If you want to contract a project, it cannot be solved with a few simple sentences. Instead, you need to negotiate and sign a contract. So how should you write a contract? The following is a "Simple Template of Engineering Contracting Contract" compiled by me for your reference only. You are welcome to read it. Simple template of project contract (1)

Contractor: ______________

Contractor: ______________

Signing time: ______________

Signing place ：______________

In order to ensure the quality of _________ construction, complete the construction tasks as scheduled, and achieve the purpose of mutual benefit for both parties, in accordance with the "Contract Law of the People's Republic of China and the People's Republic of China" and the "Contract Law of the People's Republic of China and the People's Republic of China" Construction Law" and other laws and regulations, both parties negotiated friendly and reached consensus on the construction project of this project and entered into this contract.

1. Project name: ____________________

2. Construction area (project form)_______________

3. Construction location: ____________________

4 , Construction period:

1. Start of construction: _______ year _____ month ___ day;

2. Completion: _______ year _____ month ___ day; < /p>

3. The total contract period lasts for ____ days.

5. Contracting form: _______________________

6. Project quality standard: ____________________

7. Project price: *** in RMB.

8. Payment method: After the contract takes effect, __% of the contract price will be paid, calculated as ____ yuan; after the project is completed and accepted, __% of the project price will be paid, calculated as ____ yuan. ;The warranty deposit is ___ yuan, which will be paid after the warranty period expires.

9. Warranty period: ____ years.

10. Responsibilities and obligations of both parties

1. Responsibilities and obligations of the contractor

① Provide the contractor with good construction sites, roads, water, and power supply to meet the requirements Starting conditions. Resolve neighbor relations and disputes that need to be coordinated and resolved by the contractor during the construction;

② Supervise and manage the project quality, material quality, and supervise the progress of the project during the construction process; ③ Provide construction drawings, coordinate points, and elevations to the contractor ④ Allocate funds to the contractor on time and carry out acceptance and settlement;

2. Responsibilities and obligations of the contractor

① Carry out construction according to the requirements of the contractor and drawings; ② Complete as scheduled Construction tasks;

③Accept the technical guidance and quality standard requirements of the contracting party; ④Responsible for the protection of materials and equipment provided by the contracting party;

⑤Educate construction personnel to care for Party A’s materials Property shall not be stolen or damaged; ⑥ bear responsibility and expenses for all safety accidents during construction;

11. Others

1. This contract shall take effect after being signed and sealed by both parties, and shall be valid for a period of until the warranty expires.

2. Matters not covered in this contract can be resolved through negotiation and signed by both parties in a written supplementary agreement. The supplementary agreement has the same legal effect as this contract. Negotiations failed, and the case was submitted to the People's Court of _______ County for filing a lawsuit.

3. The contract attachments are an integral part of the terms of this contract. This contract and the attachments are made in two copies. Each party holds one copy, which is equally valid.

Contractor: _______________ Contractor: _______________

Authorized agent: _______________ Authorized agent: _______________ Simple template of project contract contract (2)

The contractor (hereinafter referred to as Party A)_______________

The contractor (hereinafter referred to as Party B)_______________

These terms have been formulated by consensus between the two parties, and both parties must abide by them.

1. Contracting Project

Excavation, transportation and leveling of earthwork in this project.

2. Contracting method

Excavation, transportation and leveling are contracted, and subcontracting is not allowed.

3. Contracting price

Excavation and transportation of earthwork _______ yuan/m3 (gravel and sand).

IV. Construction period requirements

Excavation will be carried out according to the dimensions required by the drawings. Construction will begin on the day of the month. Excavation, transportation and filling of the base earthwork must be completed within days according to the drawings. Leveling.

5. Quality and construction requirements

1. The plane position, bottom size, slope slope, elevation and bearing layer of the base should comply with the requirements of the design drawings, and the deviation should be controlled within Within the scope allowed by construction regulations.

2. Prepare ditches and drainage facilities. Achieve location, size and elevation in compliance with design requirements.

3. When backfilling soil, turf, debris and accumulated water should be removed and compacted in layers. The density after compaction should meet the design requirements.

4. After the earthwork is excavated, it must be inspected by the design, construction (supervision), company, and quality supervision station to meet the requirements before it is qualified; otherwise, the cost of renovation and rework will be borne.

VI. Safety Requirements

1. Before starting work, Party B shall educate workers on the safety ideology and safety precautions of this type of work and make disclosure records.

2. Carry out construction in strict accordance with the safety precautions in the technical operating procedures for earthwork construction. Otherwise, B will be responsible for any safety accidents.

3. Abide by construction site rules and regulations, obey the instructions of on-site managers and the supervision and management of relevant superior departments.

4. The excavated earth should be stacked at the designated location. Ensure that construction roads are smooth.

5. During rainy season construction, attention should be paid to slope stability and inspection work should be strengthened. If necessary, the slope can be appropriately slowed down or support retaining boards can be installed.

6. If groundwater or buried pipes, cables, etc. are found, the person in charge of the construction site should be reported promptly and drainage, waterproofing and other measures should be taken.

VII. Settlement method

Cash payment will be used, and the project payment will be paid on the second day after the excavation is completed and the project is accepted. ·Store contract contract·Housing contract contract·Orchard contract·Fishery contract contract

8. Arbitration and mediation

In the event of labor disputes and economic disputes, both parties agree to submit them to the labor arbitration department or the People's Court for mediation.

Once this agreement is signed, both parties shall consciously perform their contractual obligations and shall not regret it. This agreement is made in duplicate, with Party A and Party B each holding one copy. It will take effect after being signed and sealed by both parties, and will automatically expire after the project payment is settled.

Unit project leader (Party A): ____________ Contracting team leader (Party B): ______________

Contact number: ____________________________ Contact number: ____________________ Simple template of project contracting contract (three )

Contractor: ______________

Contractor: ______________

In accordance with the "Contract Law of the People's Republic of China" and other relevant laws and administrative regulations, Party A will contract the construction of the rural road construction project from the ancient city of Saishisi Town to Mazhatang Village to Party B, and Party B will be responsible for contracting the construction. Following the principles of equality, voluntariness, fairness and good faith, both parties reached consensus on the construction matters of this construction project, clarified the rights and obligations of both parties, and concluded this contract after negotiation.

1. Project Overview

Project Name: _______________

1. The roadbed is 5 kilometers long, the road surface is 3.5 meters wide, and the total renovation area is 17,500 square meters. The winning bid price is 30,000 yuan.

2. The road surface is 5 kilometers long, and the desertification on the road is 3.5 meters wide and 15 centimeters thick. The total desertification area is 17,500 square meters, and the winning bid price is 120,000 yuan.

3. Lay 4 culverts with a depth of 3 to 5 meters. The winning bid price is 20,000 yuan.

Project content: roadbed treatment, sand surface layer, small bridges and culverts, and road shoulder construction.

2. Project Contracting Scope

Contracting Scope: All contents of construction design.

3. Project price and payment method: Total contract price (in capital letters): 1.16 million yuan (RMB): 160,000 yuan.

The project price will be paid in installments according to the progress of the project, and the final settlement will be made after the project is accepted and accepted. Party A deducts 5% of the total project price as a quality deposit, which will be paid to Party B after the project is completed without quality defects.

IV. Rights and Obligations of Both Parties

1. Party A shall provide drawings, Party B must construct according to the drawings and the technical specifications of the highway reconstruction project, and Party B shall ensure that the quality is up to standard.

2. Party B must start construction within 3 days from the date of signing the contract.

3. Party A has the right to supervise and manage Party B’s construction. Party A shall inspect and accept Party B’s construction according to the construction progress. Only after the inspection is qualified, the next step of construction can be carried out.

4. Party B shall not change the project manager without the consent of Party A. Otherwise, Party A has the right to terminate the contract.

5. Party B shall not subcontract the project, and shall not subcontract without the consent of Party A. Otherwise, once verified, Party A has the right to terminate the contract without assuming any legal liability arising therefrom.

6. Party B shall ensure construction safety during the construction process. If any safety accidents such as work injuries occur, Party B will be responsible.

If Party B's construction causes damage to national, collective, or individual property or personal life, Party B will be responsible for compensation.

7. Party A is responsible for coordinating and handling disputes surrounding the construction process.

8. Party B shall be responsible for all taxes and fees required for construction.

5. Liability for breach of contract

1. Party B must complete the project on time, otherwise, it will pay liquidated damages of 1,000 yuan/day for each day overdue.

2. If Party B terminates the contract midway, Party A will not compensate for its early construction investment, and the project price allocated by Party A will be refunded by Party B.

3. If Party A fails to accept the quality of the project and needs to be reworked and repaired, Party B will unconditionally rework and repair it until it reaches the required standards, and Party B will be responsible for any losses incurred.

4. If Party A terminates the contract midway without reason and causes losses to Party B, Party A will be responsible for compensating Party B for the losses. If the quality of the project does not meet the standard and requires rework and repair, but Party B refuses to do so, Party A has the right to terminate the contract and terminate the contracting relationship. Party B will be responsible for any investment losses, and the project price allocated by Party A will be refunded by Party B. .

VI. Contract Period

Start date of construction: _______year__month___day

Completion date:_______year_____month_ __days

The total number of calendar days during the contract period is _______ days.

7. Quality standards

Project quality standards: qualified.

8. The contractor promises to the contractor to carry out construction and completion in accordance with the contract and assume the responsibility for project quality warranty within the quality warranty period.

9. The developer promises to the contractor to pay the contract price and other payable payments in accordance with the time limit and method stipulated in the contract.

10. The contract takes effect

This contract will take effect after both parties agree to sign and seal it.

Employer: _________ (signature)

Contractor: _________ (signature)

Contract signing time: _________

Contract signing place : _____________ simple template of project contracting contract (4)

Contractor (Party A): __________________

Address: ____________ Telephone: ____________

Contractor ( Party B): _______________

Address: ____________ Telephone: ____________

In accordance with the "Contract Law of the People's Republic of China" and the relevant regulations of _________ City, both parties have reached consensus through consultation , sign this contract and perform it seriously.

Article 1 Project

1. Project name:

2. Project number:

3. Project location:

p>

IV. Scope of the project: The construction and installation area of ??all projects in this contract totals ________ square meters (see the project list for details of the construction and installation area of ??each individual project).

5. Project cost: The budgeted cost of all construction drawings of this contract is RMB ________ (see the project list for details of the cost of each individual project).

Article 2 Project Period

1. According to the national construction period quota and usage needs, it is agreed that the total construction period of the project is ____ days (calendar days), starting from _______ year____ The construction will start on _month___ and will be completed and accepted on _____month___, _______ year (the start and completion date of each unit's project is attached, see Appendix 1).

2. ____ days before the start of construction, the contractor shall issue a notice of commencement to the contractor.

3. During the construction process, if the following circumstances occur, the construction period may be extended. Both parties shall negotiate in a timely manner and determine the extension period in writing:

1. Due to natural disasters or The work is forced to stop due to irresistible reasons;

2. The construction cannot be continued because Party A proposes a change of plan or construction drawing;

3. According to the construction preparation regulations, the construction cannot be continued Providing construction sites, water, and power supply, the roads are not smooth, and the obstacles are not cleared, which affects the access to the construction site;

4. Because Party A is unable to provide drawings, materials, equipment or its supplies on time The materials and equipment do not meet the specifications and the work is forced to stop or the construction cannot be carried out smoothly.

5. During construction, if there is a power outage or water outage for more than 8 hours or a continuous intermittent water or power outage for more than 3 days (each time for more than 4 hours in a row), the normal construction will be affected;

< p> 6. The supervision visa is not timely due to reasons other than the contractor’s, which affects the construction of the next process;

7. The construction is affected by failure to allocate advance payment, project progress payment or price difference for purchased materials as stipulated in the contract; < /p>

8. Due to policy changes, force majeure, and reasons beyond Party A and Party B, the construction of the project is suspended or postponed, making the contract unable to continue to be performed. Party B shall properly protect and protect the completed project and purchased materials and equipment. Hand over the work; withdraw its own mechanical equipment and personnel from the construction site at the request of Party A. Party A shall provide necessary conditions for Party B's withdrawal, pay the above economic expenses, pay the price of the completed project and compensate Party B for relevant losses in accordance with the contract. . The ordering party is responsible for returning the ordered materials and equipment. The non-refundable payment and return costs shall be borne by Party A. However, the responsible party shall bear the losses caused by failure to return goods in time.

4. The construction period is advanced. If it is necessary to complete the project ahead of schedule during construction, both parties can sign an early completion agreement after consensus, and the contract completion date can be advanced. Party B shall revise the schedule accordingly and submit it to Party A for approval. Party A shall give approval within 5 days and provide convenient conditions for expediting work. The early completion agreement includes the following main contents.

1. The advance time;

2. The measures taken by Party B to rush the work;

3. The conditions provided by Party A to rush the work;

< p>　4. Economic expenditure and commitment for rush measures;

　5. Sharing of proceeds from early completion (if any).

Article 3 Construction Preparations

1. Party A should obtain all the documents and approvals required for construction before starting construction, apply for a construction license; and clear the construction site of any obstructions that may affect construction The original pipelines, trees and other obstacles; solving the construction land (including the storage and transfer sites of materials and components, and the land for building large temporary facilities); solving the smooth flow of construction water sources, power supplies and transportation roads; it should be completed in _______ year_ Provide ____ copies of all engineering design drawings to Party B on ____month___; organize design and construction units to conduct engineering design disclosures.

2. Party B shall organize relevant personnel to study and familiarize themselves with the drawings and participate in the design briefing before the start of construction; compile a budget for construction drawings; be responsible for preparing construction organization design or construction plan; leveling the construction site and construction boundaries Water, electricity, roads and construction temporary facilities within the project are arranged, the overall construction progress plan is arranged, materials are stored, components are processed, and all construction preparations are made.

Article 4 Material Supply

1. The following materials and equipment shall be supplied by the contracting party in kind or indicative: ____________

2. In addition to those supplied by the contracting party Other materials and equipment shall be purchased by the contractor; 3. Materials and equipment supplied by the contractor and purchased by the contractor must be accompanied by a product certificate before they can be used in the project. If the materials and equipment that Party A is responsible for supplying are not supplied on time or the specifications and quality do not meet the requirements, it cannot be resolved despite the efforts of both parties. The resulting losses to Party B shall be borne by Party A. If either party believes that the materials provided by the other party require re-inspection, re-inspection shall be allowed. If it meets the quality requirements after re-inspection, it can be used in the project, and the re-inspection fee will be borne by the party requesting re-inspection; if it does not meet the quality requirements, it should be handled in accordance with relevant regulations, and the re-inspection fee will be borne by the party providing materials and equipment.

IV. How to deal with the price difference of materials and equipment for this project: ____________

Article 5 Project Quality

1. The quality of this project has been studied by both parties to meet the following requirements: ____________

2. The contractor must strictly carry out construction in accordance with the construction drawings, documentation and construction engineering codes, specifications and standards issued by the state, and accept the supervision of the representative of the contract-issuing party.

Article 6 Payment and Settlement of Project Price

1. Within ____ days after the signing of this contract, the contractor shall pay no less than the total contract price (or the amount of investment for the year) ____% of the material preparation amount, calculated as RMB________ million yuan; temporary facility fees, calculated as ____% of the total contract cost of the civil engineering project, calculated as RMB________ million yuan, and the installation project is calculated as ____% of the labor cost, calculated in RMB________ Ten thousand yuan; the price difference for materials and equipment is _________ ten thousand yuan, paid in ____ times, each payment time is ____, and the amount is ________.

2. The employer receives the contractor’s project progress month After the submission, the progress payment must be made according to the verified project progress within ____ days. When the project progress payment reaches ____% of the total contract price, the material preparation payment will gradually begin to be deducted according to the prescribed proportion.

3. When the project price payment reaches 95% of the total contract price, payment will no longer be made according to the progress. After completion of the handover acceptance, the principal and interest (financial appropriation does not include interest) will be paid to the contractor in one lump sum.

4. If the contractor defaults on the project progress payment or final payment, it shall pay the contractor a liquidated penalty of _three-ten thousandths___ of the default amount per day.

5. If the progress of the project is indeed affected by the contract-issuing party's arrears of project payment and price difference for purchased materials, resulting in the contractor's stoppage or delay in work, the contract-issuing party shall bear the responsibility.

Article 7 Construction and Design Changes

1. Party B must organize construction in accordance with the construction acceptance specifications and quality inspection standards and design requirements issued by the state, and all must be qualified.

2. Construction must be carried out according to the drawings, and no party may change the design at will. If the following circumstances cause the other party to suffer losses such as work delays, rework, backlog of materials and components, relocation of construction force and machinery, the responsible party shall bear the responsibility:

1. If errors in the design are discovered during construction or seriously unreasonable, Party B shall notify Party A in writing, and Party A shall negotiate with the original design unit within 7 days to propose modifications or changes to the design documents. Construction will only be allowed after both parties sign an agreement.

2. During construction, if construction is stopped or postponed midway, Party A and Party B should agree to ensure that the project under construction is in a safe position.

3. During the construction, if Party A is found to have insufficient investment and is unable to allocate project progress funds on time, and the construction is stopped or delayed midway, Party A shall bear the losses caused to Party B.

Article 8 Liability for breach of contract

Responsibilities of the contractor:

1. If the quality of the project does not meet the provisions of the contract, it will be responsible for free repair or rework.

2. If the project cannot be delivered for use within the construction period specified in the contract, overdue fines shall be paid in accordance with the provisions of this contract on rewards and penalties for advancing or delaying the construction period.

Responsibilities of the contracting party:

1. If it fails to perform its responsibilities in accordance with the provisions of the contract, in addition to the extension of the completion date, it shall also compensate the contractor for any resulting losses. actual loss.

2. If the construction of the project is stopped midway, delayed or reworked due to design changes or design errors, measures should be taken to make up for or reduce the losses. At the same time, the contractor shall be compensated for actual losses caused by work stoppages, delays, rework, reshipping, relocation of personnel and machinery, and backlog of materials and components.

3. If the project is not inspected and accepted, and the contracting party uses it in advance or uses it without authorization, the contracting party shall be responsible for any quality or other problems that may occur.

IV. If the contractor fails to conduct acceptance after the acceptance notice is delivered to ____, overdue liquidated damages shall be paid in accordance with regulations.

5. Failure to allocate project funds as stipulated in the contract, and the contractor’s compensation shall be reimbursed at 30,000 per day of the deferred payment amount in accordance with the bank’s provisions on overdue payment methods.

Article 9 Dispute Resolution Methods

When a dispute arises in a construction project contract, the parties shall negotiate in a timely manner. If the negotiation fails, either party may apply to the urban and rural construction committee at any level or both parties The superior business department will conduct mediation; if the solution cannot be resolved, you can choose item ( ) below:

(1) Apply to the arbitration committee where the building is located for arbitration;

( 2) File a lawsuit directly with the People's Court.

Article 10 Effectiveness and Termination of the Contract

1. This contract is made in ____ copies and the contract attachments are in ____ copies. Party A and Party B shall each hold one original copy. The remaining copies shall be submitted by the contract-issuing party to the ___________ agency and the construction department for filing.

2. This contract will take effect on the effective date when representatives of both parties sign it and affix the official seals of both parties; the project will be completed and accepted to meet the requirements and terminate after the project payment is settled.

3. After the signing of this contract, if the contracting party and the contracting party need to propose modifications, they can sign a supplementary agreement as a supplementary contract to this contract after both parties reach consensus through negotiation.

Contractor (seal): ______________ Contractor (seal): _______________

Address: ____________________________ Address: ____________________________

Legal representative (signature): ___________ Legal representative (signature): ___________

Bank of account: _______________ Bank of account: _______________

Account number: _______________________________ Account number: ____________________

Telephone number: _____________________________ Telephone number: ____________________________

Signing date: _______________ Signing place: _______________ Simple template of project contract contract (5)

Party A (hereinafter referred to as Party A): ____________________________

Party B ( (hereinafter referred to as Party B): ____________________________

In accordance with the Contract Law of the People's Republic of China and other relevant laws and administrative regulations, and in compliance with the principles of equality, voluntariness, fairness and good faith, the two parties shall agree on this decoration project After reaching consensus on construction matters, this contract is concluded.

Project overview

1. Project location:

2. Project name:

3. Decoration construction content: (see attachment " Decoration project budget sheet").

4. Contracting method: ____________________ (contracting work and materials, clearing work, partial contracting).

5. Total price: ￥_________ yuan, capitalized (RMB): ___________________________ Both parties agree that if the construction content or construction materials are changed, this part of the project payment will be calculated separately based on the actual project volume and the agreed unit price. .

1. Contract duration

If the first project payment is paid on time, the construction period will be calculated from _______year__month____ to _______year_ Ending on ____month___, the total number of calendar days is ___ days. If the first project payment is not paid on time, the construction period will be postponed to the next day after the first project payment is received.

2. Method of project payment

1. First payment: After the contract is signed, ___ yuan is paid ___ days before the start of the construction period.

2. Second payment: ___ yuan shall be paid within ___ days from the date of completion of concealed acceptance of wall and floor tile paving and wooden ceiling.

3. The third payment: ___ yuan shall be paid within ___ days from the date of completion of concealed acceptance of carpentry.

4. The fourth payment: The project payment settlement time shall be paid within ___ days from the date of acceptance.

3. Liability for breach of contract

(1) Party A

1. Party A cannot handle material certification on time, and the delay caused will not be included in the construction period and must be compensated Party B signs to confirm.

2. After the completion of a single project, Party A does not accept the work according to the time requested by Party B. The delay caused will not be included in the construction period and must be signed by Party B for confirmation.

3. Party B puts forward various certification and acceptance requirements. If Party A fails to respond for more than three days, it will be deemed as acceptance. Party A will be fully responsible for any quality and construction period problems caused.

4. The delay caused by Party A’s failure to pay the project payment on time will not be included in the construction period.

5. If the construction period is delayed due to the project changes required by Party A and the construction conditions provided are not met, they will not be included in the construction period, and Party B will be given signature approval for the extension of the construction period.

6. If the construction period is delayed for more than 10 days due to Party A's reasons, liquidated damages will be calculated based on the total project price × 2 ‰ × the number of days the construction period is delayed for the excess days.

7. If Party A fails to pay the settlement amount on time and is overdue for more than 10 days, liquidated damages will be calculated based on the unpaid amount × 3‰ × the number of overdue days.

(2) Party B

1. Make a construction progress plan according to the project and strictly implement it. If it is caused by Party B and exceeds the construction period by more than 15 days, fines will begin to be calculated based on the total amount of the project. The price × 2‰ × the number of days exceeded will be used to calculate the penalty for breach of contract.

2. If there are quality problems during the project, Party B will bear full responsibility.

3. If the materials provided by Party A should be qualified products that meet the design requirements and the acceptance standards must be adjusted, Party A must sign and approve them. If there are quality problems caused by Party A that are not approved by Party A, Party B will be responsible for all responsibility.

4. If Party A fails to pay the project price according to the contract, Party B has the right to stop the work until Party A pays and resumes construction.

5. Party B shall be responsible for safety during the construction process.

IV. Basis for settlement

1. Contract attachments (1. Budget; 2. Project schedule; 3. Quality standards)

2. Each Material confirmation, quality acceptance, construction period and change visa form.

5. Follow-up service and resolution of quality disputes

This project is constructed according to excellent standards and has a one-year warranty. After the project quality warranty period, if there are material quality problems that require repairs, the following procedures must be followed: Method of handling:

1. If Party A provides materials, Party A and the material merchant will report the repair and solution on their own.

2. If the material merchant cannot solve the problem, Party A needs Party B to assist in repairs, and the repair costs will be borne by the material merchant.

3. If a quality dispute occurs between the two parties, after the negotiation fails, the party raising the quality objection shall pay the testing fee or appraisal fee in advance, and both parties must jointly entrust a qualified home improvement quality appraisal agency to conduct testing or appraisal. Appraisal: quality responsibility is determined based on the test or appraisal results, and the responsible party bears the testing or appraisal costs. The period of commissioned testing or appraisal will not be included in the construction period.

6. Dispute Resolution If there is a dispute that cannot be reconciled, both parties can submit a request to the People's Court where the decoration is located for legal resolution.

7. Supplementary Provisions This contract is made in two copies. Party A and Party B each hold one copy. The signature shall take effect immediately.

Party A (with seal): ______________ Party B (with seal): ______________

ID number: ____________________ ID number: _______________

Opening bank/account Name:_____________

Account number:_______________