Greening construction contract

Greening construction contract can protect everyone’s interests from being harmed to the greatest extent, but many people have lost the legal constraints of the contract due to errors in the signed content. The power makes one's own interests irreparable. Let's take a look at the greening construction contract. Greening Construction Contract 1

Contractor: ____________ Company (hereinafter referred to as Party A)

Contractor: ______________ (hereinafter referred to as Party B)

In accordance with the "Contract Law of the People's Republic of China", the "Construction Law of the People's Republic of China" and relevant regulations, combined with the specific conditions of this project, and upon consensus reached by both parties, this contract is signed to * **Same compliance.

Article 1 Project Overview

1. Project name: ______________ Project external environmental landscape and ______________ landscape landscaping project;

2. Project location ：___________________;

3. Project contracting scope and content: ______________ garden landscape, ______________ landscape engineering, ______________ landscape engineering (including entrances and exits), greening engineering, garden construction engineering and supporting water and electricity engineering, lighting system, etc. (see construction drawings for details). Party B is responsible for deepening and optimizing the design of the construction drawings of this project. If the construction of this project is contracted by Party B, Party B will provide this service for free; if Party B is not contracted for the construction of this project, Party A will pay the service fee______________ Yuan to Party B.

4. Contracting method: Party B is responsible for labor, materials, machinery, management, quality, construction period, safety, taxes, civilized construction, deepening, and optimized design, etc.

Article 2 Project Period

1. The start date of this project shall be subject to Party A’s commencement notice and confirmed by Party B. The completion date shall be _________year________month _______day.

2. In the event of the following circumstances, upon approval by the on-site supervision engineer or project representative of the contract issuing party, the construction period will be extended accordingly and the extension period shall be determined in writing.

(2) It is clear that the materials, equipment, finished products or semi-finished products that the contracting party is responsible for supplying fail to arrive at the site at the time agreed by both parties, or the materials, equipment, finished products or semi-finished products that enter the site are handed over to the contractor. Those who find stage defects during the inspection and need to repair, modify, replace or replace the construction progress;

(3) Those who are affected by water and power outages during construction for more than _______ hours continuously;

(4) The on-site supervision engineer or engineer representative of the contracting party delays the visa procedures and affects the construction of the next process;

(5) Failure to allocate advance payment, project progress payment, and purchasing agent as stipulated in the contract Those who affect the progress of the construction due to material price differences;

(6) Those who affect the progress of the project due to irresistible natural disasters (such as typhoons, floods, fires caused by natural causes, earthquakes, etc.);

p>

(7) Major design changes occur.

Article 3 Project Contract Cost:

1. The budgeted cost of this project contract is RMB____________ yuan, that is, RMB______hundred______ten______ten thousand_ _____Thousand______ Hundred______ Shi______ Yuan (including tax).

2. Settlement will be based on the actual project quantity in accordance with the standards in Article 8.

Article 4 Supply and inspection of materials and equipment

1. Imported special materials will be supplied to the site or designated location by the contractor. If the delivery is outside the specified delivery location, the contracting party shall be responsible for the over-distance freight and other expenses incurred;

　2. For complete sets of equipment and special equipment, the contracting party shall be responsible for bidding, ordering, supply and The goods are delivered to the contractor after inspection. Equipment that arrives in advance should be stored in a warehouse by the contracting party and delivered to the contractor for safekeeping during installation. It must not be misappropriated, lost or damaged;

3. All materials and equipment, finished products, and semi-finished products should be accompanied by qualified certificates. certificate.

4. If any unqualified materials are found to have entered the site, the supplier must quickly remove them from the site.

5. If the building materials and equipment with certificates of conformity have objections and require inspection, they can be re-inspected. If the products are qualified after inspection, the inspection costs will be borne by the contractor who requested the inspection; For unqualified products, the inspection costs shall be borne by the contractor.

6. The contractor shall not use building materials, equipment, components, etc. that do not have certificates of conformity and have not been tested and identified or have been found to be unqualified by testing.

7. If Party A changes the materials that Party B has ordered or purchased, Party A will bear the losses caused.

Article 5 Project Quality and Inspection and Acceptance

1. The quality requirements of this project are excellent;

2. The contractor must strictly follow the construction drawings and documentation Carry out construction in accordance with the relevant specifications and procedures issued by the state, and accept the supervision and inspection of the on-site supervision engineer or engineer representative of the contract-giving party;

3. The on-site supervision engineer hired by the contract-giving party is ____________;

4. The contractor should provide technical information on project quality in a timely manner according to the progress of the project. For example, materials, equipment certificates, and material substitution must be approved and signed by the design unit and the contracting party before they can be used.

5. After the concealed project is self-inspected by the contractor, the contractor shall fill in the "Concealed Project Acceptance Form" to notify the on-site supervision engineer or engineer representative for inspection and acceptance. The supervising engineer or engineer representative shall go to the site for inspection within 24 hours after receiving the notification. , only after the visa is approved can the next construction process be carried out.

6. The completion acceptance of the project shall be based on the construction drawings, drawing descriptions, technical briefing minutes, design change notices, construction acceptance specifications and quality inspection standards issued by the state.

7. After the project is completed, the contractor shall compile and provide complete technical archives in accordance with regulations and issue a completion notice. The acceptance time will be determined through negotiation between both parties, and the contractor will organize relevant units to conduct completion acceptance. After passing the acceptance inspection, both parties will sign a handover acceptance certificate and hand over the project to the contractor for management.

8. The contractor is responsible for keeping the completed but not accepted projects before delivery.

9. After the project is handed over and accepted, the warranty period for the garden construction project is 1 year, and the warranty period for water and electricity is 2 years. During the warranty period, any damage caused by construction quality will be borne by Party B. The maintenance of the greening project will be current. For 6 months, the maintenance water fee will be borne by the contractor. For project quality problems caused by construction, the contractor shall notify the contractor in writing and agree on a time for repairs. The contractor shall make repairs within seven working days.

Article 6 Changes in Construction Design

1. The design drawings, instructions and relevant technical data delivered by the contractor are the valid basis for the construction and the contractor shall not modify them without authorization.

2. Major modifications and changes to the construction drawings must be approved by the contractor and the design unit, and a design modification agreement must be processed ______ days before the modification. The contractor will not implement the design modification agreement until it has been signed by the contract-issuing party. The agreed order and revised drawings are supplementary documents to the contract.

3. When the modified drawings are due to design errors, equipment changes, structural changes, standard improvements, process changes, or geological conditions that are inconsistent with the design, the additional costs (including rework losses, shutdowns, delays, personnel and actual losses due to the relocation of machinery and equipment, the backlog of materials and components) shall be the responsibility of the responsible party and the contract price shall be adjusted.

4. On the premise of ensuring the quality of the project and not lowering the design standards, the contractor puts forward reasonable suggestions for modifying the design, which will be implemented after being approved by the contractor, the design unit or the relevant technical department;

5. When one of the following facts occurs during project construction, the contractor must immediately notify the contracting party in writing and request confirmation;

(1) The design drawings and documentation are inconsistent with the project site conditions, and the design documents are inconsistent with the project site conditions. The marked construction conditions are inconsistent with the actual conditions;

(2) The design drawings and design documents are unclear or contain errors and omissions, and the drawings are inconsistent with the instructions;

(3) Design drawings and unexpected special difficulties occurred due to construction conditions not specified in the documentation.

(4) The confirmed facts must be resolved within 2 days. If the problem cannot be resolved as scheduled and the work is stopped, the loss during the construction period will be borne by the contractor.

Article 7 Matters that both parties are responsible for

1. Contract issuing party

(1) Handle land acquisition, compensation for young crops and trees, relocation of cemeteries, house demolition, Remove obstacles (including overhead and concealed), and provide relevant concealment and obstacle information;

(2) Make "three connections" before starting construction; design or construct the plan according to the approved construction organization , provide water and power connection points within the red line diagram no more than ______ meters away from the building, and install water and electricity meters so that the contractor can bill according to the meter;

(3) According to the construction area Water supply, power supply, water pressure, and voltage conditions, and take measures to meet the needs of construction water and electricity;

(4) Provide construction sites as required;

(5) After the contract is signed Provide the contractor with a complete ______ set of construction technical information within ______ days (subject to the last drawing received);

(6) Determine the roads, lines, and Positioning stakes, leveling points and coordinate control points for water supply and sewerage;

(7) Organize the presentation of construction drawings with the participation of both contractors and the design unit, and prepare the presentation minutes signed by the three parties, and submit them in ______ Distribute it to relevant units within days;

(8) Review the contractor's project schedule and pay the contractor timely progress payments;

(9) Supervisory engineers or engineers stationed at the construction site Representative, supervises and inspects project progress, project quality, hidden projects and contract execution, is responsible for handling design drawing issues, design change visas, project intermediate acceptance, project progress payment appropriation visas and other necessary visas.

(10) Organize the completion acceptance of the project, and cooperate with the contractor to complete the completion settlement work according to the date specified in the contract.

2. Contractor

(1) Leveling of the construction site, construction of water, electricity, roads and temporary facilities within the construction boundary;

(2) Prepare the construction organization design (or construction plan), overall construction progress plan, site entry plan for materials, equipment and finished and semi-finished products, water and electricity plan, completion notice, concealed project acceptance form, etc., and send them to the contractor and related parties in a timely manner Unit;

(3) Procurement, supply and management of materials and equipment according to the scope of division of labor agreed upon by both parties;

(4) Carry out construction in strict accordance with the construction drawings and instructions, Ensure the quality of the project and complete and deliver it as scheduled according to the time specified in the contract;

(5) Responsible for safekeeping and cleaning up the site before delivery;

(6) Provide completion acceptance technology Information, handle project completion settlement, and participate in completion acceptance;

(7) During the warranty period stipulated in the contract, the contractor will be responsible for free repairs for work quality problems that are the responsibility of the contractor.

Article 8 Payment and Settlement of Project Price

1. Within ten working days after signing the contract, ______% of the total project contract price shall be paid;

　2. When Party B completes ______ of the contract project quantity, Party A shall pay a progress payment of ______% of the total contract price within ten working days after receiving Party B’s project payment application report;

3. After the project is completed, Party A will pay a progress payment of ______% of the total contract price within ten working days after receiving Party B’s project payment application report;

4. After the project is accepted, Party A will Complete the review of project settlement within thirty days after receiving Party B's settlement letter. ______% of the total settlement price shall be paid within seven days after the settlement of the project; a balance of 5% of the settlement price shall be retained, and shall be paid to the contractor in one lump sum within ______ days after the individual warranty period of the garden construction project and greening project expires.

5. If the contracting party is in arrears with the project progress payment or final payment, it shall be handled in accordance with the bank's relevant regulations on overdue payment methods.

6. If the progress of the project is indeed affected due to the contract-issuing party's default in project payment or the difference in purchase of materials, resulting in the contractor's stoppage or delay in work, the contract-issuing party shall bear the responsibility.

Perform calculations;

7.2 The project costs of garden construction and landscaping projects shall be calculated based on the 2003 "Guangdong Province Comprehensive Quotas for Landscape Building and Greening Projects";

7.3 The installation project project fee is calculated based on the 2002 "Guangdong Province Installation Project Comprehensive Quota";

7.4 The settlement cost of garden buildings and greening projects is based on___________ _The "2003 Landscape Project Fixed Pricing Procedure Table" issued by the Construction Project Cost Management Station on July 12, 2003 will be calculated with a 5% reduction in the total price after calculation; the settlement cost of water and electricity installation projects shall be based on ____________ Construction Project Cost Management According to the "2003 Installation Project Fixed Pricing Procedure Table" issued by the station on July 12, 2003, the total price will be reduced by 5% after calculation;

7.5 Garden construction and greening projects and installation projects The price of main materials shall comply with the July 2004 "xxx Construction Engineering, Installation Engineering, Landscaping Engineering Materials, Seedlings Price List" issued by the Dongguan Construction Committee. The contracting party may specify the brand, manufacturer, origin and price of some materials and seedlings;

7.6 The materials or prices specified by the outsourcing party will be included in the independent fee during settlement, and the price will not be reduced according to Article 8, Section 7.4 of this contract.

Article 9 Liability for breach of contract

1. Responsibilities of the contractor

(1) If the quality of the project does not meet the provisions of the contract, it will be responsible for free repair or rework.

(2) If the project delivery time does not meet the regulations, Party B shall pay Party A RMB ____________ yuan as overdue liquidated damages for each day overdue.

2. Responsibilities of the contracting party

(1) Failure to perform its responsibilities in accordance with the provisions of the contract, the completion date will be postponed.

(2) If the project is not inspected and accepted, and the contract-issuing party uses it in advance or uses it without authorization, the contract-issuing party shall be responsible for any quality or other problems arising therefrom.

Article 10 Dispute Resolution

If any dispute arises during the execution of the contract, both parties will resolve it through consultation in a timely manner. If negotiation fails, any party may directly file a lawsuit with the People's Court of ____________.

Article 11 Special Terms

If there are any unsatisfied matters under the terms of this contract for special circumstances, both parties may negotiate special terms based on the specific circumstances and in conjunction with relevant provisions

Article 12 Supplementary Provisions

All other matters not stated in this contract shall be governed by the Contract Law of the People's Republic of China and relevant regulations.

Contract attachments: all construction drawings. The above attachments are an integral part of this contract and have the same legal effect.

This contract will come into effect after being signed and sealed by both parties. The entire contract project will be completed and handed over for inspection, and the final payment for the project will be settled. The warranty will naturally expire after the expiration of the warranty period.

There are 2 original copies of this contract, including 1 copy held by the issuing party and 1 copy held by the contractor. There are 2 copies, 1 copy held by the issuing party and 1 copy held by the contractor.

Contractor (seal) ____________________ Contractor (seal) ____________

Legal representative (signature): ____________ Legal representative (signature): ____________

Authorized representative (signature): ____________ Authorized representative (signature): ____________

Signing date: ______year______month____Signing date: ______year______month___ _Japanese Greening Construction Contract 2

Party A entrusts Party B to implement the greening project. In order to clarify the responsibilities, obligations and rights of Party A and Party B of this project, ensure quality and quantity, and complete the project construction tasks on schedule. After consensus reached between Party A and Party B, the following contract terms are signed:

Article 1: Project location and name:

1. Project location:.

2. Project name: Greening project on both sides of the east section of the national highway.

Article 2: The following documents shall be considered an integral part of this contract. Namely:

1. Other agreements signed by Party A and Party B during the implementation of the contract.

2. Drawings and bill of quantities: based on the greening design plan and bill of quantities provided by Party A.

3. The negotiation, changes and written agreements or documents between the two parties regarding the project shall be regarded as an integral part of this contract.

Article 3: Contracting method:

1. Contract content: greening construction.

2. Contracting method: contracting work, materials, quality, construction period, maintenance, survival rate, and safety.

3. Project cost: The contract is signed based on the winning bid price (￥ yuan) (attached with a bill of quantities). The unit price of the seedlings is guaranteed at one time. After the completion acceptance is passed, the quantity of the project will be calculated based on the actual quantity.

4. Project changes during the construction process: Adjustments will be made based on the visa of Party A’s representative.

Article 4: Commencement and completion dates of this project: From to

Article 5: Project quality and safety:

1. Construction quality, Inspection and assessment are based on relevant construction technical specifications and quality inspection and assessment standards. Standards, specifications and relevant technical documents: Provincial Construction Committee Document Su Jianyuan (XX) No. 204 "Provincial Technical Regulations for Planting Plants in Urban Landscaping (Trial)" and "Provincial "Technical Regulations on Urban Greening Plant Maintenance (Trial)" and "Unified Standards for Construction Quality of Construction Projects", etc.

2. Party B must carry out construction in strict accordance with the construction drawings, instructions and construction operating specifications to ensure quality and safety.

3. Party B should actively and conscientiously prepare the construction plan, submit it to Party A for review and approval before the start of construction, and Party B will organize and construct the construction plan reviewed and approved to ensure the smooth completion of the project.

4. Design changes must be signed and approved by Party A before they can take effect. Party B should be familiar with the drawings and strictly implement relevant standards.

5. The excavation, loading, unloading, transportation and stacking of seedlings shall be carried out strictly in accordance with the operating specifications.

6. During the planting process, grasp the quality control of pond opening, planting, watering and other work.

Article 6: Requirements for the organization and supply of materials:

1. All seedlings shall be organized and supplied by Party B. The seedlings entered by Party B shall meet the variety, specification, quantity and quality requirements. It can only be used after approval by both parties.

2. The seedlings will arrive quickly according to the construction schedule.

Article 7: Payment of project price:

1. Support for project price: 50% of the total project price will be paid after the project is completed and accepted, and the total project price must be paid before the end of the month. The price is 30, and the total project price must be paid before the end of the year.

2. Settlement of project price: The project price is based on the actual amount of work.

Article 8: Project completion acceptance and defect liability period:

1. Project completion acceptance should be based on construction drawings and instructions.

2. Before the completion of the project, Party B shall organize a self-inspection.

3. Within 10 days after Party A receives Party B’s project completion report, Party A shall organize relevant units to conduct completion acceptance.

Article 9: Supplementary Provisions:

1. This project contract will take effect after it is signed and sealed by Party A and Party B. Upon expiration of the liability period for project defects, all completion and acceptance will be qualified, and the project price will be settled. later failed.

2. During the construction process of Party B, Party A shall provide all construction conveniences, such as: electricity, water, etc., and coordination of local conflicts.

3. Defect liability period: The defect liability period of this contract is one year after completion acceptance.

4. During the defective maintenance period, the contractor shall promptly carry out a series of maintenance management such as cleaning, weeding, fertilizing, pest and disease protection, pruning, watering and moistening, and replanting to ensure that the success rate reaches 98.

5. During the defective maintenance period, if there are incidents such as cars crushing seedlings, personnel intentionally damaging, stealing, etc., all matters shall be resolved by Party A and Party B will assist, and Party A shall pay the expenses in one lump sum.

6. Unfinished matters of this project shall be determined through negotiation between Party A and Party B.

7. This project is made in duplicate. Party A and Party B each hold one copy and one copy.

Party A: Party B:

Party A’s representative: Party B’s representative:

Signing date: Year, month, day Greening Construction Contract 3

Owner (Party A):

Contractor (Party B):

According to the "Contract Law of the People's Republic of China" and relevant national laws, According to the provisions of the regulations, Party A and Party B have reached an agreement through friendly negotiation on the basis of equality, voluntariness, compensation of equal value, fairness and good faith on Party A entrusting Party B to carry out the construction project, and hereby sign this contract in order to abide by it.

Article 1: Project Overview

1. Project Name:

2. Project Location:

3. Scheduled Start Date: Year, month, day

Article 2: Construction scope

1. Construction scope:

Backfill planting soil shall be settled according to the actual amount of work on site, and shall be signed by representatives of both parties Approved, but the unit price is not allowed to exceed the budget unit price limit approved by Party A.

Article 3: Construction methods

1. This project will be constructed by Party B in the form of contracting work and materials.

Article 4: Construction Period

1. The construction period starts from the scheduled start date to the date when Party B completes the construction and passes all acceptances agreed in the contract, estimated days (including legal holidays) , excluding the time Party B waits for Party A’s acceptance after notifying Party A of acceptance.

2. In case of the following circumstances, Party B must notify Party A in writing within 2 days of the visa issue, and obtain a visa from representatives of both parties, and the construction period will be postponed accordingly. Otherwise, Party B will be deemed to have waived the right to obtain a visa, and the project will not be completed. postponed.

(1) The construction progress of the project is affected due to Party A’s reasons, such as failure to hand over the site on time, connect water and electricity, Party A’s design changes, etc.

(2) Force majeure factors.

Article 5: Project Quality and Acceptance Standards

1. The project quality must be up to standard (the acceptance standards shall be implemented in accordance with the owner’s design requirements and industry specifications). The project was not completed due to Party B’s intentional delay. If the settlement can be made on time or submitted for acceptance, the project cannot be assessed as qualified.

2. The quality of the seedlings provided by Party B must be controlled in advance. The seedling specifications must be selected strictly in accordance with the design requirements. The quality of the seedling planting must strictly follow the greening planting specifications.

3. The survival rate of seedlings reaches 100.

4. After the project is completed, Party B shall notify Party A for acceptance. Both parties will inspect the project quality on site and if the quality is qualified, Party A will sign for it.

Article 6: Project Price, Settlement, and Payment Methods

1. The total project budget price is RMB Yuan (uppercase Yuan).

2. Settlement method:

(1) Party A shall prepay 30% of the total project budget price to Party B within one working day before the scheduled start date;

(2) Party A shall pay Party B 30% of the total project budget price within one working day after Party B’s materials and workers arrive at the site and submission of the start-up report;

(3) Both parties shall handle completion acceptance Within three working days after the settlement procedures, Party A shall pay Party B an additional amount of 90% of the total project settlement amount.

(4) 10% of the total project settlement amount will be used as the project quality deposit and maintenance deposit. Party A shall re-inspect the site with Party B within one working day after the expiration of the maintenance period and handle the maintenance termination procedures. According to the contract, the amount shall be settled to Party B after deducting various amounts and liquidated damages that should be paid by Party B during the maintenance period.

(5) The above payment methods are all paid by .

Article 7: Maintenance Period

1. The maintenance period of seedlings is months, starting from the date of completion of the construction of this project and all acceptances agreed in the contract.

2. During the maintenance period, any quality problems caused by Party B’s construction shall be unconditionally maintained within 12 days from the date when Party B receives notification from Party A. If the seedlings are not viable, they shall be replaced in time. Otherwise, Party A has the right to send another construction team for construction and maintenance, and all costs will be deducted from the maintenance fee. Party A has the right to recover from Party B the excess of the maintenance fee.

Article 8: Obligations of both parties

1. Obligations of Party A

(1) Appoint an on-site representative to be responsible for overall management of project construction.

(2) Provide Party B with a construction site, ensure smooth transportation roads, and provide construction water and electricity (water and electricity bills shall be borne by Party B).

(3) Provide construction drawings of this project and be responsible for organizing drawing review and design disclosure.

(4) After receiving the completion settlement statement and complete completion settlement information submitted by Party B, Party A shall notify Party B within two weeks to verify the project price and within two months after completion acceptance Complete settlement.

2. Party B’s obligations

(1) Appoint an on-site representative to be responsible for the overall management of the construction process.

(2) According to the construction drawings confirmed by Party A, the construction work within the contract scope shall be completed in accordance with this contract.

(3) Carry out safe construction in accordance with relevant safety regulations, abide by Party A’s relevant regulations on construction site management, and assume safety responsibilities such as setting fires, preventing theft, and preventing accidents during the construction process. If safety problems arise, Party B shall be solely responsible.

(4) Before the project is delivered to Party A, Party B shall be responsible for the protection of the completed project. If any damage occurs during this period, Party B shall repair it at its own expense and deliver it to Party A as stipulated in the contract. This may cause delays in the construction period. , handled according to the overdue completion clause in the liability for breach of contract.

(5) Party B shall ensure that the quality of the project meets the acceptance standards.

(6) Party B shall submit the completion settlement statement and complete completion settlement information to Party A within two weeks after the completion acceptance of the project, and shall contact Party A within two weeks from the date of receipt of the notice of project price verification from Party A. Party A shall check the project price and complete the settlement within two months after completion acceptance.

Article 9: Liability for breach of contract

1. If the construction period is delayed due to changes in Party A’s project quantities or drawings, the completion date shall be postponed.

2. If Party A fails to conduct completion acceptance as stipulated in this contract, Party A shall bear the project custody and risk responsibilities.

3. If Party A pays overdue, causing the construction to be unable to proceed, Party B may stop the construction.

4. If the project quality fails to meet the agreed standards, Party B shall bear the corresponding responsibilities.

5. During the construction process, Party B shall not stop work for any reason except for force majeure or Party A’s reasons. If work is stopped for more than two consecutive working days for reasons other than those mentioned above, Party A will terminate the contract, causing Party A’s construction period to be delayed. or other losses, Party B shall compensate.

6. The liquidated damages that Party B should pay to Party A shall be deducted from the outstanding payments due by Party A. If the liquidated damages are insufficient to compensate for Party A’s losses, Party A may continue to pursue compensation from Party B.

Article 10: Transfer Terms

Without the written consent of both parties to the contract, neither party may unilaterally transfer all or part of its rights and obligations under this contract. .

Article 11: Termination of the Contract

1. Termination due to rescission

(1) This contract cannot be performed or cannot be fully performed due to Party B’s breach of contract, If Party A believes that it is no longer necessary to continue to perform this contract or Party B still does not correct its breach of contract after receiving a notice from Party A requiring it to correct its breach of contract, Party A has the right to issue a written notice to terminate this contract to Party B, which notice will be effective from It will take effect when delivered to Party B. Party B shall bear liability for breach of contract as stipulated in this contract. If the liquidated damages are insufficient to compensate for Party A's losses, Party A may continue to pursue compensation from Party B.

(2) This contract cannot be performed or cannot be fully performed due to Party A's breach of contract. If Party B believes that it is no longer necessary to continue to perform this contract or Party A still refuses to perform the contract after receiving Party B's notice requiring it to correct the breach of contract. If Party B corrects its breach of contract, Party B shall have the right to issue a written notice of termination of this contract to Party A, which shall take effect when it is delivered to Party A. Party A shall pay Party B the amount of work confirmed by both parties to have been completed, and shall pay Party B the amount of work that both parties have confirmed to have completed, and shall comply with the provisions of this contract. Bear liability for breach of contract.

(3) If one party to the contract exercises the right to terminate in accordance with this contract, the contract shall be terminated from the date of delivery of the notice of termination.

(4) After the contract is terminated, it does not prevent one party from pursuing liability for breach of contract against the breaching party.

2. The rights and obligations of the contract will be terminated if one of the following circumstances occurs:

(1) This contract has been performed as agreed;

(2) This contract Terminate by consensus of all parties;

(3) This contract is terminated due to one party's breach of paragraph 1 of this article (including one party's unauthorized transfer of rights and obligations under this contract), and the other party issues a notice of termination of the contract. Notice;

(4) Other circumstances for termination as stipulated by laws and regulations.

Article 12: Applicable legal provisions

The formation, validity, interpretation, performance and resolution of disputes of this contract shall be governed by the laws of the People's Republic of China.

Article 13: Resolution of Disputes

All disputes arising from the execution of this contract or related to this contract shall be resolved through friendly negotiation by the parties to the contract; if negotiation If the dispute cannot be resolved, either party may bring a lawsuit to a people's court with jurisdiction.

Article 14: Others

1. Matters not covered in this contract shall be negotiated friendly by Party A and Party B and a supplementary agreement shall be signed. The supplementary agreement has the same legal effect as this contract.

2. The attachments to this contract are an integral part of this contract and have the same legal effect as this contract.

3. The contract and its supplementary agreement will take effect from the date they are signed and sealed by both parties, and will terminate automatically from the date the remaining balance is paid when the maintenance period expires.

4. This contract is made in duplicate, Party A and Party B each hold one copy, and each copy has the same legal effect.

Party A: Party B:

Address: Address:

Legal representative: Legal representative:

(or authorized signatory ): (or authorized signatory):

Date: Date:

Complaint supervision telephone number: Complaint supervision telephone number: