(This article provides you with two contract templates)

Part 1:

Contract issuing party: (hereinafter referred to as "Party A")

< p> Contractor: (hereinafter referred to as "Party B")

According to the provisions of the "Contract Law of the People's Republic of China" and relevant laws and regulations, Party A and Party B shall enter into an agreement on an equal basis, voluntarily, and by consensus through consultation. On the basis of this, in order to ensure the smooth progress of the project and in combination with the specific conditions of the project, this contract (including the attachments to this contract and all supplementary contracts) was signed through friendly negotiation to ensure mutual compliance.

Article 1 Project Overview

1.1 Project Name: .

1.2 Project location: .

1.3 Project content and practices (see: "Project Budget Quotation Form" and "Construction Drawings" for details).

1.4 Project contracting method: Both parties agree to adopt the following ______ contracting method.

(1) Party B shall contract the work and materials.

(2) Party B contracts the work and part of the materials, and Party A provides some materials (for details, please refer to the "Details of Decoration and Decoration Materials Provided by Party A" and "Details of Decoration and Decoration Materials Provided by Party B");

(3) Party B will contract the work and Party A will contract the materials (see the "Details of Decoration Materials Provided by Party A" for details).

1.5 The project period is __ ___ calendar days, the start date is ______ year, month and day, and the completion date is _______ year and month _____ (the construction period will be based on the date of material entry). counting from days).

1.6 Contract price: Please refer to the "Project Budget Quotation Form" for details of the project cost of this contract. If there are any additions or reductions during the construction process, both parties shall negotiate, agree and sign to confirm the increase or decrease of this part of the cost.

Article 2 Construction Drawings

Both parties agree that the construction drawings shall be provided in the following _______ method:

(1) Party A will design and provide the construction by itself Drawings, the drawings are in duplicate, Party A and Party B each have one copy (see: Decoration and Renovation Engineering Design Drawings);

(2) Party A entrusts Party B to design construction drawings, the drawings are in duplicate, and Party A , Party B each has one copy (see: Decoration and Renovation Project Design Drawings for details), and the design fee is __________ yuan, which shall be paid by Party A (this fee is not included in the project price).

Article 3 Obligations of Party A

3.1 ______ days before the start of construction, create conditions for Party B to enter the construction. Including: clearing out indoor furniture and furnishings or stacking and covering indoor furniture and furnishings that are difficult to move, so as not to affect the construction; if Party A fails to take necessary protective measures and causes loss of furniture or furnishings, Party A shall Responsible.

/p>

3.4 Responsible for coordinating the relationship between Party B and the neighbors and the property management office;

3.5 Do not dismantle the indoor load-bearing structure. If it is necessary to dismantle the non-load-bearing structure or equipment of the original building, pipelines, and is responsible for going to the relevant departments to go through the corresponding approval procedures;

3.6 During the construction period, Party A still needs to partially use the site and is responsible for the security and fire protection of the construction site;

< p>3.7 Participate in the inspection and supervision of project quality and construction progress, handle acceptance, change registration procedures and other matters, and be responsible for material arrival and completion acceptance.

3.8 Provide self-purchased materials used for construction on time, quality and quantity.

Article 4 Party B’s Obligations

4.1 Party B is assigned as the construction site supervisor to be responsible for the performance of this contract; organize construction as required, ensure quality and quantity, complete construction tasks on schedule, and deal with them by Party B Responsible for all matters.

4.2 Strictly implement safe and civilized construction operating specifications, fire safety regulations, construction specifications and quality standards during construction, and complete the project on schedule and with high quality;

4.3 Strictly implement relevant construction site management regulations, strictly implement Carry out safe and civilized construction according to the drawings or instructions, and make various quality inspections and construction records;

4.4 Protect the furniture and furnishings in the original place and ensure the smooth flow of indoor water and sewer pipes;

4.5 Ensure the cleanliness of the construction site and be responsible for cleaning the construction site after the completion of the project.

4.6 Before the project is completed and handed over to Party A, Party A is responsible for protecting all on-site facilities and finished project products.

Article 5 Project Changes

If the project and construction methods need to be changed, both parties should reach an agreement and sign for confirmation. At the same time, the relevant project costs and construction periods will be adjusted (see the addition of decoration projects). item reduction list).

Article 6 Provision of Materials

6.1 The materials and equipment provided by Party A (see the detailed list of decoration materials provided by Party A) shall comply with the facility requirements. Party A will be responsible for project losses caused by problems or differences in specifications. Party A shall notify Party B before the materials are transported to the construction site, and both parties must agree to accept them and go through the handover procedures; Party B shall be responsible for keeping them properly after acceptance.

6.2 For materials and equipment provided by Party B (for details, please refer to the detailed list of decoration materials provided by Party B), Party B shall notify Party A before the materials are transported to the construction site and accept Party A's inspection. If the quality does not meet the requirements or the specifications are different, use should be prohibited; if it has been used and causes losses to the project, Party B will be responsible.

Article 7 Construction Period Delay

7.1 If the completion date is delayed due to the following reasons, upon Party A’s confirmation, the construction period will be postponed accordingly;

(1) Changes in project volume and design changes;

(2) Force majeure;

(3) Other circumstances in which Party A agrees to postpone the construction period.

7.2 If the construction period is affected because Party A fails to complete the work it is responsible for as agreed, the construction period will be postponed; if the quality of the project is affected because the materials and equipment provided by Party A are not up to standard, the rework costs will be borne by Party A Responsible, the construction period will be postponed.

7.3 If Party A fails to pay the project payment on time, the contract period will be postponed accordingly.

7.4 If the construction period cannot be started on schedule or is stopped midway due to Party B's responsibility, the construction period will not be postponed; if there are problems with the project quality due to Party B's fault, the rework costs will be borne by Party B and the construction period will not be postponed.

Article 8 Payment Method for Project Payment

8.1 After the contract comes into effect, Party A shall pay the project payment directly to Party B in accordance with the provisions of the regulations:

First Times: When signing this contract, Party A pays % of the total amount determined in Party B's quotation (including the total project payment and the amount of additional projects), that is, yuan.

The second time: the carpenters enter the site, and Party A pays % of the total amount determined in Party B's quotation (including the total project payment and the additional project amount), that is, yuan.

The third time: Fanhui Paint comes into the site, Party A pays % of the total amount determined in Party B’s quotation (including the total project payment and the amount of additional projects), that is, yuan.

The fourth time: After the project is completed and completed and accepted, and the settlement is completed, Party A shall pay 5% of the total amount determined in Party B's quotation (including the total project payment and the amount of additional projects), that is, yuan.

8.2 After the project acceptance is passed, Party B shall propose project settlement to Party A and send relevant information to Party A. If Party A has no objection within days after receiving the information, it will be deemed as agreement. Both parties should fill in the project settlement form and sign it. Party A should settle the final payment of the project to Party B when signing.

8.3 After the project payment is fully settled, Party B shall issue a formal unified receipt to Party A. The project payment paid by Party A shall be subject to the receipt issued by Party B's Finance Department and stamped with a special financial seal.

8.4 After the project is accepted and accepted, the warranty period is 12 months from the date of signature by both parties

Article 9 Responsibilities of both parties and handling of delays in construction period

9.1 Below If the construction period is delayed due to Party A's reasons, Party A will be responsible for the loss, and the construction period shall be postponed:

(1) Water and electricity cannot be provided;

(2) More than 8 hours of work per day cannot be guaranteed. time (including overtime);

(3) Failure to provide self-purchased materials and equipment on time;

(4) Failure to pay project fees on time, affecting normal construction;

< p>　(5) The design is changed and construction items are added due to Party A's reasons;

(6) Other circumstances in which the construction period is agreed to be postponed.

(7) Overdue acceptance or unreasonable delay in acceptance;

(8) Other situations that cause delays in the construction period due to Party A’s responsibility.

9.2 If the construction period is delayed due to the following reasons, the construction period will not be postponed:

(1) If the construction period cannot be started on time due to Party B's responsibility or the construction period is stopped without reason, the construction period will not be postponed;

p>

(2) The rework costs for project quality problems caused by Party B will be borne by Party B, and the construction period will not be postponed.

(3) If Party B violates the safety operating regulations and causes personal injury during the construction process, Party B shall be responsible for it;

(4) Party B’s construction causes damage to Party A’s items, Party B shall repair or repair them or Compensation;

(5) Party B shall be responsible for any losses caused by Party B’s violation of property management regulations.

(6) If the quality of the project fails to meet the quality standards agreed by both parties due to Party B's reasons, Party B will be responsible for repairs and the construction period will not be extended.

9.3 If any party in the contract suffers losses due to failure to perform the contract or performance inconsistent with the contract, the responsible party shall bear the responsibility and compensate for the economic losses caused to the other party.

9.4 If Party A uses the finished product in advance or uses it without authorization without completing the acceptance procedures, Party A will be responsible for any losses.

9.5 When the contract cannot continue to be performed due to one party’s reasons, the party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

9.6 If Party A fails to pay the project payment on time, it shall pay liquidated damages of _______ yuan to the other party for each day of delay.

9.5 If the construction period is delayed due to Party B’s reasons, liquidated damages of _______ yuan shall be paid to the other party for each day of delay.

Article 10 Agreement on Design, Construction and Acceptance

10.1 The construction drawings completed by Party B’s designer must be reviewed with Party A within the agreed time and confirmed by Party A After signing, Party B can proceed with construction.

10.2 Party B must carry out construction (installation) strictly in accordance with the drawings approved by Party A.

10.3 During the construction process, if Party A proposes to change the drawings, stop construction, or add or remove items, it shall notify Party B in writing, stating the reasons for stopping construction or adding or removing items, project location, time, materials, etc. . According to the change requirements, Party B shall submit to Party A as soon as possible a list of the measures taken for the change, the increased or decreased costs, construction delays, material losses, and cost losses caused by work stoppages and other reasons, and report to Party A. Party A will make a signed reply or negotiate a settlement within two days after receiving the report.

10.4 Before acceptance of the concealed project, Party B shall notify Party A to come to the site for acceptance. The acceptance period is two days. If Party A fails to accept on time, Party B can truthfully fill in the hidden records after self-inspection. Party A shall recognize the results of Party B's self-inspection.

10.5 After the project is completed, Party B shall notify Party A for acceptance. Party A shall inspect and accept the goods within days after receiving the notice and go through the acceptance and handover procedures. If Party A fails to accept the goods within the above specified time, Party A shall promptly notify Party B in writing and set another date for acceptance, otherwise Party A shall be deemed to have passed the inspection. If another acceptance date is set, Party A shall acknowledge the completion date and bear Party B's care fees and related expenses.

10.6 Party A is not allowed to move in if both parties have not completed the acceptance procedures. If Party A moves in without authorization, it will be deemed that the acceptance has been passed, and the resulting losses will be borne by Party A.

Article 11 The "Project Budget Quotation Form", "Construction Drawings" and other documents agreed upon and signed by both parties shall be attached to the contract and have the same legal effect as the contract.

Article 12 Resolution of Contract Disputes

Disputes arising during the performance of this contract shall be resolved through negotiation between the parties; it may also be mediated by the Dongguan Decoration Association; negotiation or mediation If it fails, you can file a lawsuit with the People's Court in accordance with the law.

Article 13 Supplementary Provisions

13.1 If there are any unsatisfied matters in this contract, the two parties shall negotiate and resolve them in accordance with the principle of friendship and mutual benefit. If a supplementary agreement is signed after negotiation, the supplementary agreement shall be consistent with this contract. have the same legal effect.

13.2 After the signing of this contract, the project shall not be subcontracted.

13.3 This contract is made in _two___ copies, each party holds _one___ copy. The contract will officially come into effect after being signed by both parties and stamped with the official seal or contract seal, and will be automatically terminated after the performance is completed.

13.4 The contract attachments are an integral part of this contract and have the same legal effect as this contract.

Party A: _________ ___ (signature) Party B: Dongguan Decoration Engineering Co., Ltd. (seal)

Legal agent: Legal agent: _____________

Authorization Agent:_____________ Authorized agent:_____________

Address: Address: Zhen Road, Dongguan City

Tel: Tel: 0769-8

Chapter 2:

Project name: _________________________________________

Project number: _________________________________________

Contract number: _________________________________________

Commissioning unit (A Party): ____________________________

Design unit (Party B): ____________________________

Beijing Urban and Rural Planning Commission supervised by Beijing Administration for Industry and Commerce

Fill in the contract instructions

p>

1. All units undertaking construction project design tasks in the Beijing area shall use this contract uniformly;

2. When filling out this contract, you must use block letters, the handwriting must be neat and clear, and the filled-in content must be accurate and complete. ;

3. Attachment 3 "Entrusted Design Project Form" in this contract shall be filled in by the design unit according to the list of project characteristics and attached to the contract. Both parties shall affix the contract seal and seal seal;

4. This contract is not applicable to foreign investment, Sino-foreign joint ventures, and Sino-foreign cooperative design projects;

5. This contract will be unified by the Beijing Survey and Design Management Office with unit numbers;

6. This contract is formulated by the Beijing Municipal Urban and Rural Planning Commission and supervised by the Beijing Municipal Administration for Industry and Commerce. No unit may reproduce it on its own.

Commissioning unit: ____________________________ (hereinafter referred to as Party A)

Design unit: ____________________________ (hereinafter referred to as Party B)

According to the "People's Republic of China and the National Economy "Contract Law", "Construction Engineering Survey and Design Contract Regulations", and relevant regulations of Beijing City. After negotiation between both parties, this contract is signed and will be performed jointly.

Article 1 Engineering Project

Party A entrusts Party B to undertake the following engineering design tasks:

Project name: _______________________________

Project address: _______________________

Project task approval document: ____________________________ (see attachment 1);

Beijing Urban Planning Management Department approval document: ____________ (see attachment 2);

The design stage, content, scale and project investment of this project (see Appendix 3).

Article 2: Submission of design information, design stages and design documents

This project design is carried out in two stages: preliminary design and construction drawing design. The design progress is in accordance with the design cycle stipulated by the Ministry of Construction, and taking into account Party A's actual requirements for the project and Party B's possibilities, after mutual consultation between Party A and Party B, the agreement is as follows:

(1) Party A The following construction documents and design information shall be submitted in writing: Serial number document content or name document submission date remarks

(2) Party B shall submit the following design documents according to the agreed time: Serial number design document name number copies delivery date remarks The number of copies of design documents submitted shall be subject to the regulations of the National Price Bureau and the Ministry of Construction. Any excess copies will be charged separately. (3) If the design document submission date cannot be determined when the two parties sign the contract, it can be determined when the design work is in progress. Party A and Party B will separately sign a "Phase Design Agreement" as an attachment to this contract.

Article 3 Design Charges and Payment Methods

(1) The design charges for this project shall be in accordance with the current national and Beijing charging standards. If Party A requires the design unit to provide design drawings in a hurry beyond the specified design period, the design unit may charge a rush fee of no more than one-third of the design fee. The specific amount shall be agreed upon by Party A and Party B.

(2) Please see Appendix 3 "Entrusted Design Project List" for details of the design charges for this project. When this contract takes effect, Party A prepays 20% of the total estimated design fee to Party B as a contract deposit. After the design work is completed, the deposit will be used as the engineering design fee.

(3) When Party B submits preliminary design documents to Party A, Party A shall allocate 30% of the total design fee payable to Party B (excluding deposit).

(4) When Party B submits construction drawing design documents to Party A, Party A shall settle all engineering design fees according to the design estimate to Party B.

(5) For designs that use advanced technology to save investment, shorten the construction period, or have significant economic benefits after completion, after confirmation by the Beijing Urban and Rural Planning Commission in conjunction with relevant departments, the engineering design fee may be appropriately increased. The amount of increased income shall be implemented in accordance with the relevant standards of Beijing Municipality. If the specific standard is not determined, it shall be negotiated by Party A and Party B.

(6) During the execution of this contract, if the design fee standards stipulated by the state are adjusted, the design fee amounts determined by Party A and Party B shall be re-assessed according to the new standards, and the design fee amounts after approval shall be proceed to checkout.

Article 4 Responsibilities of both parties

(1) Responsibilities of Party A

1. Submit relevant construction documents and design information stipulated in this contract to Party B as scheduled, and Ensure that the quality of submitted materials meets the engineering design requirements.

2. Pay the deposit and engineering design fee to Party B according to the agreed date and quantity.

3. Responsible for submitting the design documents of each stage of the project to the planning and design management department for review and approval, and responsible for formally notifying Party B of the approval results in writing.

4. When Party A requires Party B to conduct on-site design or dispatch on-site design representatives, it shall formally issue an invitation letter to Party B and be responsible for Party B’s necessary working conditions. The required expenses shall be borne by Party A and shall not be included in the calculation. of the total engineering design fee.

5. If the processing and ordering of building materials and equipment for this project requires the cooperation of Party B’s designers, Party A will bear the required costs.

6. Without increasing the total engineering design fee, Party A is responsible for assisting Party B in handling the new technologies, new materials and other items used in the engineering design that should be handled by Party A in the technical contract. related procedures. The technology contract can be used as a contract attachment to this contract and has the same effect as this contract.

(2) Party B’s Responsibilities

1. Pay Party A the design documents stipulated in this contract as scheduled, and ensure that the quality of the design documents complies with relevant national and Beijing regulations and standards. requirements and comply with Party A’s construction and use requirements.

2. Responsible for the design briefing before the start of the engineering design projects listed in this contract. Responsible for timely resolution of design-related technical issues during the construction of the project. Participate in the acceptance of the foundation, main structure and completion of the project as required.

Article 5 Engineering Design Copyright

The design copyright of this project belongs to Party B, and Party A is responsible for protecting it. The design shape, design documents, and and relevant data may be modified, copied, depicted or provided to third parties for use, nor shall they be used for the construction of other projects that are not part of this project.

Article 6 Liability for Breach of Contract

(1) Due to Party A’s changes to the planned mission statement, construction conditions, construction technical conditions, selected design plan, approved preliminary design, When the submitted usage requirements, documents and information cause design rework to Party B, both parties need to renegotiate the date for submitting the documents. Party A shall pay Party B the fee based on the actual rework day, which shall be calculated as _____ yuan per day. If the change leads to redesign, Article 7 of this contract shall be followed, the design fee payable shall be settled, the contractual relationship shall be terminated and the contract shall be re-signed. (2) If Party A fails to pay the engineering design fee within the time stipulated in Article 3 of this contract, Party A will calculate the design fee from the next day when the design fee is payable. For each day of delay, the contract will be re-signed.

(2) If Party A fails to deliver the engineering design fees within the time stipulated in Article 3 of this contract, Party A will pay Party B the amount of engineering design fees payable for each day of delay, calculated from the day after the design fees are payable. _____ of the design fee shall be used to pay liquidated damages.

(3) Due to Party A's violation of Article 5 of this contract, Party B has the right to demand payment of liquidated damages from Party A. The amount of breach of contract shall be twice the total design fee payable by Party A to Party B. And bear responsibility for violating relevant government regulations and laws. (4) If Party B fails to submit the design documents within the time specified in this contract due to Party B's reasons, Party B shall compensate Party A for economic losses equal to _______ of the design fee during the design stage for each day of delay, calculated from the day after the due date of submission. Liquidated damages. (5) When Party B's design errors cause serious economic losses to Party A, Party B is responsible for continuing to take remedial measures in the design and compensate Party A for part of the actual economic losses incurred as appropriate. The total compensation amount shall not exceed the cost of that part of the project. All design fees.

(6) If Party A fails to perform the contract, Party B will not return the deposit, and Party B will pay an additional design fee based on the actual amount of work completed. If Party B fails to perform the contract, it shall return double the deposit to Party A, and at the same time return all design fees except the deposit collected.

Article 7 Effectiveness, Suspension and Ending of the Contract

(1) This contract must be affixed by Party A and Party B with the official seals of the legal entities, and must have legal representatives of both parties or be represented by legal representatives The signature (or seal) of the authorized agent is required to be valid. The effective date of this contract shall be the date signed (or stamped) by the last party between Party A and Party B.

(2) If Party A and Party B need to change or terminate this design contract for any reason, they shall notify the other party in writing one month in advance, obtain consensus on the remaining issues in this contract, and form a written agreement as an attachment to this contract. This contract will remain in effect until an agreement is reached.

(3) If Party A requires the design work to be stopped midway due to reasons, the deposit paid will not be refunded; when the design work is less than half of the corresponding design stage, Party A shall pay half of the design fee for that stage; design When the work proceeds to more than half of the design stage, Party A shall pay half of the design fee for that stage; when the design work proceeds to more than half of the design stage, Party A shall pay the entire design fee for that stage. At the same time, the contractual relationship between Party A and Party B of this project shall be terminated in accordance with paragraph (2) of this article.

(4) This contract ends on the date when Party B provides Party A with all the engineering design documents stipulated in this contract and Party A pays all the design fees in accordance with the provisions of this contract, unless otherwise stipulated in this contract.

Article 8 Force Majeure

During the execution of this contract, if force majeure occurs and the contract cannot be performed or cannot be fully performed, Party A and Party B can resolve it through negotiation and shall not be affected by this contract. bound by the relevant terms of the contract.

Article 9 Contract Dispute Resolution Methods

If a dispute occurs during the execution of this contract and the parties fail to reach an agreement through negotiation, the following ____ method will be used to resolve it:

< p>　1. Apply to the Beijing Municipal Urban and Rural Planning Commission for mediation;

2. Apply to the Economic Contract Arbitration Committee of the Administration for Industry and Commerce with jurisdiction for arbitration;

3. Apply to the competent authority for arbitration Proceed in the competent people's court;

4. Other solutions: _______________

Matters not covered in Article 10 and additional terms

(1) Not covered in this contract Matters shall be determined through negotiation between Party A and Party B, and a written agreement shall be formed and executed as an attachment to this contract.

(2) The additional terms of this contract are as follows:

____________________________________________________________________________________________ ____________________________________________________________________________________________ ____________________________________________________________________________________________ ____________________________________________________________________________________________ ____________________________________________________________________________________________ ____________________________________________________________________________________________

Article 11 Contract Text

This The contract is officially made in two copies, with Party A and Party B each holding one copy. There are ____ copies, Party A will hold ____ copies, and Party B will hold ____ copies.

Contract signing place: _____________ District (County), Beijing

Construction unit: Design unit:

Legal representative of the unit: ____________________ Legal representative of the unit: ______________

Purchased agent: ______________

Purchased agent: ______________

Purchasing agent: ______________

Purchasing agent: ______________

Purchasing agent: ______________

>

Postal code: ______________ Postal code: ______________

Bank of account: ______________

Bank of account: ______________

Account number: ______________

Year month day year month day