Current location - Quotes Website - Personality signature - Planting agreement
Planting agreement
Planting Agreement 1 Contractor (Party A):

Labor Service Unit (Party B):

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Construction Contract of Construction Projects and relevant regulations, in order to clarify the rights and obligations of both parties, this contract is signed on the principle of voluntariness, mutual benefit and equality of rights and interests through consultation.

Article 1 General situation of the project

1, project name: _ _ _ _ _ _ _ Greening and Planting Project

2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Project content: plant planting labor settlement package.

4. Labor contract scope: _ _ _ _ _ _ _ Party A contracts plant planting services within the scope of greening planting project.

5. Duration of the labor contract:

Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _:

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total calendar duration: _ _ _ _ _ _ days.

Article 2 Standards and laws applicable to contract documents

Under any of the following circumstances, Party B shall apply for a time-limited visa, and the contract period shall be extended after confirmation by Party A:

(1) was forced to stop work due to irresistible disasters;

(2) Party A changes the planning and design, which affects the construction;

(3) Party A fails to pay the labor service fee on time, which affects the construction;

(4) Temporary water and power cuts have accumulated for more than 8 hours;

(6) Other circumstances agreed by both parties that cannot be attributed to Party B and affect the construction.

6. Engineering quality grade: current national or provincial quality acceptance standards.

7. Number of people engaged in construction by Party B: about _ _ _ _ _ _.

Article 3 Contract Price: This project is subject to a unit price lump sum contract, and the final settlement is based on the actually completed workload and the unit price agreed in the contract.

1. Applicable laws and regulations: current laws in People's Republic of China (PRC) and local regulations of the project location;

2. Applicable standards and specifications: current national and local standards and specifications for this project;

Article 4 the work before construction

1. Party A is responsible for contacting the contractor's owner (hereinafter referred to as the owner) to handle the construction permit, road occupation, sewage discharge and temporary construction planning procedures. Party B is responsible for night construction and other necessary construction procedures.

2. Party B shall be responsible for the preparation and construction of production, living and temporary facilities before construction, and shall not affect the construction, otherwise it shall compensate all losses caused to Party A.. ..

Article 5 Party A's responsibilities

1, set up a project management team suitable for the project and implement the overall organization and management of the project;

2, responsible for the preparation of construction organization design, project management objectives, supervision, inspection and acceptance of the implementation of project quality, safety, time limit for a project and civilized construction;

3, responsible for engineering survey positioning, settlement observation, technical disclosure, unified arrangement of technical file collection, completion acceptance;

4. Check the operation of Party B's construction equipment, the storage and use of materials at any time, and check the valid certificates and certificates of Party B's on-site management personnel and operators. When Party B violates the regulations or fails to meet the required standards, it has the right to require Party B to carry out rectification and maintenance, and the corresponding expenses shall be borne by Party B.:

5. Be responsible for reviewing the construction labor budget, material plan and various reports prepared by Party B;

6, responsible for the work contact with the owner, supervision, design and other units and related departments, coordinate the relationship between the relevant units on the construction site;

7. Handle all kinds of reports and visas of Party B in time. All changes, technical disclosure and related documents submitted by Party A are in written form, and Party A shall reply within 3 working days after receiving Party B's written report. No reply, as the report has been confirmed;

8. According to the engineering situation, Party B needs to increase or decrease the construction personnel to meet the needs of construction and production. Dismantle personnel whose construction quality is unqualified and who violate Party A's management regulations;

9. Make overall arrangements and coordinate to solve the problems of water and electricity consumption for the temporary living facilities of Party B's construction personnel, and the expenses of water, electricity and water and electricity shall be borne by Party B;

10. The person in charge of Party A at the construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 6 Responsibility of Party B

1. Be responsible to Party A for the construction services within the contract scope, and all construction tasks must be completed by our own efforts. It is strictly forbidden to subcontract or subcontract the construction services agreed in this contract; Once Party A discovers subcontracting or subcontracting, Party A has the right to terminate this contract, and the expenses incurred by Party B will not be settled.

2. Consciously abide by laws, regulations and relevant rules and regulations of Party A and the owner. Accept the management, inspection and supervision of Party A and relevant departments. Coordinate with other units on site;

3. Responsible for the preparation of technical measures related to construction services, which shall be strictly implemented after being approved by Party A;

4. According to the requirements of the general progress plan of construction organization design compiled by Party A, submit the labor service operation plan to Party A before 25th of each month, and implement it after being approved by Party A. Submit the statistical report of the project image progress reflected by the completed labor service on 25th of each month. Those who fail to report within the time limit will be deemed to have given up the service fee of this month and will not be audited.

5. Earnestly keep the original records such as construction logs and concealed works of the labor services undertaken, accumulate the construction data completely, clearly, in detail and accurately, provide relevant technical and economic data to Party A in time, and cooperate with filing;

6. Clean up the site before the completion of the project, prepare for the acceptance, provide convenient conditions for the acceptance and participate in the completion acceptance; Actively cooperate with the warranty, and repair the construction quality defects involved in the labor service free of charge in time during the warranty period;

7. Party B's change and visa in the construction process shall be submitted to Party A for approval within 3 working days, otherwise it will not be recognized;

8. Sign for all kinds of documents, changes, technical disclosure, reward and punishment notices and other materials conveyed by Party A on time, and shall not refuse to accept them;

9. Do a good job in the protection of finished products of buildings, structures, underground pipelines and completed projects around the construction site. If the damage is caused by Party B's responsibility, Party B shall bear all economic losses and various fines caused thereby:

10. Stack materials, machines and tools according to the unified planning of Party A; Properly keep and reasonably use the machines and tools, turnover materials and other facilities provided or leased by Party A to Party B;

1 1. Sign a labor contract with each migrant worker according to the national policy and pay the wages of migrant workers according to the terms stipulated in the contract (the wages of migrant workers are made monthly for filing), and bear the disputes caused by this work, or the punishment and responsibility consequences of relevant local administrative departments;

12. Provide the construction personnel with necessary labor protection and safety protection articles (such as safety helmet, work clothes and other related protective articles);

13, the construction personnel entering the site are required to have good ideological quality, good health and skilled technology; /kloc-minors under the age of 0/8, the elderly over the age of 55 and the sick and disabled are not allowed to enter; It is strictly forbidden to use illegal personnel, and Party B shall bear the responsibilities and consequences caused by using the above unqualified personnel.

14. If Party A fails to pay the project payment in time, it can be settled by Party A through negotiation, otherwise all negative responsibilities caused to Party A therefrom shall be borne by Party B. ..

15. Person in charge of Party B at the construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 7 Project Payment and Settlement

1. Party B shall submit the progress output report completed from 25th of last month to 25th of this month on 25th of each month, and Party A shall check with Party B within 5 working days after receiving the report, and pay 80% of the current output value at the beginning of next month. 95% of the settlement amount shall be paid after the completion and acceptance of the contract project, and the remaining 5% shall be paid as quality deposit after the expiration of the warranty period (three months) of the contract project.

2. Party B shall submit the service fee to settlement book within 20 days after all the service projects undertaken by Party B have passed the completion experience;

3. Party A shall, within 30 days after receiving Party B's statement of settlement, review it, and confirm it or propose amendments;

4. Settlement method: the unit price of fixed services is multiplied by the physical quantity or working day or construction area confirmed by both parties for final settlement.

5. See attached table 1 for the standard and content of service fee.

Article 8 Quality and acceptance of labor services

1. When completing the agreed labor service, Party B shall carefully follow the requirements of standards, specifications and design and the instructions of Party A's representative, strengthen internal inspection, adhere to the system of self-inspection, mutual inspection and handover inspection, accept the inspection of Party A's representative and appointed personnel and quality supervision departments at all levels at any time, provide convenient conditions for inspection and inspection, rework and modify according to Party A's requirements, and bear the expenses for rework and modification caused by its own reasons;

2. Party B carefully organizes the construction according to the national construction specifications and quality inspection standards, as well as the construction drawings, design changes and Party A's disclosure, and the project quality all meets the qualified requirements. If the quality is agreed to be excellent, it must meet the excellent standard;

3. Strictly implement the concealed engineering acceptance system. After the concealed work is completed, Party B must collect and record the experience before continuing the construction of the next procedure. For major and complicated concealed works, Party B shall notify Party A for acceptance, and go through the acceptance procedures for concealed works;

4. The project is qualified for completion acceptance, and Party B shall notify Party A in writing of acceptance within 10 days before completion. If Party A cannot attend on time, inform Party B in advance and set another acceptance date;

5. After the project is completed and accepted, Party B shall be responsible for the quality warranty of the construction project for three months, and the maintenance shall be free during the warranty period.

Article 9 Safe construction

1. Party A shall be responsible for the safety disclosure of the projects undertaken by Party B, put forward clear safety production requirements, and conduct supervision and inspection. Party B must conscientiously implement the rules and regulations related to safe construction and strictly abide by the safety operation rules;

2. Party B is responsible for all safety responsibilities in the construction process, and must carry out safe production and civilized construction in accordance with the relevant requirements of the current specifications;

3. Labor protection articles, tools and appliances for personal use during the construction period shall be provided by Party B. ..

Article 10 Emergency Relief

No matter during the project construction or during the warranty period, when an accident, fault or other event occurs in any part of Party B's labor scope, Party A's representative thinks that emergency remedy or repair is an urgent need to ensure normal construction or project safety. If Party B fails to remedy or repair in time, Party A has the right to arrange other personnel to engage in the work. If the work or repair completed for this purpose is Party B's responsibility according to the contract, all responsibilities and expenses shall be borne by Party B. ..

Article 11 Site management

1. The personnel of Party A and Party B shall strictly abide by the site management systems and organize the construction under the unified leadership of the site leader of Party A.. The two sides cooperate closely in planning, progress and material supply to ensure the smooth progress of the construction. The responsible personnel of Party B shall attend all kinds of meetings organized by Party A on time and implement the meeting requirements;

2. Party B shall educate the constructors about obeying the law, ensuring safety in production and caring for property, and designate a special person to be responsible for the on-site safety work and protect the finished products. In case of theft, fighting or damage to finished or semi-finished products on site, Party A has the right to impose a fine of 500-2,000 yuan, and Party B will lose double indemnity;

3. Party B's construction personnel shall remain relatively stable, wear signs when entering or leaving the construction site, and prohibit non-construction personnel from entering or leaving the site and accommodation area.

Article 12 Supply and storage of materials and equipment

1. The quality, variety, specification and model of materials supplied by Party A shall meet the design requirements and relevant standards. If there is any nonconformity, Party B shall raise it when receiving the goods, and Party A shall be responsible for replacing it, otherwise Party B shall bear all rework expenses and quality problems caused by Party B's poor quality acceptance.

2. The materials provided by Party A shall be collected by Party B and kept and used by Party B after delivery. Party B shall strictly plan and manage, accurately provide the planned consumption and use time, and avoid unreasonable inventory occupying funds and affecting project funds, and avoiding unreasonable plans affecting the supply and construction of materials and equipment;

3. After receiving the materials supplied by Party A, Party B shall properly keep them and use them reasonably, and take effective saving measures and limited material control measures to save raw materials;

4. The materials supplied by Party A belong to Party A, and are only used for the project within the scope of labor service operation in this contract. Party B shall not misappropriate or deal with it without authorization, otherwise Party A has the right to deduct the increase.

Thirteenth construction machinery and equipment and turnover materials supply

1. The machinery operated by Party A's personnel shall be managed and maintained by Party A. For the machinery handed over to Party B's personnel for operation, Party B shall handle the handover procedures and be responsible for daily maintenance and custody;

2. Party B's own machinery shall be handled in accordance with relevant regulations;

3. The construction machines and tools provided by Party A to Party B shall be properly kept by Party B, and if damaged or lost, Party B shall be responsible for compensation; 13.4 If the construction machines and tools provided by Party A or Party B cannot meet the construction needs, all losses caused thereby shall be borne by the responsible party.

Article 14 During the warranty period of the project, due to the quality problems of Party B's construction, arrange personnel to enter the factory for maintenance within 2 working days after receiving Party A's notice, and complete the maintenance work within the time reasonably required by Party A, otherwise, Party A has the right to arrange other personnel for maintenance, and the maintenance cost will be deducted from Party B's warranty fund, and the insufficient part will be paid by Party B. During the warranty period, the Regulations on Quality Management of Construction Projects will be implemented.

1. Contents and scope of warranty: contents and scope of engineering labor contract;

2. Warranty period: _ _ _ months from the date when the project is delivered to the property management company designated by the owner after completion and acceptance;

3. Warranty amount: _ _% of the total settlement price;

4. Payment of quality guarantee money: The quality guarantee money will be deducted from Party B's service fee and paid when there is no quality problem after the warranty period expires.

Article 15 the project is suspended or postponed.

Due to policy changes, force majeure and reasons other than the owner and Party A and Party B, the project is stopped or postponed, resulting in the inability to continue the performance of the contract. Party B shall properly protect and hand over the completed projects and purchased materials and equipment; If it is necessary to continue the construction in a safe place, Party B shall carry the project to a safe place according to the instructions of Party A; According to the requirements of Party A, withdraw their own machinery, tools and personnel from the construction site. Party A shall provide necessary conditions for Party B's evacuation, and pay the labor service fee for the completed project as stipulated in the contract.

If the materials purchased by Party B have been ordered, Party B shall be responsible for returning them. Party A shall bear the non-refundable payment for goods and the expenses arising from the return. The specific proportion shall be negotiated by both parties, but the losses caused by failure to return it in time shall be borne by Party B. ..

Article 16 Force Majeure

After the event of force majeure, Party B shall take timely measures to minimize the losses, and notify Party A of the losses within 24 hours, and report the losses and labor costs for cleaning and repairing to Party A within 10 days after the disaster. If the disaster continues, Party B shall report the disaster every 1 day until the disaster ends. Party A shall provide necessary conditions for disaster handling and be responsible for organizing and directing the handling work.

The expenses arising from the disaster shall be borne by both parties;

1, the damage of the project itself shall be borne by Party A and transferred to the owner;

2, casualties by their subordinate units responsible for, and bear the corresponding costs;

3. Party B shall bear the losses caused by the damage and shutdown of machinery, equipment and other articles brought by Party B. ..

Article 17 Liability for breach of contract and arbitration

1. If Party A's representative fails to give necessary instructions, confirmation and approval in time, which affects Party B's construction, Party A shall bear the responsibility and pay Party B the increased expenses;

2. If Party B fails to complete the project within the time limit stipulated in the contract, Party B shall pay _ _ _ _ _ _ _ _ _ _ USD to Party A.

3. If Party B's construction quality fails to meet the design and specification requirements, Party B shall be responsible for rework and free repair, and bear the responsibility for material loss and time delay caused by rework. If both parties disagree with the quality evaluation, the sixth paragraph of this article shall prevail;

4. If Party A fails to pay the payable amount as stipulated in the contract, the liability for breach of contract shall be settled by both parties through consultation;

5. After the signing of the contract, except for the contents that can be dissolved in the contract, neither party may arbitrarily change or dissolve the contract without the consent of both parties. If there is a unilateral change to terminate the contract, causing economic losses to the other party, the responsible party shall bear the responsibility;

6. In case of any dispute arising from this contract, both parties shall negotiate in time. If negotiation fails, you can apply to the construction contract management department for mediation. If mediation fails, both parties shall apply to the _ _ _ _ _ _ _ _ Arbitration Commission for arbitration.

Article 18 Others

1. Party B shall not have any economic and commercial relations with other countries in the name of Party A. Otherwise, all responsibilities and losses arising therefrom shall be borne by Party B. ..

2. When Party B needs a visa from Party A, it must complete the formalities within 5 working days from the date of each activity, and it must be signed by a designated person. The visa is only signed in kind. All expired, incomplete and unqualified visas will be invalid, and the visas handled by Party B through fraud will not only be invalid, but also be punished twice according to the visa amount.

3. Party B shall obey Party A's management, implement Party A's management measures and abide by Party A's rules and regulations.

4. Party A declares that this contract and all its annexes, all agreements and other materials related to the modification, dissolution and termination of this contract must be stamped with the official seal of Party A's legal entity. Party A's agent must hold a valid power of attorney of the legal representative issued by Party A, and his behavior is regarded as valid, otherwise it is invalid.

Article 19 Effectiveness and Termination of a Contract

1. Effective date of this contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Termination date of the contract: When the project is completed and delivered to the owner, all terms will be terminated except the relevant warranty terms. After the warranty period expires, the warranty items are completed and the warranty payment is settled, the relevant warranty terms are terminated.

Article 20 Supplementary Provisions

1. This contract is made in sextuplicate, with four copies for Party A; Party B shall make two copies, all of which have the same legal effect.

2. This contract shall come into effect as of the date when both parties affix their seals, until all subcontracted projects are completed.

Party A: (Seal)

Legal Representative: (Signature)

Authorized Agent: (Signature)

Party B: (Seal)

Legal Representative: (Signature)

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Authorized Agent: (Signature)

Planting Agreement II Party A:

Party B:

Both parties to the agreement jointly set up green seedling planting, and for the benefit of both parties, the following agreement is reached voluntarily through equal consultation:

1. According to the actual situation and current situation of both parties, at the initial stage of establishing the plantation, Party A will contribute 50% cash shares and Party B will contribute 50% shares (including 35% cash shares and 15% technology shares).

2. When the plantation enters the development stage, Party B may request to re-inject the share capital to increase the share capital to below 60%.

3, profit distribution, according to the proportion of invested capital.

4, financial management, the implementation of * * * management, division of responsibilities, mutual supervision, Party A is in charge of cash, responsible for supply and marketing, responsible for receipt and payment, Party B is in charge of data, responsible for accounting, invoice, voucher management, all expenses can only be paid with the consent of both parties, and settled regularly, so as to achieve daily settlement.

The two sides should unite sincerely, discuss things in case of trouble, do not act without authorization, bear joint and several liabilities externally, and share internal risks equally.

5. Matters not covered in this agreement shall have the same effect as this agreement through negotiation between both parties.

6. This agreement shall come into force as of the date of signing. This contract is made in duplicate, one for each party. This agreement is valid for five years, from June 20xx to June 20xx. When this agreement expires, both parties shall give priority to their cooperation.

Signature of Party A:

Signature of Party B:

Date:

Planting Agreement 3 Party A:

Party B:

In order to give full play to the land benefits, the two parties reached the following agreement on the principles of equality, voluntariness, equivalence and compensation:

1. Party A voluntarily cooperates with Party B to plant fruit trees. The land belongs to 28 mu of wasteland owned by Party A, and Party B shall bear all expenses for planting fruit trees. * * * Develop forestry together.

2. If the land is requisitioned by the state, the plants on the ground shall be shared equally by both parties. The land purchased belongs to Party A. Party B shall not interfere.

Third, the liability for breach of contract

(1) Both parties shall abide by the above terms and conditions, and shall not breach the contract, otherwise the breaching party shall pay the other party a penalty of one million yuan and bear all legal responsibilities.

(2) This Agreement is made in duplicate, one for each party, and shall come into effect as of the date of signature by both parties.

Party A (signature and seal):

Party B (signature and seal):

date month year

Planting Agreement 4 Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _

In order to better implement the spirit of the Central Committee, aim at serving farmers, help farmers to become rich and well-off, and put people's livelihood and health in the first place, Party A and Party B have reached an agreement through consultation, and based on the principles of voluntariness, fairness, honesty and credibility, this agreement is hereby formulated for both parties to abide by.

1. Planting place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Planting area and duration: the planting area is _ _ _ _ mu, from _ _ _ _ _ _ to _ _ _ _ _ _ _ _ _.

Three. Franchising fee: Party B shall provide Party A with the franchise fee of RMB yuan per mu.

Four. Rights and obligations of Party A:

1. Be responsible for providing Party B with seedlings, pesticides, fertilizers, vegetable planting techniques, etc.

2. Be responsible for formulating Party B's annual production technology management and operation regulations, and providing technical training, on-site guidance and other services, and have the right to inspect and supervise Party B's vegetable planting sites, propose rectification measures for bases that fail to meet the standards, and require rectification within a time limit.

3. Be responsible for selling the planted vegetables, evaluate the price according to the quality, and assist Party B to sell the harvested vegetables on time.

Verb (abbreviation of verb) Rights and obligations of Party B:

1. Party B provides land, labor and daily management.

2. Carry out planting, fertilization, pesticide application and management in strict accordance with Party A's technical requirements, complete every process of planting vegetables in the planting base on time and with good quality, and notify Party A in time when diseases are found.

3. When selling vegetables, Party B shall transport the vegetables to the purchasing place designated by Party A, and at the same time protect the vegetables to prevent the vegetables from being damaged.

6. When Party A sells vegetables, it shall notify Party B in advance to prepare for picking. Party A and Party B must be present to disclose the price and quantity of vegetables sold at that time and keep accounts on the spot.

7. Party B shall not sell vegetables without Party A's permission. If Party B sells vegetables without permission once, it will be fined ten times the quantity and price of vegetables sold at that time.

Eight, in the production process, in case of irresistible natural disasters, Party A and Party B shall not bear all the economic losses invested by each other, and both parties shall deal with the affected parts in time to minimize the losses.

Nine. Settlement method: On 25th of each month, Party A shall make statistics on the unit price and quantity of vegetables sold by Party B each time and pay them to Party B according to the facts. ..

X during the performance of the agreement, both parties must strictly abide by every right and obligation stipulated in the implementation agreement. If either party breaches the contract, the breaching party shall compensate the observant party for five times the economic loss due to the breach.

XI。 Matters not covered in this agreement and problems arising after the signing of this agreement shall be settled by both parties through consultation on the principle of mutual understanding, mutual accommodation and mutual benefit.

Twelve. This agreement is made in triplicate, one for Party A and Party B and one for file.

Signature of Party A:

Signature of Party B:

date month year

Planting Agreement 5 Party A:

Party B:

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, both parties shall negotiate on the basis of equality, voluntariness. In order to improve the organization and industrialization of farmers entering the market, ensure product quality and safety, and improve market competitiveness, the following agreement is reached on the related matters of periodical purchase of loquat.

Article 1 Basic information:

Article 2 Party A is responsible for providing technical guidance, training and consultation free of charge. Party B shall carry out planting management according to the technical requirements and guidance methods proposed by Party A, and shall not use any pesticides. If it is necessary to control pests, it shall be carried out under the guidance of Party A. ..

Article 3 Quality requirements of loquat: no pesticide residue, no rot, no impurities and no olives.

Article 4 Loquat grade standard:

Article 5 Delivery (delivery) and inspection method: Party B shall deliver the goods to the agreed place within the time limit stipulated in the contract, and Party A shall accept the goods on the spot according to the agreed standards; Agreed place:; Mode of transportation and expenses: The goods (loquat) shall be transported to the place of delivery by Party B at its own expense.

Article 6 Both parties shall settle the accounts with the purchase voucher, and the settlement period shall be _ _ _ _ _ _ _ _ _ _ _.

Article 7 Liability for breach of contract:

1. If one party delays delivery or payment, it shall pay liquidated damages to the other party at the rate of% of the delayed price every day.

2. If the loquat delivered by Party B does not meet the agreed requirements, Party A has the right to request replenishment, exchange or return.

3. If the technical guidance provided by Party A or the planting requirements put forward are wrong, or the qualified loquat is not purchased as agreed, the liquidated damages shall be paid according to the standard of% of the ordered loquat value (quantity × protective price).

4. If the performance is suspended without justifiable reasons or the contract is unilaterally modified or terminated, it shall compensate the other party for the losses caused.

6、________________________________________________________________。

Eighth due to force majeure such as natural disasters, major epidemics, etc., all or part of the liability may be exempted after verification, but the other party shall be notified in time and provided with proof within a reasonable period of time.

Article 9 The conditions for dissolution of this Contract shall be implemented in accordance with the Contract Law of People's Republic of China (PRC).

Article 10 Disputes arising under this contract shall be settled by both parties through consultation or by applying to relevant departments for mediation. If negotiation or mediation fails, bring a lawsuit to the _ _ _ _ _ _ _ court.

Article 11 This contract shall come into effect as of the date of signature and seal by both parties. This contract is made in triplicate, one for each party and one for the record of the industrial and commercial department, all of which have the same legal effect.

Article 12 Other agreed matters:

Party A: Party B:

Authorized Agent: Authorized Agent:

Date of signing: