Rural self-built house contract 1 agreement
Owner (Party A):
Contractor (Party B):
Party A entrusts Party B to build a two-story brick-concrete residential building. In order to clarify the rights and obligations of both parties in the construction process, the following agreement is reached through consultation:
First, the main project of private house.
Second, the construction method; Party A will contract out the main residential project to Party B in the form of contracting.
3. Construction period: the construction period is 60 days, and the commencement date is calculated from the date of signing the contract.
Four. Project price: 320 yuan in square meters.
Five, construction safety requirements and quality responsibility:
1. Party B must take strict safety protection measures in accordance with the safety construction specifications and technical requirements, pay special attention to safety construction in the construction process, put an end to all accidents, and bear the responsibility for accidents caused by inadequate or ineffective safety measures and all expenses arising therefrom.
2. Party B shall carry out the construction according to the construction operation rules, and shall not cut corners. If there are any engineering quality problems (such as the main wall is not perpendicular to the horizontal ground, the wall is uneven and cracked; The main column is not perpendicular to the horizontal ground, broken or exposed; If the cantilever beam is broken or exposed, all losses shall be borne by Party B after appraisal by relevant departments.
6. Delay in construction period: Party B shall not delay the construction period without justifiable reasons. If the completion date is delayed due to the following reasons, the construction period can be extended accordingly after being confirmed by Party A. ..
1, shut down due to power failure, rain, etc. ;
2. Force majeure;
3. Other circumstances in which Party A agrees to postpone the meeting.
Seven. Payment terms:
1. After Party B's foundation is completed, Party A shall pay off the foundation fee and pay 20,000 yuan in advance for the project.
2. After the completion of the bottom roof, if there is no quality problem, Party A will pay the project price of 20,000 yuan only.
3. After the roof pouring is completed, if there is no quality problem, Party A shall pay the project cost of 10000 Yuan only.
4. After the external wall painting is completed, if there is no quality problem, Party A will pay the project cost of 5,000 yuan.
5. After the interior wall painting is completed, if there is no quality problem, Party A will pay the project cost of 5,000 yuan only.
6. After the whole project is completed, if there is no quality problem after a rainy season next year, I will pay it in one lump sum in August.
Eight. This contract is made in duplicate and shall come into effect after being signed by both parties. After taking effect, both parties must abide by it. Matters not covered in this contract shall be settled by both parties through consultation.
Party A (signature): Party B (signature):
Rural self-built house contract agreement II
Owner: (hereinafter referred to as Party A)
Person in charge of the contract: (hereinafter referred to as Party B)
Party A builds a private house in _ _ _ _ _ _ _ _.
1. Contracting method: the project is contracted without contracted materials, and non-recyclable materials such as steel, cement, sand and gravel, nails, iron wires and ropes used by Party A are provided by Party A, and various mechanical equipment used by Party B in construction, such as mixers, paddles, winches, vibrating equipment, templates, logs, scaffolding wood, shovels, trolleys, etc.
2. Project content: The main frame structure, indoor plastering, building height and front style required by Party A shall be completed continuously from above 0.00, and the construction shall be carried out according to the urban construction design drawings, and the indoor buildings shall be constructed according to the design requirements of Party A, including the layout of kitchen and bathroom.
3. Project quality: Construction shall be carried out according to regulations. The quality requirements include straight wall, full brick grouting, vertical and flat beams and columns, and sufficient strength. Both ends of the steel bar are bent at an angle of 135.
4. Responsibility of both parties: During the construction process, if Party A's guidance error causes all losses, Party A shall take care of itself and compensate Party B for labor losses; In the process of construction, if Party B is forced to rework due to its own mistakes or weak formwork support, Party B shall compensate all material losses, which will be deducted from the project payment when the project is settled.
5. Settlement payment method: The project settlement is calculated according to the actual construction area of national standards, and Party A pays Party B RMB per square meter of construction area. After all the projects are completed and accepted, all of them will be settled and the completion payment will be paid.
6. Safe construction: Party B's construction team must pay attention to technical quality, carry out safe and civilized construction, and carry out construction according to specifications. Party B shall be responsible for quality accidents and personal safety accidents during construction.
7. Construction period: During the construction period, it is required to complete all major contracted projects within one month.
8. If there are any matters not covered in this agreement, both parties shall settle them through negotiation or according to the Contract Law.
9. This agreement is made in duplicate, one for each party and signed by both parties. After the project acceptance, it will be automatically terminated after the project payment is settled.
Signature of Party A: Signature of Party B:
Year, month, sun, moon, sun.
Rural self-built house contract agreement 3
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
In accordance with the Contract Law of People's Republic of China (PRC) and other laws and regulations, and in line with the principles of equality, mutual benefit, fairness, honesty and credibility, this contract is concluded through friendly negotiation between both parties for mutual compliance.
I. Overview of the Project:
1, project name: _ _ _ _ _ _
2. Project contracting forms: contracted projects, contracted materials, contracted quality, contracted duration and contracted safety.
3. The construction period is 7 days, counting from the commencement date determined by Party A..
4. Building structure: frame structure, with a building area of about 280 square meters.
Two. Scope and requirements of project contracting: construction shall be carried out according to the requirements of construction drawings.
Three, the project quantity, price settlement and project payment:
1. Provisional total price of the project: the provisional total price is used to pay for the project.
2. Design changes, project additions and deletions, and others recognized by both parties: all are subject to the contact sheet signed by Party A, and the total project cost is adjusted.
3. Payment method of project funds: 30% of the project funds will be paid after the contract is signed, 65% of the project funds will be paid after the completion acceptance, and the remaining 5% will be used as the project warranty fund. The warranty period shall be calculated from the date of completion acceptance, and the project warranty fund shall be paid in full one month later.
Fourth, the project quality:
1. The quality of this project is qualified, and the first acceptance is guaranteed. If the acceptance is unqualified due to Party B's reasons, the construction party shall not only unconditionally rework, but also bear the penalty of 5% of the contract amount.
2. The acceptance of the unit project shall be jointly conducted by Party A and Party B, subject to the written report issued by Party A..
3, all the materials needed for the project must have a warranty and certificate, and conform to the requirements of the construction drawings and construction specifications.
Verb (abbreviation of verb) construction cycle:
1. After the contract is signed, the construction period of this project shall be executed in strict accordance with the construction progress plan provided by the general contractor, and Party B shall actively contact and connect and make preparations for production and installation. And according to the requirements of civil construction progress, ensure that the project completion plan will not be delayed due to Party B's reasons.
The responsibilities of both sides of intransitive verbs:
1. Party A's responsibilities:
(1). Before starting work, if Party A really needs to change the building structure, it must be confirmed first.
(2) Party A shall provide Party B with necessary equipment such as water and electricity. , and explain the matters needing attention.
(3), do a good job in the construction of temporary use of public parts and the coordination of surrounding relations.
2. Party B's responsibilities:
(1), make on-site disclosure of Party A's construction drawings or instructions, and work out the construction plan and progress.
(2) Designate a special person to perform the contract. Organize the construction according to the requirements, ensure the quality and quantity, complete the construction tasks on schedule, and solve all matters that Party B is responsible for.
(3), strictly implement the relevant construction management regulations, and shall not be a nuisance or pollute the environment.
Seven, production safety and fire prevention requirements
1. During the construction period, Party B shall take necessary protective and fire-fighting measures to ensure the safety of construction personnel and surrounding areas. In case of any safety accident during construction, Party B shall bear all the responsibilities.
2. During the construction period, Party B shall strengthen the safety awareness education for the construction personnel, so as to achieve civilized construction and meet the requirements of the specification.
Eight. responsibility for breach of contract
After the signing of this contract, if either party fails to perform the terms of the contract or the terms in the bidding documents, causing economic losses to the other party, the breaching party shall compensate the other party for the direct economic losses.
Nine, tangled processing
During the performance of this contract, if there is any dispute between the two parties, both parties can settle it through consultation without affecting the progress of the project. If the negotiation fails. Take legal measures to solve the problem according to the contract.
X. Other matters
1. Matters not covered in this contract. Both parties shall negotiate separately.
2. This contract is made in duplicate, which will take effect after being signed by both parties, and both parties must strictly implement it.
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _ _ _ _
Rural self-built house contract agreement 4
Party A: _ _ _ _ _ _ _ _ _ _ Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ Name: _ _ _ _ _ _ _ _ _ _ _ _ _
Party A has contracted the construction project of the self-occupied house located in _ _ _ _ _ _ _ _.
1. The construction contract mode of this building is Party B's contract and Party A's contract. Party B shall be responsible for the construction and solve all the equipment required for the construction by itself; Party A shall be responsible for all the raw materials used for the construction; the water and electricity expenses required for the construction shall be paid by Party A; and Party B shall be responsible for the accommodation and living of the construction personnel. During the construction, Party B shall pay attention to the construction safety and take full responsibility for the construction safety. All casualties caused by mistakes in the operation of construction equipment and Party B's personnel shall be borne by Party B, which has nothing to do with Party A. If Party B's negligence in the management of the construction site causes personal and property damage to a third party other than the construction personnel, Party B shall bear all responsibilities.
2. The building area of the house to be built is _ _ _ _ _ _ _ _ _ square meters, and Party A will contract out all the building construction projects (including external wall tiling, stairs and their ancillary facilities) including ground beams to Party B.. And the unit price of the main building contracted by Party B is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ 1 square stairs are calculated as two squares. Build a retaining wall on the second floor.
Three. This contract is made in duplicate, one for each party. It will take effect as of the date of signature.
Party A: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _ _ _ _
Rural self-built house contract agreement 5
Signature time:
Signing place:
Party A: _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _
According to China's Property Law, Land Management Law and other relevant laws and regulations, Party A and Party B voluntarily reach the following agreement on the purchase and sale of rural houses through full and equal consultation:
I. Both parties to this contract are _ _ _ _ _ _ _ _ collective members.
Two. Property: The property under this contract is located in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
3. The transaction house is fully funded by Party A, and the land used is _ _ _ _ _ _ group collective land, which can be occupied and used for a long time with the consent of other villagers and village collectives.
Four. Before the house is delivered to Party B, Party A guarantees that:
1. Party A has the full right to dispose of the house under this contract, or has the right to dispose of the house with the consent of other obligees;
2. Except for Party B, the house under this contract has not signed any sales agreement, compensation agreement or mortgage agreement with any third party. Party B has a relationship with a third party due to personal or family debts of Party A, or the third party has no right to enjoy the house due to court judgment;
3. If Party A violates this guarantee, Party A shall pay Party B a penalty of 30% of the total payment under this contract.
5. The knock-down price of the house under this contract is RMB _ _ _ _ _ _ _ _, including the land occupation cost of the house, the building construction cost, the value of ancillary facilities, reasonable appreciation and relevant taxes payable.
Payment of house price by intransitive verb: Party B shall pay all the house price in one lump sum from the date when both parties sign this contract, and remit the money to Party A's account; If Party B fails to pay the house price on schedule, Party B shall pay Party A the liquidated damages for the total house price every day. If Party B fails to pay the house price within days from the date of signing this contract, Party A may terminate the contract without Party B's consent, and has the right to hold Party B liable for breach of contract.
Seven. Delivery of the house: Party A shall deliver the house under this contract and all originals including but not limited to the house homestead use right certificate and real estate license to Party B within days after Party B remits all the house payment to the account provided by Party A according to Article 6, and shall be responsible for vacating the house; If Party A fails to deliver the materials and houses on time, it shall pay Party B RMB liquidated damages on a daily basis until Party A delivers all the materials and houses; If Party A fails to deliver the house within one month after the signing of this contract, Party B may terminate the contract without Party A's consent, and hold Party A liable for breach of contract, except for the reasons why Party B fails to pay the house price.
Eight, after receiving the written notice of Party B's transfer of real estate, Party A shall actively cooperate with Party B to handle the relevant formalities of real estate property right transfer according to Party B's needs; If Party A refuses or delays without reason and refuses to cooperate, Party A shall pay RMB to Party B as liquidated damages every day until assisting Party B to complete the property handover; If the transfer cannot be handled due to force majeure, policies or other reasons unrelated to Party A, Party A has nothing to do with it.
9. After the house is delivered to Party B, all rights and interests of the house (including land, house and ancillary facilities) shall be owned by Party B, including but not limited to compensation for land acquisition and demolition; If Party A receives the above compensation, it shall pay all the money to Party B. If Party A delays or refuses to pay Party B without reason, it shall pay Party B a penalty of RMB yuan in addition to all the compensation.
X. Since the delivery date of the house, all matters related to the house have nothing to do with Party A, and Party A shall not hinder or infringe upon Party B's right to possess, use and dispose of the house for any reason; Party A infringes upon Party B's rights for personal reasons (including but not limited to house sales and personal debts, etc.). , so that Party B can no longer occupy, use or dispose of the house, Party A shall, in addition to returning all the purchase price in this contract, compensate Party B according to the current market price when there is a substantial impact that prevents Party B from occupying, using or infringing Party B's right to dispose of the house.
XI。 Party A shall not sell the house to any third party without the consent of Party B from the date of signing this contract. If Party A violates this Agreement and disposes of the house without authorization, Party A shall return all the purchase price and pay liquidated damages at 100% of the total purchase price.
Twelve. Other matters:
1. Both parties have disputes over this contract, and if both parties can't solve them through negotiation, they should first request the village committee and the sub-district office to coordinate and solve them.
2. Both parties shall invite at least two members of the village collective to be the witnesses of this transaction, and sign this contract with their handprints.
3. The original of this contract is in sextuplicate, with each party holding three copies; It will take effect from the date when both parties sign and press their fingerprints, and it will remain valid.
Party A's (signature and seal) ID number:
Party B's (signature) ID number:
Witness (signature and seal) ID number:
Witness (signature and seal) ID number:
Attached:
Rural self-built house contract agreement 6
Party A:
Party B:
Party A plans to build a house on the basis of the original village, and Party B has been engaged in rural housing construction for a long time, with a certain professional level and popularity. Party A now contracts the house renovation project to Party B for construction, and both parties reach the following contract on the basis of equality, mutual benefit and consensus:
I. House structure and contract scope:
Party A plans to build a one-story bungalow with brick-concrete structure. Party A has completed the laying of foundation and bottom ring beam, and now the ground construction of the house is contracted to Party B. The contracting scope includes the building main body, laying ring beam, painting the roof, plastering the house, pasting porcelain (porcelain on the front wall, sanitary porcelain on the living room wall, sanitary porcelain on the kitchen and bathroom), ground cement calendering, and cement external powder wall on the east side of the house;
II. Valuation area and payment method of the house:
1. Calculation method of area: After the building is completed, both parties shall first measure the length and width of the built building, from the time when the eaves of one building dripped to the time when the eaves of the other building dripped, the area obtained by multiplication minus the bright sky area in the courtyard is the house pricing area. The appraised area of the house is _ _ square meters;
2. Price: Both parties agree that the unit price is RMB/m2 (in words) and the total price (multiplied by the unit price of the house) is RMB;
3. Payment method: Before the signing date of this contract, Party A shall pay Party B RMB (in words) as the down payment, and pay RMB _ _ _ _ _ _ _ _.
Three. Term of contract:
The term of this contract is from year to year. Among them, the main body of the wall building, the roof with beams and beams will be completed 20 _ _ _ _ _ _ _ _ _ _ _ years ago.
Four. Rights and obligations of both parties
1. Party A shall pay the price to Party B as agreed, and provide the building materials such as cement, sand, steel bars, etc. required for the building according to Party B's construction progress;
2. Party A shall provide water and electricity for Party B's use and ensure that water and electricity can be used normally;
3. Party B shall ensure that the project is completed as scheduled according to the design intention of Party A to build the house, and ensure that the quality of the house meets the industry requirements and overall requirements, and the required professional equipment such as mixers, scaffolding, pipes, etc. shall be provided by Party B;
4. During the construction, Party B shall be responsible for the personnel employed by its own headquarters, organize and supervise the construction, and be responsible for the quality of the house. Party B shall actively take safety measures to ensure safe production. In case of any safety accident during construction, all the injuries caused shall be borne by Party B, and Party A shall not bear any responsibilities.
5. Party A does not participate in the construction organized by Party B, but has the right to supervise the construction process of Party B. If any quality problem is found in the house built by Party B, Party A shall communicate with Party B in time and have the right to ask Party B to correct it in time. After Party A accepts the quality of the house built by Party B, both parties sign it, and Party B completes the delivery obligation.
Verb (abbreviation of verb) liability for breach of contract:
1. Party A shall pay the salary to Party B within the agreed time limit. In case of breach of contract, Party A shall pay liquidated damages to Party B for each day overdue;
2. Party B shall complete the construction with good quality and quantity within the agreed time limit. In case of breach of contract, Party B shall pay liquidated damages to Party A for each day overdue;
3. If there is any problem with the quality of the house, Party A has the right to ask Party B to redo or repair it in time. If Party A fails to complete it within three days after notifying Party B, Party A has the right to ask others to repair or redo it, and Party B shall bear the expenses required for removal, repair and rework.
During the construction of intransitive verbs, matters not covered in this contract or changes in contract contents shall be settled through friendly negotiation between the two parties and the intermediary agency, and a supplementary contract may be signed, which has the same legal effect as this contract;
7. This contract shall come into effect after being signed by both parties, in triplicate, one for each party and one for the intermediary, with the same legal effect.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Rural self-built house contract agreement 7 pages
Party A: Name _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Address: _ _ _ _ _ _ _ _
Party B: Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Address: _ _ _ _ _ _ _ _
Party A needs to build a new house because the child is about to get married, and it needs to occupy a little business road of Party B because of the sunshine degree of Party A's original homestead. Through negotiation, Party A and Party B have reached the following construction agreement.
1. Party B agrees that Party A's building will occupy Party B's official roads: Beimi, Nanmi and Simi (see the attached schematic diagram for details).
2. Party A agrees to compensate Party B for the inconvenience caused by occupying public roads.
3. Party A and Party B agree that part of the ownership of Party A's building occupied by Party B's road will always belong to Party B, and the right to use it will always belong to Party A. ..
4. Party A and Party B agree that Party A's building occupies part of Party B's business road, and after Party A demolishes it by itself, the ownership belongs to Party B, but Party B shall not ask Party A to demolish the building.
5. Both parties agree that Party A's building occupies part of Party B's business road. In case of government expropriation or planning and other related matters, the house compensation fee shall be owned by Party A and the land compensation fee shall be owned by Party B. ..
6. This agreement is printed in duplicate by computer, and each party holds one copy, which has the same effect.
7. If there are any deficiencies in this agreement, both parties can supplement it separately.
Party A: (signature and seal)
Party B: (signature and seal)
Person: (signature and seal) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A: _ _ _ _ _ _ _ _ _ (name, ID number)
Party B: _ _ _ _ _ _ _ _ _ (name, ID number)
Party A plans to build a house in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
I. Rights and obligations of both parties
1. Party A is responsible for providing building materials such as lime, bricks, cement, sand, water and steel. According to the construction progress, Party B shall notify Party A to purchase the required materials _ _ days in advance.
2. Party B has mature experience in rural housing construction and is responsible for the construction and delivery of housing achievements. Both parties made it clear that there was no employment relationship between them.
3. All construction machinery, such as mixers and vibrators, and all labor tools, such as templates and scaffolding, shall be brought by Party B, and the expenses shall be borne by Party B. ..
4. The construction period starts from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ In case of force majeure such as rain, power failure and earthquake, the construction period can be postponed.
5. Party B shall strengthen the safety education for its personnel, strictly manage, abide by national laws and regulations, and carry out safe construction. Safety accidents caused by intentional or negligent behavior of Party B's personnel shall be borne by Party B itself, and have nothing to do with Party A.. ..
6. The wages and remuneration of Party B's employees shall be paid by Party B, which has nothing to do with Party A. ..
Second, the quality requirements
1. Party B shall carry out construction according to the principle of quality and quantity of drawings, and strengthen quality management.
3. Important construction procedures: The foundation and pouring must be accepted by Party A before the next procedure can be carried out.
3. Party A has the right to ask Party B to stop work or make rectification when it finds that Party B has cut corners during the construction and is irresponsible for the work that affects the quality of the house.
2. If Party A finds quality problems within one year after the house is completed, Party B must carry out free maintenance.
Three. terms of payment
1. Method of payment: calculated according to the construction area, RMB per square meter.
1. Payment time: the first payment shall be made within _ _ days after the commencement of construction, the second payment within _ _ years, the third payment within _ _ years, and the fourth payment within _ _ days after the house is completed and accepted by Party A. ..
Fourth, the liability for breach of contract
1. If the project quality does not meet the requirements, Party B shall repair and redo it; If losses are caused, Party B shall make compensation. If the Contract cannot be performed due to Party B's reasons, Party B shall bear the liquidated damages of RMB Yuan and compensate all losses caused to Party A due to its breach of contract.
2. If Party B ignores Party A's reasonable requirements, or embarrasses Party A by taking measures such as slacking off and delaying the construction period, it will be regarded as Party B's fundamental breach of contract, and Party A has the right to terminate this contract. Party B shall bear the penalty of RMB yuan.
3. If Party A fails to pay the project price as agreed in the contract without Party B's breach of contract, it shall bear the liquidated damages of RMB (or RMB per day).
Verb (abbreviation of verb) dispute settlement method
1. In case of contract dispute, both parties shall negotiate amicably.
If negotiation fails, both parties may submit the dispute to the people's court for adjudication.
Supplementary clause of intransitive verbs
This contract is made in duplicate, one for each party.
This contract shall come into force as of the date of signing.
Both parties must abide by the above contract. If both parties agree to sign a supplementary contract through consultation, the supplementary contract has the same legal effect as this contract.
Signature of Party A: _ _ _ _ _ _ _ _ _ _ _ _
Signature of Party B: _ _ _ _ _ _ _ _ _ _ _
date month year