Current location - Quotes Website - Signature design - Three copies of hydropower renovation contract model.
Three copies of hydropower renovation contract model.
In the house decoration work, water and electricity embedded installation is a very important work. Do you know how to write hydropower renovation contract? The following is the renovation contract model of hydropower that I compiled for you. Welcome to reading.

Renovation contract model essay on hydropower 1

Party B: (Contractor)

Based on the principle of mutual trust, the following agreement is reached on Party A's hydropower project.

Article 1 General situation of the project

1. Decoration construction site: Qianjin Road, Anyi County

2. Duration: 20_ years to 20_ years.

Article 2 on the supply of materials

1. Materials provided by Party A Party B must submit a list of materials to be purchased in the next process to Party A at least three days in advance, and specify the quantity of materials required. Party A shall provide the materials required by Party B on time. Party A is responsible for purchasing and supplying qualified products that meet the design requirements, and supplying them to the site on time, and both parties shall handle the handover procedures. If Party B finds any quality problems or specification differences in the materials provided by Party A, it shall promptly raise them with Party A, and Party A shall be responsible for the engineering losses caused by Party A's use.

After the materials supplied by Party A arrive at the site on time, Party A shall be responsible for keeping them, and Party B shall be responsible for keeping them after leaving the warehouse. Party B shall be liable for the losses caused by its improper behavior.

2. Decorative materials purchased and supplied by Party A shall be used for residential decoration specified in this contract, and Party B shall not use them for other purposes without Party A's consent ... If Party B violates this regulation, it shall compensate Party A at double the price of misappropriated materials.

3. The materials provided by Party B and the water and electricity materials provided by Party B shall be accepted by Party A on site. Do not meet the design and construction requirements or different specifications, it is forbidden to use. If it has been used, Party B shall be responsible for the losses caused to the project. Party B shall carry necessary tools (awls, cutting pieces, etc.). ) construction, to ensure safety and good performance, Party B shall bear the cost of maintenance and loss of tools.

Article 3 Agreement on Project Quality and Acceptance

1. This project shall strictly implement the national Code for Construction of Residential Decoration Engineering (GB502 10-20_-20) and Code for Quality Acceptance of Architectural Decoration Engineering.

2. If quality problems are caused by Party B's poor construction technology and weak sense of responsibility, the rework cost shall be borne by Party B, and the construction period shall remain unchanged.

3. Project completion: Party B shall notify Party A of the acceptance two days in advance, and Party A shall organize the acceptance within two days after receiving the notice and go through the acceptance procedures.

Article 4 Agreement on Safety Production and Fire Control Site Management:

1. Strictly abide by the stipulated decoration construction time, reduce construction noise and environmental pollution. Deal with the problem of disturbing people by construction and the relationship with surrounding units and residents.

2. Without the consent of Party A and the approval of relevant departments, the original building structure and various equipment and pipelines shall not be dismantled and changed at will during construction.

3. Before the completion of the project is handed over to Party A, it is responsible for protecting all the facilities and finished products on site.

4. Ensure the cleanliness of the decoration site, and do a good job of cleaning and handling before completion.

5. If Party B needs to live on site for construction reasons, he must pay attention to the safety of daily water and electricity consumption.

6. Party B shall properly keep the construction materials and prohibit other personnel from entering the site.

7. Without Party A's permission, Party B shall not take any decoration materials provided by Party A out of the house. If it is found stolen, Party B shall pay double indemnity according to the material price.

Article 5 Agreement on project price, contract content, construction technology and settlement:

1. Payment method of project funds:

After starting work, each worker pays the living expenses in advance, and the team pays 80% of the actual workload every month. After the project acceptance, the remaining 95% will be paid, and the remaining 5% will be paid one year later.

2. Contents of Party B's contract:

1)。 Installation and maintenance of temporary construction water and electricity

2)。 Water and electricity slotting, wiring, threading, installation of strong and weak current bridge and trench burying.

3)。 In the later stage of hydropower construction, garbage needs to be piled up.

4)。 Wall penetration, ground drilling, cutting and hole plugging in hydropower construction

5)。 Installation of switch panel: (the wall is sealed, the bottom box is positioned and leveled according to the drawings or Party A's requirements, and the seal is leveled with cement mortar powder)

6)。 Installation of hardware, toilet and sanitary ware

7)。 Installation of lamps and lanterns in all drawings in the later period.

8)。 All weak current systems of this project are not within the scope of this contract. If construction is needed, it shall be settled separately according to the requirements of weak current drawings.

9)。 If weak current bridge needs to be installed, it will be settled at 6 yuan per meter.

10)。 Power supply for the computer room on the second floor, water and electricity for the kitchen, excluding equipment installation.

1 1)。 Install the main power supply of air conditioner and fan power supply to the specified location, and reserve the interface for fire fighting cooperation construction.

12)。 Party A shall provide quantities other than the original design drawings and plane change drawings, and the quantities of intermediate changes shall be negotiated separately.

3. Project settlement method:

Actual settlement: building area: 2 142.6m2, building area: 1800.5m2, building area: 1899. 1m2, building area:1899.

Article 6 Liability for breach of contract:

1. If Party A fails to make payment according to the time stipulated in the contract, Party A shall pay Party B a penalty of 50 yuan for each day overdue.

2. If the completion is overdue due to Party B's reasons, Party B shall pay Party A a penalty of RMB 50 yuan for each day overdue.

Article 7 Dispute settlement methods:

Disputes arising from the quality of the project shall be settled by both parties through consultation; If the parties are unwilling to settle the dispute through negotiation or mediation, or if negotiation or mediation fails, they may bring a lawsuit to the people's court in accordance with this contract.

Article 8 Modification and dissolution of the contract:

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after consultation. After the contract is signed and before the construction, if one party wants to terminate the contract, it should put forward in writing, pay 20% of the total contract price as penalty, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in writing, and both parties agree to go through liquidation procedures, conclude a termination agreement and terminate the contract.

Article 9. Other agreements:

1. Both parties agree that the negotiation will be supervised by a third party. Without the confirmation of the third-party supervisor, Party A has the right not to pay relevant fees to Party B..

2. After being confirmed by the third-party supervisor, Party A must pay relevant expenses to Party B as agreed.

3. If the construction period is delayed due to force majeure or unforeseeable factors such as climate and power failure, it can be postponed after confirmation by both parties.

4. During the warranty period, quality problems caused by Party B's construction and products shall be repaired by Party B free of charge and must arrive at the site within 48 hours after receiving Party A's notice ... For problems caused by Party A's improper use, force majeure or unforeseeable reasons, Party A shall pay the maintenance fee to Party B according to the actual cost.

5. Abide by and strictly implement the project safety production management regulations, and Party B shall bear the safety responsibilities and expenses.

Article 10 Supplementary Provisions

(1) This contract shall come into effect after being signed (sealed) by both parties.

(2) After signing this contract, the project shall not be subcontracted.

(3) This contract is made in duplicate, with each party holding one copy.

(4) This contract is valid until the end of the project warranty period.

(5) The hydropower project is guaranteed for one year. After the warranty period, Party B shall pay Party A the corresponding maintenance expenses. ..

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Hydropower renovation contract model essay II

Sender: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of family room decoration project construction, both parties reached the following agreement on matters related to the family room decoration project of the Employer (hereinafter referred to as the project) through consultation:

Article 1 General situation of the project

1. 1 Project location: _ _ _ _ _ _.

1.2 project contents and practices (budget table of family room decoration project).

1.3 project contracting method: both parties agree to adopt the following _ _ _ contracting method.

(1) Contractor's contracted works and materials;

(2) The contractor contracts, part of the package materials (list of decoration materials provided by the contractor) and part of the materials provided by the employer (list of decoration materials provided by the employer); (3) Contractor contracting and employer contracting (the employer provides a list of decoration materials).

1.4 The duration of the project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1.5 contract price: the project cost of this contract is (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2 Where a project supervisor supervises a project, the employer and the supervision unit shall separately sign a project supervision contract, and notify the contractor of the name, unit, contact information and responsibilities of the supervision engineer.

Article 3 Construction Drawings Both parties agree that the construction drawings shall be provided in the following ways:

(1) The employer shall design and provide the construction drawings in duplicate, one for the employer and one for the contractor (see the design drawings of family room decoration engineering for details);

(2) The employer entrusts the contractor with the design and construction drawings in duplicate, one for the employer and one for the contractor (see the design drawings of family room decoration engineering for details), and the design fee is (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _, which shall be paid by the employer (this fee is not included in the project price).

Article 4 Obligations of employers

4. 1 _ _ _ _ days before commencement, to create conditions for the contractor to enter the site for construction. Including: on the principle of not affecting construction, demolishing or stacking indoor furniture and furnishings, and covering indoor furniture and furnishings that are not easy to move;

4.2 Provide water and electricity supply during construction;

4.3 Responsible for coordinating the relationship between the construction team and the neighborhood;

4.4 If the indoor load-bearing structure has not been dismantled, if it is necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, it is responsible for going through the corresponding examination and approval procedures with the relevant departments;

4.5 During the construction period, if the Employer still needs to use the bedroom partially, it shall be responsible for the public security and fire control of the construction site.

4.6 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance.

Article 5 Obligations of the Contractor

5. 1 During construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;

5.2 Strictly implement the construction site management regulations, and do not disturb the people or pollute the environment;

5.3 Protect the furniture and furnishings of the original living room and ensure the smooth flow of the upper and lower water pipes in the living room;

5.4 Ensure the cleanliness of the construction site, and be responsible for the cleaning of the construction site after the project is completed.

Article 6 In case of engineering change, both parties shall reach an agreement through consultation and sign a written change agreement (or

Article 7 Provision of materials

7. 1 Materials and equipment provided by the Employer. Before the materials are transported to the construction site, the Employer shall notify the Contractor, and both parties shall accept and handle the handover procedures.

7.2 The materials and equipment provided by the contractor (list of decoration materials provided by the contractor) shall be notified to the Employer before the materials arrive at the construction site, and shall be inspected by the Employer.

Article 8 Time limit for a project is delayed

8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by the Employer:

(1) engineering quantity change and design change;

(2) Force majeure;

(3) Other circumstances in which the Employer agrees to postpone the construction period.

8.2 If the time limit for a project is affected by the failure of the Employer to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the quality of the project is affected by the unqualified materials and equipment provided by the employer, the cost of rework shall be borne by the employer, and the construction period shall be postponed.

8.3 If the Employer fails to pay the project payment on schedule (within three days after signing the acceptance certificate), the construction period shall be postponed accordingly.

8.4 If the construction period is affected due to the contractor's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem with the project quality due to the contractor, Party A or Party A's representative shall put forward a specific rectification plan within three days, and the cost of rework shall be borne by the contractor, and the construction period shall be postponed through negotiation. The second rectification period of the same quality problem shall not be postponed.

Article 9 Quality standards:

Both parties agree on the construction quality standards of this project:

Article 10 Project Acceptance and Warranty

10. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:

(1) After the completion of hydropower construction and transformation, the switch socket shall be positioned and accepted; The waterproof layer does not leak after 48 hours of testing;

(2) After the bricklayer has paved the new wall, the wall and floor tile shall be laid;

(3) The carpentry ceiling and woodwork are finished;

(4) the painting project is completed;

(5) All the projects are completed. The contractor shall notify the Employer for acceptance two days in advance, and fill in the project acceptance form (home improvement project acceptance form) after the stage acceptance is qualified.

10.2 after the completion of the project, the contractor will notify the employer for acceptance, and the employer will organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance sheet (family room decoration project acceptance sheet). After the project payment is settled, the handover formalities shall be handled. 10.3 the warranty period of this project starts from the date of acceptance and signature by both parties 12 months, and the warranty fee will be charged after 12 months. The warranty scope includes the projects that our company has constructed, the damage caused by external forces and the charged maintenance of equipment and projects provided by other units. Article 11 Method of payment for project funds

1 1. 1 Both parties agree to pay the project payment in the following ways:

(1) After the contract is signed, the employer shall directly pay 40% of the advance payment for the project to the contractor as agreed, that is, RMB _ _ _ _ _ _ _ _ _ _ _ _ _; Upon completion of the bricklayer's work, the Employer shall directly pay 40% of the project progress payment to the Contractor as agreed, that is, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _; After the completion acceptance of a single project, the Employer will directly pay additional money to the contractor after the additional project is added as agreed, and after the painting project is completed, the Employer will directly pay 15% of the project payment balance to the contractor as agreed, that is, _ _ _ _ _ _ _ _ _. Pay 5% of the balance within three days after the completion of all projects, that is, _ _ _ _ _ _ _ _ _ _ _.

(2) 20% of the down payment after signing the contract, namely _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ In the future, the payment shall be made within three days after the completion acceptance sheet of each phase of the project is signed, and it shall be made in multiple installments (5%-20%) according to 10. 1, and 20% of the second phase will be paid after the completion acceptance of hydropower transformation.

(3) Other payment methods: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1 1.2 After the acceptance of the project, the contractor puts forward the project settlement proposal to the employer and sends relevant information to the employer. If the Employer has no objection within three days after receiving the information, it shall be deemed as consent. Both parties shall fill in the project acceptance form (family room decoration project acceptance form) and sign it. The Employer shall settle the progress payment of each project within three days after signing the contract. 1 1.3 After all the project funds are settled, the contractor shall issue a formal unified invoice to the employer (taxes shall be calculated separately). Article 12 Liability for breach of contract

12. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for the economic losses. 12.2 The Employer shall be responsible for the losses caused by the Employer's use of the completed project in advance or without going through the acceptance formalities.

12.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

12.4 If the Employer fails to pay the project progress payment on schedule (within three days after signing and acceptance), it shall pay the other party a penalty of 2‰ for each day overdue, and Party B may terminate the contract after fifteen days. 12.5 If the construction period is delayed due to the reasons of the contractor, a penalty of 2‰ shall be paid to the other party for each day of delay.

Article 13 Settlement of Contract Disputes

Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following _ _ _ _ _ _ _ way:

(1) Submit it to Wuhan Decoration Association or _ _ _ _ _ _ _ _ _ for arbitration;

(two) to bring a lawsuit to the people's court according to law.

Some specific provisions of Article 14

14. 1 construction waste shall be transported out of the construction site by the contractor and transported to the designated place. The developer is responsible for paying the garbage removal fee (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

14.2 during the construction period, the employer will give the key of the outhouse to the contractor for safekeeping. After the project is completed and accepted, the Employer is responsible for returning the lock _ _ _ _ _ _ _ _, and the Contractor is responsible for site installation and delivery.

14.3 during the construction period, the contractor's daily working hours are: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 15 Other agreed matters: _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 16 Supplementary Provisions

16. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.

16.2 after the signing of this contract, the project shall not be subcontracted.

16.3 this contract shall come into effect on _ _ _ _ _ _ _ _ _ _ _ _.

16.4 annexes to this contract are an integral part of this contract and have the same legal effect as this contract.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Hydropower renovation contract model essay 3

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), Regulations on Decoration Engineering Contracts and relevant laws and regulations, Party A and Party B have reached the following agreement on relevant matters on the basis of equality, voluntariness and consensus, and combined with the specific conditions of this project, and * * * will abide by this agreement.

Article 1 General situation of the project

1. 1 project name:

Location:

1.2 project content (with engineering design drawings and text description and project budget)

Decoration content is subject to drawings and budget. Any increase or decrease in actual construction shall be agreed by both parties and confirmed in writing, and settled according to the facts.

1.3 mode of contract: it is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Class A is contractors and contractors, and Class B is contractors and contractors without contractors.

1.4 According to the design drawings, the contents of the project budget and the contracting method.

Both parties confirm that the contract amount is RMB, and the amount is in words (RMB).

The design fee is RMB and the amount is in words (RMB).

1.5 construction period: according to the national construction decoration project construction period quota, both parties agree.

Start with _ _ _ _ _ _ _ _.

1.6 In case of the following circumstances, the construction period shall be postponed accordingly.

1.6. 1 According to the provisions of the construction preparation, the construction site cannot be provided, the power line cannot be connected, and obstacles cannot be removed, which affects the construction in the field.

1.6.2 major facilities that are not within the coefficient range are changed, and the provision of engineering data is not allowed to change the design scheme or affect the progress due to the inability to construct.

1.6.3 During the construction process, if the power and water supply are cut off, the normal construction will be affected.

1.6.4 The supervision visa of the person in charge of Party A's site is not timely, which affects the construction of next working procedure.

1.6.5 The delay of Party A's material supply affects the construction. 1.6.6 Failure to allocate advance payment, project progress payment or price difference of purchased materials as stipulated in the contract affects the construction.

1.6.7 The construction period is delayed due to force majeure factors such as government actions and natural disasters.

Article 2 Project supervision

If the project is supervised, Party A and the supervision company shall separately sign (project supervision contract) and notify Party B of the name, unit, contact information and responsibilities of the supervision engineer.

Article 3 Obligations of Party A

3. 1 _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

During construction: Party A shall send the person in charge of the site to conduct 24-hour inspection and acceptance with Party B, and sign an opinion after passing the inspection, and Party B shall take it as the basis for completion acceptance.

3.2 The bearing structure of the original building shall not be demolished. If it is necessary to dismantle or change the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments.

3.3 Do a good job of timely supply, and make up the shortage of materials immediately.

3.4 The project completion acceptance shall be the responsibility of the supervisor who participates in the project quality and construction progress.

Article 4 Obligations of Party B

4. 1 During the construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project on time with good quality and quantity.

4.2 Ensure the cleanliness of the construction site. Strictly implement the regulations of cities (districts) and counties on construction site management, and do not disturb the people and pollute the environment.

Article 5 Engineering changes

If it is necessary to change the project or construction method, both parties shall reach a consensus through consultation, determine a written change agreement, and adjust the related project cost and construction period.

Article 6 Project acceptance

6. 1 Concealed works: Party A shall send the technical director to inspect the concealed works with Party B for 24 hours, and sign an opinion after acceptance, which shall be kept by Party B as the basis for completion acceptance and repair.

6.2 After the project is completed, Party B shall notify Party A for acceptance. After receiving the acceptance notice, Party A shall organize the acceptance and fill in the acceptance form within two days. If it is not paid within the time limit, it will be deemed as qualified, and the handover procedures will be handled after the project payment is settled.

Article 7 Method of payment for project funds

7. 1 On the date of signing the contract for the first time, Party A shall pay _ _ _ _% of the total contract amount, namely _ _ _ _ _ _ _ _. 7.2 When the second time is _ _ _ _% of the project progress, Party A shall pay _ _ _ _% of the total contract amount, namely _ _ _ _ _.

7.3 When the third time is _ _ _% of the project progress, Party A shall pay _ _ _ _% of the total contract amount, namely _ _ _ _ _ _ _ _.

7.4 After the acceptance of the project, Party B puts forward the project settlement proposal to Party A, and sends relevant materials to Party A. If Party A has no objection within three days after receiving the materials, it will be deemed as agreement. Both parties shall fill in the project settlement list and pay the balance within seven days.

Article 8 Liability for breach of contract

8. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, and is fined or causes economic losses to the other party, the responsible party shall bear the responsibility and compensate the other party for the economic losses.

8.2 Party A shall be responsible for the losses caused by Party A's early use or unauthorized use of the finished engineering products without going through the acceptance and handover procedures.

8.3 If the performance of the contract cannot be continued due to unilateral reasons, the parties concerned shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

8.4 If Party A fails to pay the second (third) project payment on schedule, it shall pay Party B a penalty of _ _ _ _ _ _ _ _ _ _ yuan for each day of delay.

8.5 If the construction period is delayed due to Party A's reasons, Party B shall be paid a penalty of _ _ _ _ _ _ _ _ _ _ yuan for each day of delay.

8.6 If the project quality fails to meet the quality standards agreed by both parties due to Party B, the repair period for which Party B is responsible will not be postponed.

8.7 If the construction period is delayed due to Party B's reasons, Party B shall pay the other party a penalty of _ _ _ _ _ _ _ _ _ _ _ _ _ _ yuan for each day of delay.

Article 9 guarantee

9. 1 The warranty period of this project is one year, counting from the date of acceptance and signature by both parties.

9.2 Party B shall provide lifelong maintenance service, and Party A shall be responsible for the maintenance expenses outside the warranty period.

9.3 Losses caused by man-made damage and external factors, quality reasons of materials specified or provided by Party A, natural disasters and force majeure are not covered by the warranty.

Article 10 Dispute settlement methods

In case of any dispute during the execution of this agreement, both parties may apply to the Economic Contract Arbitration Committee for arbitration or bring a lawsuit directly to the court.

Eleventh specific provisions of other projects

1 1. 1 The garbage generated by the project construction shall be transported out of the construction site by Party B and transported to the designated place, and the garbage cleaning fee shall be borne by Party A (this fee is not included in the project price).

1 1.2 The final accounts of project completion shall be subject to the calculation of actual quantities.

1 1.3 The increase or decrease of items shall be negotiated by both parties, subject to the visas of both parties. Article 12 Supplementary Provisions

This contract shall come into effect after being signed by both parties.

12.2 The direct appraisal contract between Party A and Party B was concluded on _ _ _ _ _ _ _ _.

12.3 this contract will automatically terminate after the project is completed, accepted, paid and settled.

12.4 this contract is based on the principle of voluntary visa, and the contract text can be submitted to the relevant visa departments of the city (district) and county where it is located for visa, so as to protect the legitimate rights and interests of both parties to the contract.

12.5 Other annexes to the contract.

Article 13 Other agreed terms

Contractor of the Employer:

(Seal) (Seal)

Address: Address:

Authorized Agent: Authorized Agent:

Tel: Tel:

Signing place: Signing place:

Signature time: Signature time:

Three articles related to renovation contract model of hydropower;

★ There are 3 model essays on hydropower project renovation contract.

★ 3 pieces of simple water and electricity contract model for home improvement.

★ 3 pieces of renovation water and electricity contract model are the latest.

★ Simple template for hydropower contract

★ 3 copies of water and electricity installation contract.

★ 3 copies of personal water and electricity contract model

★ 3 model essays on civil engineering and water and electricity contracts.

★ Three rural housing and water and electricity contracts.

★ hydropower renovation contract model (2)

★ 5 copies of simple hydropower installation contract