In today’s society, the legal awareness of the public is constantly increasing, and there are more and more occasions where contracts can be used. Signing a contract can balance the equal status of both parties. So does anyone know the format of the contract? The following is a fire protection project clearance contract template (5 general articles) that I have carefully compiled. Welcome to read and collect it. Fire protection project clearance contract 1
The client (hereinafter referred to as Party A): __________ The trustee (hereinafter referred to as Party B): __________
In accordance with the "Contract of the People's Republic of China and the People's Republic of China" Law", "Construction Law of the People's Republic of China", and "____ City Non-commercial Government Investment Projects Implementation Agency Construction Management Measures (Trial)", after Party A's study, Party A agreed to entrust the construction project to Party B to implement agency construction , in accordance with the principles of equality, voluntariness and good faith, in order to clarify the responsibilities and rights of all parties, this contract is now concluded through consultation on the agency construction matters.
1. Project overview
1. Project name: __________
2. Project location: __________
3. Project (estimated budget) Investment: __________
4. Project approval number: __________
2. Project construction period __________ Total construction period of the project (from the date of contract signing):
3. Quality standards:
4. Contract price
Party A shall use __________% of the planned investment amount of the project in Document No. 9 issued by the Construction Committee as Party B’s construction fee. The total amount is RMB ___________ yuan.
5. Documents constituting the contract
1. Contract agreement and contract conditions;
2. Project construction power of attorney;
3. Supplementary and revised documents signed by both parties during the project implementation process.
6. Party A agrees to pay the project construction fee to Party B in accordance with the time limit, method and currency specified in this contract.
7. Party B agrees to undertake the project construction work within the scope of the project contract document in accordance with the provisions of this contract.
This contract is made in two original copies, with each party holding one copy; and four copies, with each party holding two copies. It will take effect after being signed and sealed by Party A and Party B, and has the same legal effect.
Party A (official seal): _________ Party B (official seal): _____________ Legal representative (signature): _________ Legal representative (signature): _________
_______year____month ____day_______year____month____ fire protection project clearance contract 2
General contractor: ____________________________ (hereinafter referred to as Party A)
Subcontractor ：____________________________ (hereinafter referred to as Party B)
In accordance with the "Contract Law of the People's Republic of China", the "Implementation Measures for General Subcontracting of Construction and Installation Projects" of the Ministry of Construction and the _______ Municipal People's Government No. _______ The relevant provisions of the document were agreed upon by both parties, and this contract was signed and strictly performed.
Article 1 Project
1. Project name: ____________________
2. Project location: ____________________
3. Project number: ____________________
4. Construction license number: ______________
5. Business license number: ____________________
6. Subcontracting scope and quantity (with budget attached) )
7. The subcontracting project period is to start on _________year______month______ and to be completed on _________year______month______.
8. The labor cost of the subcontracted project is ________ yuan.
9. Party B invests in the types of work and the number of _________ people.
Article 2 Project Settlement
According to the subcontracted project, the living expenses advanced in the first month are calculated based on _________ per person of the contract number, and will be deducted in the settlement of the next month. During the construction of the project, the project quantity will be pre-settled according to the acceptance quantity completed in the month (the range shall not exceed ________% of the completed quantity). After the completion of the project, both parties will agree to accept it and the settlement will be made.
Article 3 Project Quality
Party A conducts technical disclosure and organizes acceptance in accordance with national quality acceptance specifications and assessment standards. Party B carefully organizes construction in accordance with the requirements of construction drawings and instructions to ensure the project If the quality is substandard and must be reworked and repaired, Party B will be responsible for the loss of labor and material costs; if the quality of the project is poor and cannot be saved, Party B shall be responsible for compensating for all losses of labor and materials.
Article 4 Safety in Production
1. Party A must make safety disclosures on the projects undertaken by Party B, put forward clear safety requirements, and conduct supervision and inspection. Party B must conscientiously implement the relevant safety requirements Construction rules and regulations, and safety operating procedures must be strictly followed. The safety production facilities provided by Party A can only be used by Party B after passing the inspection. If any casualty accident occurs due to violation of the above regulations during the construction, Party B will be responsible for the losses.
2. Labor protection supplies and live operating tools for personal use during construction such as insulating gloves, rubber boots, etc. shall be handled by Party B by itself. If Party B does have difficulties, it may propose a usage plan and Party A will assist in solving the problem.
3. During the construction process, Party B will be responsible for any fire accidents caused by Party B's violation of fire protection regulations and laws.
Article 5 Life Management
1. After Party B’s workers enter the site, Party A will provide accommodation and main cooking utensils (large pots, cages, hair dryers, large panels) ) shall be kept by Party B, and any damage or loss will be compensated at the price. Party B will prepare small and scattered utensils by itself, and Party A will provide coal for daily use in rations.
2. Party B shall take care of the food and oil needed for daily life. Party A shall provide convenience in medical treatment and sanitation. If Party B’s workers are sick, they may work in Party A with the signature and consent of the person in charge. Party B seeks medical treatment, and Party B is responsible for paying the medical expenses on a monthly basis.
Article 6 Unit price of labor costs for subcontracted projects
1. For unit project subcontracting, each budgeted working day is _________ yuan. The labor cost per square meter is lump sum, and the labor cost is ________ yuan per square meter.
2. The inner eaves plastering is subcontracted, and each budgeted man-day to achieve high quality is _________ yuan. Each qualified working day is _________ yuan. Implement a lump sum of itemized labor costs of _________ yuan per square meter.
3. Each budgeted working day for individual subcontracted stone and earthwork projects is _________ yuan.
4. The cost of cleaning work is ________ yuan per working day.
5. The working day for full-day shutdown, waiting for materials, water supply, power outage, and cleanup is _________ yuan.
6. For water, electricity, heating and sanitary projects, each budgeted working day (subcontracted based on building number) is _________ yuan.
7. During the winter construction period (from _________ to the end of _________), the work efficiency will be reduced by ________% of working days. The unit price per working day is _________ yuan.
8. Subcontracting project cost details (all ________ items are acceptable, and shall be attached to this contract in the form of an attachment after consensus has been reached by both parties)
Article 7 Material Supply Management
Party B shall set up a dedicated person to handle the quota requisition procedures for cement, steel, commercial components, hardware, linoleum, asphalt, water, electricity, heating, sanitary and other special materials from Party A. Party B shall strictly comply with the quality requirements and materials provided by Party A for construction. Party B shall be responsible for any waste of materials used in construction and any unreasonable excess of the limit. Party B shall use materials in stacks (piles) during construction, ensure that they are cleaned every day after use, and the materials are cleaned after work is completed, and the site is kept clean and tidy.
Article 8 Construction Machinery
1. Party A is responsible for large tools to ensure their use.
2. Party B is responsible for manual operation of tools.
3. Party B shall carefully keep and take care of the machines and tools that Party A is responsible for supplying. If there is any loss or damage, Party B shall be responsible for compensation.
4. The small and medium-sized machinery required for construction shall be equipped by Party A according to the construction plan. Each machine shall be equipped with a driver to ensure the normal construction by Party B. Party B is not allowed to operate the equipment without authorization (bringing its own machinery) Handled according to relevant regulations).
Article 9 Site Management
1. Party B’s personnel must strictly abide by various on-site management systems and organize construction under the unified leadership of Party A’s on-site person in charge, including plans, schedules, and materials. The supply and other parties should cooperate closely to ensure the smooth progress of the construction.
2. Party B shall educate construction workers on compliance with laws, production safety, and property protection, and designate a dedicated person to be responsible for on-site security work. It is strictly prohibited to steal on-site materials. If there is any illegal behavior that violates the on-site management system , Party A has the right to take necessary measures, and Party B shall bear legal responsibility and be responsible for compensation for economic losses.
3. Subcontracted personnel must remain relatively stable and wear work signs when entering and exiting the construction site. Persons outside the contract are not allowed to enter or leave the site and accommodation.
Article 10 Liability for breach of contract
1. Projects subcontracted by Party B shall not be subcontracted again. During the construction process, if the inspection fails to meet the national acceptance specifications and the quality of the project cannot be guaranteed, Party A has the right to terminate the contract and Party B shall compensate for the loss caused by rework.
2. After the contract is signed, neither party may change or terminate it at will without the consent of both parties. If Party B unilaterally terminates the contract without the consent of Party A, Party B shall compensate Party A for the economic losses caused by affecting the construction plan; if Party A terminates the contract midway, Party B shall compensate Party B for the economic losses caused thereby.
3. Party B must complete the project in accordance with the construction period and quality requirements stipulated in the contract. Otherwise, Party A shall be reimbursed to Party A with overdue liquidated damages equal to ________% of the labor cost of the subcontracted project for each day overdue.
4. Party A and Party B shall not default on various payables for any reason. If they default on payment, they will pay the other party penalty for overdue payment according to the bank's short-term loan interest rate.
Article 11 Supplementary Provisions
1. When a dispute arises under this contract, the parties shall negotiate in a timely manner. If the negotiation fails, the parties shall negotiate in a timely manner. If it cannot be resolved, it can be resolved according to the following item ():
(1) Apply to the Economic Contract Arbitration Committee where the building is located for arbitration;
(2) File a lawsuit in the People's Court.
2. This contract is made in _______ copies, and Party A and Party B each hold _______ copies of the original. The remaining copies shall be submitted to _______ for filing.
3. If you require authentication (notarization), you can go to the district or county industrial and commercial administration bureau where the building is located for authentication or notarization.
4. Other terms agreed upon by both parties:
①____________________________
②____________________________
Article 12 Contract validity period
This contract will take effect from the date of sealing by both parties and will expire after the project is fully completed and settled.
General contractor (seal): _______________Subcontractor (seal):_______________
_______year_______month_______day_______year_______ Fire protection project clearance contract 3 on _month________
Party A: _______________ (hereinafter referred to as Party A)
Party B: _______________ (hereinafter referred to as Party B)
According to the "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China" and other relevant laws, regulations, ordinances, rules, etc., both parties follow the principles of equality, voluntariness, fairness and good faith, Reach a consensus on this project, enter into an agreement and agree to abide by it.
Article 1: Project name:
Article 3: Project scope: see attachment.
Article 4: Total project price:
RMB (this is the bidding price, payment is based on the actual project quantity, this is the after-tax price), Party B will contract the work and materials.
Article 5:
5.1 Completion date: (Completion report shall prevail) Delivery date
5.2 Total contract period: Yuan.
5.3 Party A’s payment is not premised on Party B providing an invoice.
Article 6: Quality standards for this project
Construction shall be carried out in accordance with the standards stipulated in the design documents and relevant specifications and shall comply with relevant national acceptance standards.
Article 7: Representation
Party A shall designate one or two persons as representatives of Party A. Documents signed by him shall be deemed as Party A’s official documents. The power of attorney of the relevant personnel shall be included as part of this contract. If a change occurs, Party A shall notify Party B in writing on the same day after the change, and any losses caused by Party A's delay in notifying shall be borne by Party A.
Article 8: Construction Site Management
8.1 Party B must strengthen the safety and professional skills education of construction personnel. During the construction process, safety must be ensured, hidden dangers must be eliminated, and all accidents must be eliminated. .
8.2 Strictly implement various management systems on the construction site. The construction site must be constructed in a civilized manner. The site must be cleared after the work is completed, and the garbage must be piled and transported to the designated location.
8.3 After entering the construction site, Party B shall not fight, drink or cause trouble. If the case is serious, the case will be transferred to the judicial department for handling.
Article 9: Equipment, materials, access and supporting facilities
9.1 Party A provides Party B with temporary housing, as well as temporary or permanent properties required to complete and maintain the subcontracted project. equipment.
9.2 Materials used in this project: see attachment.
9.3 The place where Party B stores equipment shall be within the scope approved by Party A and shall not hinder the progress of the project and the smooth flow of the streets. In order to enable Party B to carry out the construction smoothly according to the subcontract, Party A shall provide Party B with sufficient facilities to enable its equipment to enter part or several parts of its construction site.
9.4 During the construction of this project, Party A is responsible for providing temporary water and electricity facilities at the construction site and related places. Party A should pay attention to maintaining the safe and normal operation of transportation, electricity, communications, water supply, gas or other facilities at all times.
Article 10: Project Insurance
10.1 Party B shall purchase insurance for its employees
10.2 The insurance policy handled by Party A is to fulfill the general provisions of the general contract. If Party B shall enjoy the benefits in the insurance policy, and Party A shall indicate or specifically list the benefits enjoyed by Party B on the insurance policy and this part of the schedule.
10.3 Both parties must maintain its validity period until the entire subcontracting project is completed.
10.4 Unless it can be proven that the construction period is extended due to force majeure or intentional or gross negligence of Party B, Party A shall pay the renewal fee.
Article 11: Change of Design
11.1 Both parties may change the project of their subcontract according to the following circumstances:
11.2 The parties to this contract shall agree to reduce the matters.
11.3 For the benefit of Party A, Party B may notify Party A in writing 10 days in advance of changes, additions or reductions.
11.4 Party B can price the increased or changed fees according to the relatively high price during the period from signing to change. 11.5 For reduced projects, Party A shall not only bear the loss of materials purchased by Party B, but shall also pay Party B’s reasonable expenses for this purpose.
Article 12: Project Extension
12.1 When the completion date needs to be extended, Party B can truthfully notify Party A in writing of the project extension notice within 3 days after the cause occurs, but it can Except if it is proven that Party B intentionally caused the delay.
12.2 During the construction of this project, Party A may notify Party B to suspend all or part of the project.
Article 13: Acceptance
13.1 When the project has covering or covering conditions or reaches the intermediate acceptance position, Party A shall conduct acceptance within 24 hours after receiving Party B’s notice .
13.2 When the progress of this project meets the completion or phased acceptance standards, Party B shall submit a written submission for completion acceptance. After approval by the supervision engineer, it will be accepted by Party A.
13.3 Party B shall notify Party A in writing of the date of acceptance 3 days before acceptance. If Party A cannot participate on time, Party B must notify Party B in writing 2 days in advance. The resulting delay shall be based on Article 13 of this contract. Compensation for damages. 13.4 If Party A fails to conduct acceptance within 3 days after receiving Party B’s notice, and does not propose an extension, the project quantities listed in the acceptance notice submitted by Party B will be deemed to be approved, and the acceptance date in the notice will be deemed to be the date of passing the acceptance. as the basis for payment of the contract price.
13.5 After the project is completed and accepted by Party A, Party B shall hand it over to Party A within 10 days. The ownership and related rights and obligations will be deemed to be transferred on the date of acceptance.
Article 14: Liability for breach of contract and damages
14.1 If one party encounters any of the following circumstances, the other party may terminate or terminate this contract, and one party shall pay the other party according to the project Liquidated damages calculated at 10% of the total price.
14.2 One party requires that the project amount be reduced by 20% of the original contract amount.
14.3 One party requires a suspension of work for 15 days, unless it can be proved that it is force majeure or the other party’s intention or gross negligence.
14.4 One party is in danger of going out of business, going bankrupt, going bankrupt or experiencing financial difficulties, or one party is apparently unable to pay for the project.
14.5 When this contract is terminated or canceled due to the above reasons, or other compensation events occur due to other reasons resulting from the contract, one party may still seek compensation from the other party in accordance with the law.
14.6 Unless it can be proven that Party B deliberately failed to enter the construction site on time, Party A shall compensate Party B for liquidated damages of RMB 150,000.
14.7 Unless it can be proved that the suspension or delay is caused by force majeure or intentionally caused by Party B, Party A shall bear compensation to Party B at the rate of 100 yuan per person per day, and pay Party B the expenses incurred by the suspension or delay, including But it is not limited to depreciation of construction machinery and tools, construction site expenses and management expenses, etc. Party A shall take the initiative to compensate Party B within ten days of notifying the suspension of work.
14.8 If Party A fails to pay the project payment, liquidated damages, compensation, etc. on time as stipulated in the contract, Party A will pay liquidated damages equal to 3% of the total project price for each day of delay.
Article 15: Dispute Resolution
If Party A and Party B have a dispute over the terms of this contract, both parties shall negotiate on an equal footing. If the negotiation fails, the matter shall be under the jurisdiction of the People's Court.
Article 16: Others
16.1 Contract Limitation: This contract will take effect after being stamped by both parties, and will be terminated after the balance is paid.
16.2 Number of Contract Copies: This contract is made in four copies, with Party A and Party B each holding two copies.
16.3 The stamp of the original contract shall be affixed by both parties respectively.
16.4 The address provided by one party is a deliverable address. If there is a change, it should be notified in time. Otherwise, delivery at the address specified in the contract will be regarded as delivery.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________year____month__________year____month____ fire protection project clearance contract 4
Contract-issuing party: ____________________ (hereinafter referred to as Party A)
Contractor: __________________ (hereinafter referred to as Party B)
In accordance with the "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China" and other relevant laws and administrative regulations , regarding matters related to the construction of this project, following the principles of equality, voluntariness, fairness and good faith, the following agreement has been reached through negotiation between both parties:
Article 1: Construction Period
1. The contract project is scheduled to start on ______ month ______ of ______ year and be completed on ______ month ______ of ______ year. The number of calendar days in the contract period is ______ days. If the construction period needs to be advanced, the total number of days in the contract period calculated based on the agreed start and completion dates will be ______ days.
2. The corresponding measures taken by the contractor to advance the construction period and the resulting increased economic expenditure: ____________________.
3. Rewards and penalties for advancing or delaying the construction period shall be determined in the contract after negotiation between the two parties. Agreement: ____________________.
Article 2: Drawings
The party issuing the drawings shall provide ______ set of drawings to the contractor.
Article 3: Representatives of the contract issuing party and the contractor at the construction site
Name of the contract issuing party’s engineer: ______; Name of project manager: ______.
Article 4: Work of the Contractor
Land acquisition, compensation for young crops and trees, relocation of cemeteries, demolition of houses and structures, and removal of above-ground, overhead and underground obstacles must be completed before the start of construction. Connect the water, electricity lines, and roads required for construction to the construction site, and ensure the needs during the construction period. Provide the contractor with the engineering geology and underground pipe network line information of the construction site, submit the legal procedures for relevant certificates and approvals, and standardize the standards. The locations of points and coordinate control points shall be submitted to the contractor in writing and shall be inspected on site. We shall coordinate and deal with the protection of buildings, structures (including cultural relics protected buildings), ancient and valuable trees, and underground pipelines around the construction site, as well as the construction disturbance to residents. When constructing in a toxic and harmful environment, the contractor shall provide corresponding protective measures in accordance with relevant regulations and bear relevant economic expenditures.
Article 5: Contractor’s work
1. Submit monthly construction plan and completed project progress statistical report to the contractor on ______ day of each month.
2. Comply with the management regulations of the relevant national and municipal departments on traffic and construction noise at the construction site, be responsible for safety, cleanliness and other work, and do a good job in keeping the buildings and structures around the construction site (including Protection of cultural relics buildings), ancient and valuable trees and underground pipelines. When underground obstacles and cultural relics are discovered, they should be reported to the relevant departments in a timely manner and effective protective measures should be taken, and they should be handled in accordance with relevant specific regulations. The contractor will bear the resulting costs, and the delayed construction period will be postponed accordingly. If the contractor fails to complete various tasks as stipulated in the contract, he shall bear the resulting economic losses and the construction period will not be extended.
Article 6: Project Quality Inspection and Acceptance
1. When the project meets the coverage or cover conditions or reaches the intermediate acceptance position, the contractor shall conduct self-inspection and notify 48 hours in advance. Only after the contractor has participated and passed the acceptance inspection can the concealment and construction continue. If the acceptance fails, the contractor will revise it within a limited time and re-accept it. The economic expenses caused by incorrect correction by the contract-giving party or other reasons not caused by the contractor shall be borne by the contract-giving party. The inspection should not affect the normal progress of the construction. If it affects the normal progress of the construction and the inspection fails, the contractor will be responsible for the costs that affect the normal construction. In addition, the economic expenses that affect normal construction will be borne by the contractor, and the construction period will be postponed accordingly.
2. The project meets the conditions for completion acceptance. The contractor shall provide complete completion information and completion acceptance report to the contracting party in accordance with the relevant regulations of the country and this city on project completion, and the contracting party shall organize acceptance within 10 days. If the contract issuing party cannot organize acceptance on the agreed date, it shall bear the responsibility for project storage and the fees payable from the day after the last day of the agreed period. After the contract issuing party and the contractor have completed the project completion acceptance procedures, the contract issuing party shall report the quality record of the completed project to the quality supervision agency in accordance with relevant regulations within 5 days. This contract will be terminated. The contractor shall be responsible for the quality warranty of the project delivered to the contractor during the quality warranty period in accordance with laws, administrative regulations or relevant national regulations on project quality warranty.
Article 7: Design changes and contract price adjustments
1. During the construction, the contracting party makes changes to the original design. After approval, the contracting party shall report to the contractor 10 days before the change. The contractor shall issue a written notice of change, otherwise, the contractor shall have the right to refuse the change. The contractor makes changes according to the notice and submits complete information on the change price report according to the agreed adjustable contracting method within 5 days. The economic expenses and losses of the contractor caused by the change shall be borne by the contract issuing party, and the contract issuing party receives the change price report. It must be signed within 5 days from the date of delivery. If it is not signed without justifiable reasons, it will automatically take effect 5 days from the date of delivery of the price change report, and the construction period delayed accordingly will be postponed accordingly.
2. The contracting cost of this project will be adjusted as follows according to the adjustable contracting method:
Article 8: Project price and settlement
Both parties shall adjust the contracting cost according to the country and The relevant competent authorities in this city currently stipulate that after the contract takes effect and seven days before the start of construction, the contract issuing party shall advance ______% of the project payment to the contractor; the progress payment shall be allocated based on the project progress reported on the 1st of each month; the contractor shall perform according to the requirements of the contract issuing party After all obligations have been paid, a completion settlement report shall be submitted to the contract issuing party. The contract issuing party shall settle the payment to the contractor within ______ after receiving the completion settlement report. If the contract issuing party fails to allocate the project funds on time, it shall be responsible for the payables from the date of payment. Interest. This contract shall be terminated after the employer and contractor perform all obligations under the contract, the completion settlement price is paid, and the contractor delivers the completed project to the employer.
Article 9: Supply of Materials and Equipment
1. Both the contracting party and the contractor shall provide product qualification certificates for the materials and equipment they are responsible for supplying; if they are inconsistent with the design and specification requirements Products that meet the requirements will be repurchased, and each party shall bear the resulting costs.
2. When the contractor needs to use substitute materials, it must be approved by the representative of the contracting party before use, and the increase or decrease in costs will be agreed upon by both parties.
Article 10: Disputes
When a dispute arises between the contracting party and the contractor, they may negotiate or apply for mediation by the construction contract management agency in conjunction with the relevant departments. If you are unwilling to mediate or the mediation fails, you can use one of the following methods to resolve the dispute:
The first dispute resolution method: apply to the ______ Arbitration Commission for arbitration;
The second dispute Solution: File a lawsuit in ______ People's Court. Both parties agree to resolve the dispute in accordance with the ______ dispute resolution method.
Article 11: Quality Warranty
The contractor shall, in accordance with laws, administrative regulations or relevant national regulations on project quality warranty, ensure that the project delivered to the contractor for use during the quality warranty period bear the responsibility for quality warranty.
The warranty includes:
1. Lifetime warranty for the main structure of the project;
2. 5-year warranty for the roof waterproofing structure;
3 , decoration and other warranty for two years.
Article 12: Breach of Contract
If the contracting party or the contractor fails to perform its obligations in accordance with the terms of this agreement and conducts behavior that makes it impossible to perform the contract, it shall bear corresponding consequences. Liability for breach of contract includes payment of liquidated damages and compensation for all economic losses caused to the other party by its breach of contract. Unless both parties agree to terminate the contract, or the contract cannot be performed due to one party's breach of contract, the defaulting party shall continue to perform the contract after assuming the above liability for breach of contract.
The two originals of this contract are equally valid and shall be kept separately by the contracting party and the contractor; ______ copies shall be made.
Party A (official seal): __________________
Party B (official seal): __________________
Date: ______year______month______ fire protection project clearance Contract 5
Employer: (hereinafter referred to as Party A) Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of the People's Republic of China and the People's Republic of China *** and the Construction Law of the People's Republic of China and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness and good faith, both parties reached consensus on the construction matters of this construction project and entered into this contract.
1. Project name:
2. Project location:
3. Contract duration: The start date of this contract project is _________year____month From ____ to ____, month ____, _________, the construction period is 30 days. The contractor guarantees to fully complete all contract work in accordance with the provisions of the contract and assumes all obligations and responsibilities of the contractor stipulated in the contract.
IV. Project quality standards: The project under this contract is an excellent quality project. The contractor should strengthen quality management and conscientiously perform the various measures stipulated in this contract to ensure that it meets this standard.
5. Contract price: Amount (uppercase) in RMB yuan (lowercase yuan).
The geological conditions will not change much during the implementation process. When the project quantity does not exceed 10% of the bidding quantity, the total price will not be adjusted, and the excess will be increased or decreased according to the owner's unit price (the bill of quantities and the owner's unit price table are attached).
6. Documents constituting the contract: The documents constituting this contract include:
1. Agreement on this contract
2. Notice of winning the bid
3. Tender and its attachments
4. Contract terms
5. Standards, specifications and relevant technical documents
6. Drawings
7. Bill of Quantities
The written agreements or documents regarding project negotiations and changes between the two parties shall be deemed to be an integral part of this contract.
7. The meanings of the relevant words in this agreement are the same as those given to them in the "Contract Terms" of the bidding documents.
8. The contractor promises to the contractor to carry out construction and completion in accordance with the contract, and to undertake project quality warranty responsibilities within the quality warranty period.
9. Payment method: Upon completion and acceptance by Party A, Party A will pay % of the total contract cost to Party B over time, and Party A will bear the liability for breach of contract.
10. Warranty deposit: The quality deposit for this project is 10%. The warranty period is _________ years starting from the date of completion and acceptance of the project. It will be returned after the expiration of the inspection and acceptance without defects.
11. The contract takes effect
This agreement will take effect after it is signed by the legal representatives or authorized agents of both parties and stamped with the official seal of the unit. This contract is made in four copies, including two original copies, each party holds one copy, and a duplicate copy, each party holds one copy.
Party A (official seal): _________
Party B (official seal): _________
Legal representative (signature): _________
Legal Representative (Signature):_______
_________month____day
_______year____month____day