6. Recovery of project funds: timely collection according to the time and quantity specified in the terms of the "Construction Contract", with a recovery rate of 100%.

Article 5: Provisions on project payment: Party B shall submit the statistical workload report for the current month and the progress plan report for the next month to the contractor and Party A in accordance with the provisions of the "Construction Contract", and propose the following Plan the required monthly funds and materials, and propose monthly costs (accounting statements). Party A will review Party B's monthly costs in a timely manner to ensure that project funds are earmarked for special use.

Article 6: Provisions on project warranty money: After the project is completed and the warranty period expires, after Party A recovers the warranty money from the contract-issuing party, the warranty money will be returned to Party B in one go; if the contract is issued during the warranty period, If Party B requires warranty, Party B shall send personnel to carry out warranty in time, and the cost shall be borne by Party B, otherwise the warranty money will not be refunded.

Article 7 Provisions on Risk Mortgage:

(1) Party B shall be responsible for paying the full amount of the project performance bond paid to the contracting party in accordance with the provisions of the bidding documents, and use this As the risk deposit paid by Party B to Party A.

(2) The funds required during the construction will be paid by themselves. Party A does not assume the guarantee of fund loans. The creditor's rights formed due to the operation of the project are enjoyed by Party B, and Party B bears unlimited liability for the debts.

(3) Party B pays a safety risk contract deposit of RMB 10,000 for this project. If no major safety accidents or violation fines occur after the completion of the project, it will be returned without interest.

(4) Party A charges a 2% quality deposit, (if the construction unit charges a quality deposit ≥ 5%, it does not need to be charged), the quality deposit

(5) After the project is completed and settled, If the project is fully performed in accordance with the "Construction Contract", there are no quality or safety problems, all claims have been recovered without losses and debts, the project completion data are complete, and there are no non-refundable situations stipulated in the "Construction Contract", the contracting party will The performance deposit will be returned to Party B in one lump sum after the performance deposit is returned. If other problems arise, they will be refunded after the problem is resolved.

(6) Party B shall declare and pay the project work-related injury insurance to the labor department where the company is located within 10 days before the start of the contracted project. The insurance fee can be paid before construction can start. If Party B’s contractor refuses to pay the fee, the company shall If the project payment is deducted and paid, and the project payment is not transferred to the company's account to avoid payment, the contractor shall bear all economic and legal consequences.

Article 8 Handling of Credits and Debts: Before the end of the project and internal settlement, Party B must settle all claims and debts and write a written guarantee to Party A for debt settlement. If Party B conceals a debt, Party A will deduct it from the performance bond and project warranty money paid by Party B to the construction party. Party B shall be responsible for making up the difference or paying off the debt for the shortfall, and bear all the consequences caused to Party A. loss.

Article 9 Party A will deduct 10,000 yuan from the project payment allocated by Party B. When the project construction is completed and all contents of the contract have been approved by all parties, Party B will return the settlement statement and completion certificate approved by the construction party. After the information and items are returned to Party A for use, the money retained will be returned without interest.

Article 10 Financial Management: In order to ensure that the project funds are earmarked for exclusive use, payment collection shall be handled in strict accordance with the company's financial management system. Party B must pay off the debts as agreed for all materials and equipment contracts guaranteed and signed by the company. , Otherwise, Party A has the right to deduct the full payment from the project payment allocated by Party B. Each time the owner pays a project progress payment, Party A shall pay Party B in full after deducting taxes and fees.

Article 11 This Contract will come into effect after being signed and sealed by both parties. After the project is handed over and accepted, the final payment of the project has been collected, and the credits and debts related to the project have been cleared, and after the warranty period expires, this Contract will automatically become invalid.

Article 13 This "Contract" is made in two copies, with Party A and Party B each holding one copy.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): ________Legal representative (signature): _________

< p>_________year____month____day_________year____month____day

Contracting operation contract sample 2

Contracting party: (called A Party)

Contractor: (called Party B)

After friendly negotiation among all shareholders of the company, it was decided to carry out internal contracting and operation of the company’s production line by shareholders. The relevant matters are as follows:

Chapter 1 General Principles

Article 1: In order to strengthen the operation and management of enterprises and continuously improve economic benefits, in accordance with relevant national laws and regulations and the spirit of relevant meetings of shareholders, combined with the actual situation of the enterprise, in the spirit of seeking truth from facts and mutual benefit Based on the principle of mutual benefit, all shareholders must jointly sign an internal contract and operation contract (hereinafter referred to as the contract), and Party B shall undertake the overall contract operation (hereinafter referred to as the contractor).

Article 2 The contractor implements an operating model of independent operation, independent accounting, and is responsible for its own profits and losses, and is solely responsible for the claims and debts in the operation process and the resulting economic, safety and legal responsibilities.

Article 3 Enterprise Financial Management: The contractor shall manage itself in accordance with relevant financial regulations and rules and in accordance with the principles that are conducive to operation. Party A shall not interfere for any reason.

Article 4 The contractor should pay all taxes and fees on time and in full in accordance with relevant policies and relevant regulations of the industry and commerce, taxation, health, quality supervision and other departments, and strictly refer to industry service standards to provide good services. .

Chapter 2 Contracting Base

Article 5 The annual general contracting fee of the contractor is 10,000 yuan. As the income of all shareholders of the company, the annual contracting fee shall be paid in two installments each year. Fees must be paid on June 30th and December 31st. (Note: The contracting fee is exempted in the first year, and the annual contracting fee from the second to the year is RMB 10,000.

Chapter 3 Contracting Period

Article 6 This contract is valid for years. From the date of the year to the date of the year

Article 7 When the contract expires, the contractor can voluntarily renew the contract after completing the payment of the contract fee, but the contractor must do so six months before the expiration. If you submit your intention to renew in a formal written form, you will have priority to renew under the same conditions.

Chapter 4 Rights and Obligations

Article 8 Rights and Obligations

1. The company shall have legal ownership of the properties, facilities, equipment and other assets handed over to the contractor for contract operation and management, and shall have the right of supervision.

2. Supervise the legal operation of the contractor and shall not interfere with the contract operation.

3. Create a good business service environment for the contractor and ensure the normal supply of water and electricity to the contractor if the contractor pays the relevant fees on time.

4. Efforts to assist the contractor in external coordination during the contracting period

5. Assist the contractor in the handling of emergencies and major accidents.

p>

6. The contractor shall handle the maintenance of its own water supply and drainage system and bear the corresponding costs

Article 9 Rights and Obligations of Party B

1. Contract Period. Within the contract period, Party B has the right to use the assets provided by the company and must keep the equipment in good condition. Normal maintenance costs shall be borne by Party B. If the facilities are naturally damaged due to expiration of their service life, Party B shall bear the right to use them.

3. If necessary for business operations, Party B will be responsible for If the original workshops, machinery and equipment are to be renovated and updated, or new business premises are built in the corresponding area, a plan for renovation, renovation and new construction must be proposed in advance and must be reviewed and approved by the company's shareholders meeting before implementation (no reply after more than 15 working days will be deemed to be consent). Bulk purchases of fixed asset investment (mainly equipment updates) must be reported to the company's shareholders' meeting for approval in advance, and the cost will be deducted from the contracting fee.

Four. Party B may raise funds by itself based on market prospects and company development needs. If you invest in building a product production line, you will receive a commission of RMB per bottle as income for all shareholders. The fixed assets will be owned by Party B and will be produced and operated until the expiration of the operating period stipulated in the company's articles of association.

5. If the company's intangible and Financial activities such as mortgage loans with tangible assets must be approved by the company's shareholders meeting, otherwise the legal and economic responsibilities of the contractor will be held.

6. Customer service must be standardized, customer complaints must be handled carefully, and the procurement procedures for sanitary cleaning supplies and food as well as the quality assurance appraisal system must be strictly implemented.

7. Operate honestly, establish a good corporate image, establish good social relations, and consciously abide by various national management regulations on special industries.

8. Do a good job in various safety work during the operation period, especially strictly implement fire protection, food, sanitation, safety and other work, and consciously accept the supervision and inspection of relevant departments. You must bear your own legal and financial responsibilities.

Chapter 5 Liability for Breach of Contract

Article 10 Any violation of the terms of this contract by either party shall be a breach of contract. The observant party shall have the right to rely on the contract documents and the "People's and the National Economic Contract Law to hold the breaching party legally and financially responsible.

Chapter 6 Dispute Resolution

Article 11 For disputes arising during the execution of the contract, the parties shall negotiate and resolve them in a pragmatic manner. If negotiation fails, they shall The case was submitted to the People's Court of Huanjiang Maonan Autonomous County for a ruling.

Chapter 7 Supplementary Provisions

Article 12 Matters not covered in this contract can be settled through negotiation between the parties in accordance with the relevant provisions of the "Economic Contract Law of the People's Republic of China" After consensus, it will be modified and additionally added. If there is any conflict between this contract and newly promulgated national regulatory documents, the national regulatory documents shall prevail.

Article 13 This contract is made in five copies, with each shareholder holding one copy and the board of directors keeping a secret copy and taking effect after signature.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): ________Legal representative (signature): _________

< p>_________year____month__________year____month____day

Contracting and operating contract sample 3

Parties entering into the contract:

p>

Contractor:_Company

Contractor:_

The company (contractor) and _(contractor) reached an agreement through consultation and approved by the shareholders meeting of _company , the company's operating rights are now outsourced to the contractor for operation within the term of this contract, and this contract is concluded.

Chapter 1 General Provisions

Article 1 During the contract operation period, the company shall conduct independent accounting, pay taxes in accordance with the law, operate independently, and be responsible for its own profits and losses. The financial and taxation channels remain unchanged.

< p>Article 2 During the contract operation period, the contractor must engage in business activities within the company's legal business scope (subject to the company's corporate legal person business license).

Chapter 2 The term, method and main indicators of contracting

Article 3 The term of contracting is one year, that is, from August 7, 20_ to 20_ Ending on August 6th.

Article 4 The method of contracted operation is: the contracting party shall provide the company's operating rights to the contractor within the contracting period, and the contractor shall pay the contracting party RMB 2,000 for this purpose. . The amount is paid before ____.

Chapter 3 Rights and Obligations of the Contractor

Rights of the Contractor

Article 5 During the contracting operation period, the agent appointed by the contractor (limited to One person) serves as the legal representative of the company and exercises the powers of the general manager.

Article 6 The contractor shall have independent and independent management rights over the company during the contract period.

The specific rights are as follows:

1. The right to appoint deputy general managers and department managers to form the company’s leadership organization and report to the shareholders’ meeting for filing. After the contract period expires or the contract is terminated, , the leadership organization will be disbanded.

2. It has the power to decide the company's organizational structure, formulate rules and regulations, personnel recruitment, appointment and removal, rewards and punishments.

3. The right to purchase new equipment and assets based on actual needs.

Article 7 The contractor has the right to obtain the legal income it deserves in accordance with the provisions of this contract.

Article 8 The contractor has the right to use the company’s official seal and contract during the contract period. Financial documents such as seals, checks, account numbers, invoices, etc.

Obligations of the Contractor

Article 9 The Contractor shall have the following obligations during the contracting period:

1. It must pay the dues on time and in full in accordance with relevant national regulations. Pay various taxes, fees, etc. 2. During the contracting period, the company's assets should be kept intact (except for reasonable losses).

Article 10 The contractor must fully perform the obligations stipulated in this contract. All terms to be performed by the contracting party.

Chapter 4 Rights and Obligations of the Contracting Party

Article 11 The rights of the Contracting Party are as follows:

1. The right to safeguard The company's interests are not harmed.

2Have the right to supervise the company's business scope.

3Have financial supervision rights over the company.

Article 12 The obligations of the contracting party are as follows:

1. It shall not interfere with the contractor’s operating rights in any form.

2 The legitimate rights and interests of the contractor must be protected in accordance with the provisions of this contract.

3 All terms in the contract that should be fulfilled by the contracting party must be fully fulfilled.

Chapter 5 Contractor’s Income

Article 13 Contractor’s income calculation method: All profits made by the contractor during the contract operation period shall be enjoyed by the contractor.

Chapter 6 Change, rescission or termination of the contract

Article 14 This contract will be legally binding after it takes effect, and neither the contracting party nor the contractor may change or terminate it at will. When the contract needs to be changed or terminated, both parties must reach a new written agreement through negotiation. This contract will remain valid until a new written agreement is reached.

Article 15 During the performance of this contract, if the relevant national policies change significantly compared with the time when this contract was signed, and the interests of any party who issues or contracts the contract are significantly affected, the affected party may propose changes or Terminate this contract.

Article 16 If the contracting party violates the provisions of this contract, interferes with the contractor's business and management activities, makes it impossible for the contractor to continue operating, or causes the contractor's legitimate income to be unprotected, the contractor has shall have the right to terminate this contract and suspend payment of contract fees, and require the contracting party to bear liability for breach of contract.

Article 17 If this contract cannot be fully performed or cannot be performed due to force majeure, the contract must be issued. The contracting parties may change or terminate the contract by consensus through negotiation.

Article 18: Upon the expiration of the contracting period stipulated in this contract, the contract shall terminate automatically after the rights and obligations of both parties have been fulfilled.

Article 19 Thirty days before the expiration of this contract, the contractor shall accept the auditing agency sent by the contract issuing party to audit its contracting situation. After confirming that it is correct, representatives of both parties shall sign the audit opinion letter. Only the contractor can resign.

Chapter 7 Liability for Breach of Contract

Article 20 When issuing a contract, both parties to the contract shall fully and actually perform the contract. Failure to perform or incomplete performance shall bear liability for breach of contract.

Article 21 If the contractor violates the provisions of Article 20 of this contract, it shall bear liability for breach of contract and pay 50% of the contractor’s total investment in the company as liquidated damages. If the contractor’s actual If the loss exceeds the liquidated damages, the contracting party shall compensate the contractor according to the actual losses.

Chapter 8 Supplementary Provisions

Article 22 If an accident occurs and the contractor is unable to continue to perform this contract, the contractor shall select or appoint another contractor. Party determines that it will continue to perform this contract.

Article 23 When signing this contract, the contracting party shall compile a list of all the company's assets, claims and debts, and make it an attachment to this contract after confirmation by both parties.

Article 24 After the expiration of this contract, if the company is contracted for operation and the contractor performs the contract well, the contractor has the priority to re-contract under the same conditions.

Article 25 This contract will come into effect after being signed and sealed by both parties.

Article 26 There are two original copies of this contract, one copy for each party.

Article 27 This contract shall be governed by Chinese law. If any dispute arises between the two parties during the performance of the contract, they shall be resolved through negotiation. If negotiation fails, both parties shall submit the matter to the arbitration committee for arbitration.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): ________Legal representative (signature): _________

< p>_________year____month__________year____month____day

Contracting operation contract sample 4

Contracting party: (Party A )

Contractor: (Party B)

In order to better and more effectively revitalize the assets of our village __ market, fully mobilize the enthusiasm of personnel, and enhance the economic benefits of the market, according to __The actual situation of the market, in accordance with the provisions of the "Contract Law" and other relevant laws and regulations, Party A and Party B signed this contract through consultation and consensus on the basis of voluntariness and equality, in order to abide by ***:

1. __ Market Overview

The market location contracted by Party A to Party B, the market facilities and construction conditions shall be subject to the current situation inspected before participating in the bidding. The stalls in the large iron shed include pork stalls, fish stalls, chilled meat stalls, roast meat stalls, cooked food, salty miscellaneous products, chicken stalls, bare chicken stalls, melon and vegetable stalls, fruit stalls, casual stalls and street stalls, the former supply and marketing cooperative shops, The stalls within the archway, the stalls within the archway, and the night market stalls in front of the rural commercial banks (photo attached) must cooperate with the government when it comes to rectification, and at the same time, the principle is not to affect the smooth flow of the road, otherwise Party A has the right to stop and impose penalties.

2. Contracting Period

Party A will contract the entire __ market to Party B for contract operation. The contracting period is 9 years, starting from the day of the year to the day of the year.

3. Contracting rent, rent payment time and increase in installment rent

1. Because Party A has signed a lease term for the shop before contracting, part of which has not yet expired. Therefore, the contract rent for the first and second phases is calculated based on the winning bid price of RMB 10,000. After negotiation between Party A and Party B, the contract period is 9 years. The first phase of the contract rent is RMB 10,000 (in capital letters: ), and the time is from year, month, day to year, month, day; the second phase of the rental is also RMB 10,000. Yuan (in capital letters: ), the time is from year, month, day to year, month and day; starting from the third period, the contracted rent will increase by 5% per year based on the winning bid price, that is, the contracted rent is RMB 10,000 yuan (in capital letters:) and the time is from year, month and day. Until the year, month and day. The contract rent is paid on a monthly basis, and the monthly rent is paid based on the principle of paying rent first and then using it. Party B needs to pay the rent of the month before the 5th of each month. Party A will issue a payment invoice, and the invoice taxes will be borne by Party B. Responsible.

2. After Party B takes over, Party A can sign a new contract with the stall renter only after the original contract between Party A and the stall user expires. Party B must abide by national regulations and lease contracts, etc. Operate independently and maintain market stability.

IV. Payment of contract deposit

On the day when Party B signs this contract, the deposit of RMB 10,000 (in capital letters: ) paid during bidding will be converted into contract deposit. After the contract expires, if Party B does not commit any breach of contract or does not renew the contract, Party A will return the above deposit to Party B without interest within one month.

5. After signing this contract, Party A and Party B shall complete the market handover procedures before the year, month, and year. The original lessees in the market need to maintain the status quo during the contract period. When Party B rents out the market stalls after the expiration of the lessee's contract, the original lessees shall have priority in leasing under the same conditions.

6. After Party A’s original contract with the stall renter expires, Party B can sign a new rental contract with the stall renter. The deposit amount should be three times the monthly rent of the stall, and The deposit is temporarily collected and managed by Party A. The purpose is to prevent Party B from abandoning the site after collecting the deposit, which will cause Party A to be unable to operate and suffer losses (for example, after Party B takes over, it does not mean that the original rental contract has not yet arrived. Party B shall be responsible for all disputes and consequences arising from cancellation or re-signing within the contract period).

7. From the date of handover, the __ market will be operated and managed by Party B, and various risks and expenses arising therefrom (such as market management personnel wages, taxes, invoice taxes, management fees and national fees, etc.) shall be borne by Party B himself.

8. Party B must strictly refer to the requirements of relevant government departments for the business order and health management of this market. If Party B causes market chaos due to poor management, it will be deemed as a breach of contract by Party B. Party A has the right to terminate this contract, confiscate the deposit and hold Party B responsible for breach of contract.

9. Party B must manage the market order and must not affect the traffic order. Party A has the right to order Party B to remove any temporary items that have been randomly built in the market.

If Party B believes that the market needs to be transformed or rectified, it must obtain the consent of Party A and submit the relevant transformation or rectification plan to Party A (the cost of transformation or rectification shall be borne by Party B). Otherwise, Party A has the right to require Party B to clear it. The renovation and rectification parts shall not be dismantled after the expiration of the contract and shall belong to Party A free of charge.

10. The term of the contract signed by Party B and the market stall operator shall not exceed the deadline of this contract, and the original stall type distribution pattern shall not be changed. If any change is required, a change plan must be provided to Party A and Obtain Party A's written consent, otherwise it will be deemed as Party B's breach of contract.

11. During the contract period, if the government department expropriates the market, the compensation for the original building facilities and land of the __ market will belong to Party A, and the compensation for the facilities invested and built by Party B will belong to Party B. From the expiration date of the contract, all buildings and facilities in the __ market (including various buildings and facilities invested and constructed by Party B) will be owned by Party A.

12. Party A’s rights and obligations

1. Party A has the responsibility to supervise Party B’s management and, together with relevant departments, has the right to conduct unified management of the market in accordance with relevant management regulations. Party B must actively cooperate with the assessment;

2. In daily management, Party A has the right to send staff to inspect the __ market and propose rectification suggestions. Party B must actively implement the rectifications according to Party A's requirements measure.

13. Rights and Obligations of Party B

1. Party B guarantees that the __ market will be used to operate the farmers’ market and ensure the orderly operation of the market.

2. Party B should actively cooperate with the management of the village committee and relevant departments, and be responsible for investing in the purchase of various supplies such as market fire safety.

3. Party B shall be responsible for the repair and maintenance costs of various market facilities, as well as the funds for the normal operation of the market. Party B is responsible for the safety of water, electricity, fire prevention, etc. in this market. The electricity used in the market must comply with the electricity safety regulations. During the lease period, Party B must purchase property insurance worth RMB 10,000 for this market, and the beneficiary must be Party A, as well as personal accident insurance for market staff.

4. Without the consent of Party A, Party B shall not subcontract the market to others, otherwise Party A has the right to unilaterally terminate the contract and confiscate the contract deposit paid by Party B.

14. Liability for breach of contract

Party B must pay the rent in full according to the time limit stipulated in the contract. If the rent is delayed, Party B shall pay Party A RMB (in capital letters) for each day of delay. :) Late payment fee; if Party B delays rent payment for more than 30 days, Party A has the right to unilaterally terminate the contract, confiscate the contract deposit paid by Party B and hold Party B liable for breach of contract.

15. For matters not covered in this contract, Party A and Party B shall negotiate and supplement them separately. The supplementary agreement shall have the same legal effect as the original contract.

16. This contract is made in two copies, with Party A and Party B each holding one copy. It will take effect from the date of signature and seal by both parties, and both parties have the same legal effect.

17. After the contract period of this market expires, if the original contractor intends to continue the lease, he shall submit his opinions to Party A three months before the expiration, and at the same time, both parties A and B shall negotiate and agree on the contract terms. price and re-sign the rental contract.

Party A (seal): Signature of Party B:

Address:

Signature of legal representative:

Sample contract and operation contract 5

Party A:

Party B:

After friendly negotiation, both parties A and B now outsource the operation rights to Party B for operation within the term of this contract. , when entering into this contract, both parties shall jointly abide by it and strictly implement it. The specific contract terms are as follows:

Article 1 Basic Information

1.1 Party A agrees to hand over the location to Party B for contract operation and use.

1.2 After Party B contracts, Party B will be responsible for operation and management.

1.3 The contracting period is

Article 2 Contracting Form and Payment of Amount and Security Deposit

2.1 Contracting Form: Party B will hand over the contracting amount on a lump sum, and any excess will be Keep.

2.2 Both Party A and Party B agree that Party B shall pay the contracting fee to Party A in one installment every year, that is, the contracting fee shall be paid in full in the third month of each installment in RMB. All profits exceeding the quota will be retained by Party B.

2.3 In the financial computer of the club, 150,000 yuan of consumer cards will be pre-sold before February 15, 20__. When Party B's contract period expires, Party A still accepts 150,000 yuan. Party B will give the excess to Party A, and Party A will supply Party B with the excess.

Article 3 Bearing of Credits and Debts

3.1 Debts incurred before Party B underwrites the contract shall be borne by Party A.

3.2 During the contract operation period, Party B shall conduct independent accounting and pay taxes in accordance with the law. Party B shall operate independently and shall be responsible for its own profits and losses. After contracting, we will bear all the water, electricity, gas, property management fees, rent and other related expenses incurred in the operation.

3.3 During the contract operation period, Party B must engage in business activities within the company’s legal business scope (subject to the company’s legal person business license).

3.4 Party B shall be responsible for all personal injuries, property losses, and business violations that occur during the contract period. Party A assumes no responsibility and has nothing to do with Party A.

Article 4 Rights and Obligations of Party A

4.1 The Party A has the right to safeguard the legitimate rights and interests of employees in accordance with national laws, regulations and the provisions of this contract.

4.2 Both parties shall not violate the provisions of this contract and interfere with Party B’s operational autonomy.

4.3 All terms in this contract that should be performed by Party A must be fully fulfilled, and Party B’s legitimate rights and interests shall be protected in accordance with the provisions of this contract

Article 5 Rights and Obligations of Party B

5.1 Party B is responsible for all-round legal operations, is responsible for its own profits and losses, and pays Party A the dues on time.

5.2 Party B is responsible for the annual inspection and maintenance of water, electricity, gas and facilities and equipment used within the business scope, as well as all other related expenses.

5.3 Party B is responsible for the operation and staffing management of the club, and is fully responsible for the personal safety, fire protection, sanitation, taxation and other matters of all relevant personnel in the operation.

5.4 During the contract operation period, Party B shall not hand it over to others for operation in other ways. Except with the written consent of Party A.

Article 6 Commitments of both parties

6.1 Party A shall not participate in or interfere with Party B’s operation and management after Party B obtains the contract management right.

6.2 During the contracting operation, the expenses, claims and debts incurred by Party B in conducting external business activities have nothing to do with Party A.

Article 7 Liability for breach of contract

7.1 If Party B fails to hand over the contracting fee within the time specified in this contract, Party B shall pay a late payment fee of 1% of the unpaid amount to Party A every day. One month later, Party B still has not paid off the debt