A contract must be signed for every labor service, which is also a guarantee for our workers. So what is a labor contract? Now I will sort out rural private self-built house construction contracts for you. I hope you like it!
Rural private self-built house construction contract 1
Party A: _______________
Party B: _______________
Party A plans to build a house in _________. Party B has been engaged in rural house construction for a long time and has a certain professional level and reputation. Party A will now contract the house repair to Party B. The two parties have reached the following contract on the basis of equality, mutual benefit and consensus through consultation:
1. House structure and scope of contract:
Party A plans to build a one-story bungalow with a brick-concrete structure. Party A has completed laying the foundation and bottom ring beams, and will now build the ground floor of the house. The construction is contracted to Party B. The scope of the contract includes building the main body of the wall, laying ring beams, putting on the roof, painting inside the house, and porcelain tiles (porcelain tiles on the outside of the wall in front of the door, porcelain on the inside of the living room wall, and sanitary tiles on the kitchen and bathroom). , ground cement calendering, cement exterior wall on the east side of the house.
2. House pricing area and labor payment method:
1. Area calculation method: After the house is built, both parties first measure the length and width of the house to be built, from one side of the house to the other. The area obtained by multiplying the water from the eaves to the water from the eaves of the house on the other side minus the bright sky area in the courtyard is the priced area of ??the house. The priced area of ??the house is ______ square meters;
2. Price: Both parties agreed that the unit price of labor is ______ yuan/square meter (uppercase ______yuan/square meter), and the total labor cost (house The calculated area multiplied by the unit price) is ______ yuan;
3. Payment method: Before the signing of this contract, Party A pays Party B ______ yuan (in capital letters ______ yuan) as a deposit , Party A pays Party B ______ yuan (capitalized ______yuan) after the ring beams are put on the roof of the main building, and Party A pays ______yuan (capitalized ______yuan) to Party B after the painting is completed and the quality is acceptable. , the remaining balance shall be paid before ______month_________year.
3. Contract term:
The term of this contract is from _________year______month___ to _________year______month___ end. Among them, the main body of the wall construction and the roofing of the beams were completed by _______ month ___, the interior painting, porcelain tiles, cement calendering of the floor, and the cement powder exterior wall on the east side of the house were completed in ________ Completed before _____month___.
4. Rights and obligations of both parties
1. Party A pays the price to Party B according to the agreement, and provides Party B with the cement, sand, steel bars, etc. needed for building the house according to the construction progress. Building materials;
2. Party A shall provide water and electricity used by Party B, and ensure the normal use of water and electricity;
3. Party B shall ensure that the house construction is completed on schedule according to Party A’s design intention The project, and the quality of the house meets industry requirements and general requirements, and the required professional equipment such as mixers, racks, and pipes will be provided by Party B;
4. Party B shall direct the personnel employed during the construction to carry out their respective responsibilities. Party B is responsible for organizing and supervising the construction, and is responsible for the quality of the house. Party B actively takes safety measures and ensures safe production. If a safety accident occurs during construction, Party B will be responsible for any damage caused, and Party A does not bear any responsibility.
5. Party A does not participate in the construction organized by Party B, but has the right to supervise the construction process of Party B. If there are quality problems in the houses built by Party B, Party A shall communicate with Party B in a timely manner and has the right to let Party B Make timely corrections. After Party A inspects and accepts the quality of the house built by Party B, both parties sign, and Party B completes its delivery obligations.
5. Liability for breach of contract:
1. Party A shall pay Party B wages within the agreed period. If there is a breach of contract, Party A shall pay Party B liquidated damages for each ______ day overdue;
2. Party B shall complete the construction within the agreed time limit and ensure quality. If there is a breach of contract, Party B shall pay Party A liquidated damages for each ______ day overdue;
3. If the quality of the house fails If there is a problem, Party A has the right to ask Party B to redo or repair it in a timely manner. If ______ days have not arrived after Party A notifies Party B, Party A has the right to ask others to repair or redo it, including the necessary dismantling, repairs, and redoing, etc. The costs shall be borne by Party B;
6. During the construction process, matters not covered in this contract or changes in the contract content shall be resolved through friendly negotiation between the two parties and the intermediary. A supplementary contract may be signed, which shall have the same legal effect as this contract.
7. This contract shall take effect after being signed by Party A and Party B. It shall be made in triplicate, with A and B each holding one copy and the intermediary holding one copy, and shall have the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
< p> _________year______month___day_______year______month___dayRural private self-built house construction contract 2
Contractor ( (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
Since Party A is constructing a 3-story building in the community area in the south of the city, the bricks of this project will now be laid. Works such as wood molding, steel bar binding (round nails, lead wire, etc.), sand screening, concrete pouring, and racking are contracted to Party B for construction in the form of clean-up work. In order to clarify the responsibilities and facilitate the construction, the two parties reached an agreement through full consultation and signed the following construction contract terms:
1. Contract scope and form:
Party A will The construction work such as masonry, steel bars, wood molding, steel bar binding, concrete pouring, sand screening, and racking will be contracted by Party B in the form of light industry.
2. Excavation and completion date:
Foundation excavation will start from year, month, and be completed on year, month, and day.
3. Project contract payment:
The total project contract payment is RMB 76,000 yuan (76,000 yuan), which is a one-time payment.
4. Project quality:
Party B guarantees the quality of the project and the construction according to the drawings meets the qualified standards. If there are any changes to the drawings, Party B will be contacted for construction based on the changes in the original drawing design (or Party A). The foundation must be touched upright for pouring. It is required that each corner must be connected with an elbow. There are tie bars every 50-60 cm. The frame reinforcement must be 15-16 meters. The foundation must meet the standard. The floor thickness must meet the standard. The folding membrane The film can be folded within the specified time and with the consent of Party A. Each floor must be poured by machine to ensure that it is above 11 cm. Party A invites Comrade Ma Daofeng to supervise the project quality management during the process of Party B's proposal, and requests Party B's cooperation.
5. Material supply:
In order to ensure the quality of the project, Party A must purchase qualified materials. Party B has the right to refuse to use unqualified materials. Two days before a certain material is used, Party B notifies Party A to prepare materials so as not to affect the construction.
6. Project acceptance:
After the foundation, concrete waist hoops and main structure are completed, Party A invites relevant personnel and himself to attend the acceptance inspection in person. The specifications, reinforcement, and Self-inspection of quantity, connection, etc., and if the completion acceptance is qualified, the project acceptance procedures should be issued.
7. Prepayment and settlement method of project payment:
1. Completion of foundation and first floor:
2. Completion of second floor:
3. The roof is completed:
4. The interior and exterior walls are painted:
5. After the project is completed, 5,000 yuan will be temporarily withheld as maintenance money. One year later If there is no quality problem, Party A will pay Party B.
8. Safety in production:
Party B shall abide by operating procedures during construction, strictly prohibit illegal operations, and ensure construction safety. Party A shall participate in project safety and life and property insurance. Party B is responsible for all safety measures or liability accidents within its own construction scope. Any safety accidents or other liability accidents that occur shall be solely the responsibility of Party B and have nothing to do with Party A. Party A assists Party B in handling the accident.
9. Liability for breach of contract:
1. Party B fails to complete the construction on time (except for force majeure factors), such as rainy weather, shutdown for materials, cement maintenance, and installation of floor slabs. If the construction period is postponed due to normal construction, a liquidated damages of 5% of the general contract price will be imposed.
2. If rework occurs due to Party B’s construction reasons, Party B will be responsible for any loss of work and materials.
3. If Party A fails to pay in accordance with Article 7, in addition to the extension of the construction period, a penalty of 5% of the general contract price will be imposed.
10. Others:
The work shed shall be borne by Party B. During the construction, Party B shall implement civilized construction, keep the site tidy, and save Party A as much as possible while ensuring quality. If the materials present are not satisfactory, Party B will be responsible for screening them, and Party A will cooperate closely and provide various conveniences.
11. This contract is made in two copies. Party A and Party B each hold one copy. It will take effect immediately after signature by both parties. Any outstanding matters will be resolved through negotiation.
Party A (Signature):
Party B (Signature):
Date: Year, Month, Day
Construction of private self-built houses in rural areas Contract 3
Contract issuing party: ____________________ (hereinafter referred to as Party A)
ID number: _______________
Mailing address: _______________________
Contact Method: _______________________
Contractor: __________________ (hereinafter referred to as Party B)
Legal representative: ____________________
Mailing address: __________________
Contact Method: _______________________
Party A now needs to build a new house. Under the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction matters of this construction project and entered into this contract.
Article 1. Project Contracting Form
This project is contracted to Party B in the form of a single contractor, and Party B is responsible for the machinery, formwork (clear water wood), and marquees required for the construction work. , safety ropes, cutting machines and other tools. Party A is responsible for auxiliary materials such as dustpans, nails, iron wires, tie wires, and welding rods.
Article 2. Project Contracting Scope
1. Basic engineering: The design and construction drawings shall prevail. The foundation shall be dug to a hard soil layer approved by Party A, and Party B shall also be responsible for backfilling and compacting the foundation.
2. The main project: sub-projects such as brick laying, steel bar production, formwork (clear water formwork), concrete pouring, etc., construction operations shall be carried out in strict accordance with the design construction drawings and the modification plans discussed by both parties.
3. Plastering project: Latex paint is used on the east side of the interior and exterior walls, and wall tiles are used on the south side. Party B is responsible for the putty, and Party A is responsible for the latex paint. If any changes are required, Party A shall notify Party B in advance.
4. Door and window engineering: During the construction process, Party B shall strictly follow the construction requirements to keep the door and window dimensions, and at the same time cooperate with related engineering construction operations.
5. Water and electricity installation project: Party A proposes a plan, and Party A provides the materials and Party B is responsible for the installation. If any changes are required, Party A shall notify Party B in advance.
6. Ancillary and decorative projects: septic tanks and roof pools, cornices, interior and exterior wall painting, floor tiles, doors and windows, large glass, exterior wall horseshoes, skirting and bathrooms. The decoration, ceiling, operating table, and waterproofing of the kitchen are all provided by Party A, and Party B will construct and lay them according to the design construction drawings and Party A's requirements.
7. Based on the actual construction area, the price is 270 yuan per square meter (270 yuan/㎡). Sloping roofs and balconies are calculated at half price according to the national building area calculation rules, that is, one hundred and thirty-five yuan per square meter (135 yuan/㎡). The gate and the wall must be negotiated separately.
Article 3. Quality Requirements
Party B must strictly follow the drawings and the agreement between the parties. The construction quality should comply with the design requirements and the current national construction specifications and relevant standards. Since the construction party If any factors fail to meet the quality requirements, Party B shall bear all losses in addition to its own labor costs. Party B must save materials during construction and shall not cause artificial waste.
Article 4, Contracting Price and Project Payment Method
Party A shall price ______ yuan/square meter per ______ square meter (the building area is calculated according to national standards) Contracted to Party B. ______ million yuan will be paid after the foundation pouring is completed; ______ million yuan will be paid after each layer is capped; ______ million yuan will be paid after the internal and external plastering is completed; ______ million yuan will be paid after the entire house is pasted, and the rest Acceptance must be carried out within one month after completion. The balance shall be settled and paid after passing the acceptance.
However, Party A should deduct ______ yuan from Party B’s project payment as a maintenance deposit, which will be paid after one year.
Article 5. Construction Safety
During the construction period, Party B must do a good job in safety management and safety precautions at the construction site and the safety of other personnel entering and exiting the construction scope. Party B shall be fully responsible for any safety accidents and work-related injuries caused during the operation. Party B shall be solely responsible for all responsibilities for construction workers and other personnel injured, and Party A shall not be held responsible.
Article 6. Liability for breach of contract:
1. If one party fails to perform the contract without authorization, it shall pay the other party ______% of the total project price as liquidated damages, and the breach of contract will cause losses to the other party. , shall also bear corresponding liability for loss compensation.
2. Party B shall complete the construction within the agreed time limit. If the construction period is delayed due to Party B's fault, if the delay exceeds ______ days, the labor cost will be reduced by ______ yuan per square meter per day.
3. Party A shall pay Party B’s project payment regularly as agreed. For every extension of ______ days, Party A shall pay Party B a late payment penalty based on ______% of the current payment payable.
Article 7. Others: Party A shall actively cooperate with Party B in establishing good relations with surrounding neighbors. Party B must calculate and notify Party A in advance of the materials that Party A needs to purchase.
Article 8. Construction period: _________year______month______ to completion on _________year______month______.
Article 9: Unfinished matters: Party A and Party B shall resolve the matter through consultation.
Article 10. This contract is made in two copies. Party A and Party B each hold one copy. The contract will take effect from the date of signature and seal by both parties. It will be completed after the completion of the project and the acceptance and settlement by both parties until the project payment is paid in full. , this contract terminates automatically. < /p>
_________year______month______day
Rural private self-built house construction contract 4
Contract issuing party (Party A):
Contractor (Party B):
After friendly negotiation and consultation between Party A and Party B, Party A decided to entrust Party B to carry out the decoration. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, and in compliance with the principles of equality, voluntariness, fairness and good faith, this contract is signed for mutual compliance.
1. Project: Decoration project.
2. The contracting method is labor contracting.
The total project budget (excluding taxes) is in uppercase: , (lowercase: ¥ yuan)
3. Party A’s request to add or change the project design must be negotiated with Party B, and shall be implemented by If this results in an extension of the construction period, Party A shall bear the responsibility.
4. Party B shall carry out the construction on day, month, year, and complete it before day, month, year. Otherwise, Party B shall pay liquidated damages calculated as one thousandth of the total project cost for each day overdue. Liquidated damages may be calculated in the project cost. Internal deduction.
5. Party A signs and seals the confirmation after approving the construction plan (drawings). Construction should be carried out according to drawings. If the actual dimensions of the construction site do not match the drawings, Party A shall be notified to negotiate for modifications and stamped for confirmation before construction can begin.
6. Party A’s request to change the engineering design shall be notified in writing to Party B for negotiation and implementation. Both parties shall negotiate the changed design and evaluate and confirm compensation for the losses caused by Party B’s working hours and materials. If the owner requires additional items during construction, both parties will confirm the quotation at that time.
7. The quantity of the concealed work shall be measured on-site by representatives of both parties And the settlement will be based on the project quantity provided by Party B. After representatives of Party A and Party B measure the hidden engineering quantities on site but Party A’s representative does not sign for confirmation, Party B will save the handwritten engineering quantity data written by Party A’s representative and use this as the basis for settlement.
8. Party B shall complete the project Within five days after Party A receives Party B's acceptance notice, both parties shall notify Party A and agree to accept it. Both parties shall complete the acceptance inspection within five days from the date when Party A receives Party B's acceptance notice. Both parties shall sign and confirm the acceptance document. If Party A fails to agree with Party B to accept or move in or use the property within five days of receiving Party B's notice, Party A will be deemed to have defaulted that the quality of the project meets the requirements.
9. If force majeure occurs during the construction of this project, the construction period will be interrupted. After the force majeure factors are eliminated, the construction period will resume calculation.
10. The quality warranty period of this project is three years, calculated from the date of acceptance by both parties (Note: Party A will be responsible for any man-made damage).
11. Settlement of the project: Settlement based on the actual amount of work carried out on site, unit price___area___
12. Payment method: prepayment of the project before entering the site 40% of the project price. The second advance payment of 30%. The prepayment of 20% of the project price after the topcoat is completed. The remaining 5% shall be paid in one lump sum within 10 days if the project is accepted. Another 5% will be retained as the warranty deposit. After expiration, Party A shall return the warranty deposit in accordance with regulations.
13. If Party B violates construction regulations, safe operating regulations, fire prevention regulations, environmental protection regulations and other agreements between the parties, Party B shall bear all economic losses caused thereby.
14. The other attachments to this contract will take effect after they are signed by Party A and Party B.
15. This contract is made in duplicate and will take effect upon signature by Party A and Party B.
Party A: Party B:
Representative: Legal representative:
Agent: Agent:
Address: Address: < /p>
Telephone: Telephone:
Fax; Fax:
Account Number:
Date: Year, Month, Day
Date : Year, Month, Day
Rural Private Self-Built House Construction Contract 5
Party A:
Party B:
This Agreement between Party A and Party B Based on the principles of equality, mutual benefit, fairness, justice and good faith, in order to clarify the responsibilities, obligations and rights of both parties regarding the construction, materials and labor of the private house constructed by Party A, after friendly negotiation, both parties are willing to reach the following terms with a view to ** *Abide by the same.
1. Project overview:
1. Project name: Private residence
2. Structural level:
3. Construction location: Lower Xixie Village, Shu Town
4. Construction area: square meters
2. Contracting method:
Covering cleaning work, machinery, equipment and materials, and construction Material.
3. Scope and content of project operations:
1. Cushion, corner, foundation, main body, roof, indoor and outdoor decorative painting, and cement floors upstairs and downstairs.
2. All material handling.
4. Requirements for building materials:
1. Porous bricks:
2. Cement:
3. Steel bars:
p>
5. Quality management:
Quality standards: The quality of the project constructed by Party B shall comply with relevant national and local construction and acceptance standards and the requirements of Party A.
6. Project progress:
Contract duration: from year month day to year month day, the total calendar days are days.
7. Safe and civilized construction:
During the construction process, Party B is responsible for any safety accidents that occur to Party B’s construction workers and has nothing to do with Party A. (The project cost includes the insurance premiums of Party B’s workers.)
8. Settlement price and method:
1. Fixed unit price lump sum: Yuan/square meter, calculated based on the building area (building The area is calculated according to national standards)
2. After the project is completed, the project cost will be retained as the project quality deposit. After the project is completed and accepted, there will be no maintenance or other quality and safety issues, and it will be fully paid within one year.
9. Payment method:
Party A shall pay according to the progress of the project. Party A will pay at the end of the foundation, the main body, and the painting. The payment will be paid after the project is completed and accepted. If there are no quality problems, it will be paid after one year. clear.
10. On-site electricity consumption:
Party A is responsible for the cost.
11. Construction water:
Party A is responsible for the cost.
12. Cancellation and termination of the contract:
1. Cancellation of the contract: If Party B’s labor arrangements and the quality, progress and safety of the construction project cannot satisfy Party A, Party A shall notify Party A in writing. If the notice still fails to meet the requirements, Party A has the right to issue a notice to Party B to terminate the contract and order Party B to withdraw from the site. The completed work volume will be settled at 70%. Settled at the end of the year.
2. Termination of the contract: This contract will be terminated after Party A and Party B have exercised their rights and reasonably performed their respective obligations in accordance with the terms of the contract.
3. For matters not covered by the above contract terms, both parties can add a supplementary agreement, and the supplementary agreement has the same effect as the agreement.
4. This contract is made in duplicate, with Party A holding one copy and Party B holding one copy. It will take effect after both parties sign.
Party A (official seal): _________
Legal representative (signature): _________
_________year____month____day
Party B (official seal): _________
Legal representative (signature): _________
_________year____month____day
5 related articles on construction contracts for private self-built houses in rural areas:
★ The latest 3 articles on private house construction contracting documents
★ Sample contract for construction contracts on privately built houses in rural areas
< p> ★ 5 templates of individual self-built house sales contract★ 4 templates of individual self-built house contract contract
★ 4 templates of private self-built house contract contract
★ 6 templates of sales contract for self-built houses in rural areas
★ Template contract for labor and materials for rural house construction
★ Template agreement for self-built houses in rural areas
★ Ten commonly used self-built house sales contract templates
★ 3 private self-built house contract templates