Site construction contract 1 Party A:
Party B:
1. The renovation area of Party A's dangerous house is 620 square meters. Calculated by 300 yuan, the total investment is1860,000 yuan per square meter.
Second, in order to consolidate the achievements of XX, Party A transformed the original supporting bungalow that was about to collapse into a two-story supporting house. Party B is required to guarantee the quality and not to cut corners. If _ _ _ _ _ _ has quality problems, Party B shall bear all the responsibilities.
3. The front and rear balconies on the second floor are closed, and aluminum alloy windows are installed on the balcony facing the street. The balcony in the yard is not closed. There is a water tank at the top of every two process stairs, with red tiles on the roof and plywood on the ceiling.
Four, all exterior wall paint residue, interior wall is given priority to with paint, sanitary wall and doors and windows brush paint. Make sure the power is on. (The wires must be copper cores, and doors and windows must have screen doors. )
5. Party A is not responsible for all accidents that happen to Party B during the construction (including people fighting over trifles in society, etc.). ) and Party B is fully responsible for all accidents.
Six, half a month after the date of signing, completed within three months. Pay 30,000 yuan at the beginning of the project and 30,000 yuan at the time of delivery. The rest shall be paid by the contractor in advance, and the school shall pay the balance in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Seven, both parties must abide by the contract, the contract shall take effect from the date of signature, the contract is in duplicate, each party holds one copy. The words are unfounded, and the agreement is well-founded.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Site Construction Contract 2 Party A: (hereinafter referred to as Party A) _ _ _ _ _ _ _ _ _ _ _ _
Party B: (hereinafter referred to as Party B) _ _ _ _ _ _ _ _ _
Through friendly negotiation between Party A and Party B, Party A entrusts Party B to build the basketball court for primary and secondary schools in the port. In order to clarify the rights and obligations of both parties in the construction process, this contract is signed through consultation:
First, the project content:
1, fence:100m.
2. Basketball playground (1): 5 13.24 m2.
3. Cement floor in front of the new canteen: 248 square meters.
4. Taiwan Province price: 1 13.7 m2.
5. Culvert: 350m.
6. Open trench:100m
7. Reception room: 17.28 m2.
8. School gate: 1.
9. Retaining wall: 20m, flower pond fence: 80m.
10, flag-raising platform: 1
1, 6 inspection wells.
2. Floor cement for office buildings and teaching buildings:1098m2.
3. See the construction drawing provided by Party B for details of basketball court and fence.
3. Due to the geological reasons of this plot, Party B must deal with the foundation of the fence and bear all expenses to ensure the safe construction and use of the fence.
4. The acceptance standard of the fence shall be subject to the field measurement. The wall height is 2 100, and every 3500 is a span wall.
5. After completing the construction of basketball court and fence, Party B shall do a good job in the fence drainage system to ensure the normal use of the fence.
Second, the project quality:
1. Party B shall construct according to the drawings, with beautiful appearance and project quality meeting the acceptance standard.
2. After Party A confirms the main materials needed for the project, Party B can enter the site for construction.
3. The wall construction contracted by Party B must ensure that the wall does not collapse and crack during the normal use of Party A. ..
Three. Duration: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Fourth, the project price and payment:
1. The contract price of this contract is RMB through negotiation between Party A and Party B.. (All expenses paid)
2. Party A shall pay the price confirmed in this contract to Party B in stages according to the progress (Party A will not accept any form of entrusted payment or transfer payment from Party B).
(1) Within the second day after the signing of this contract, Party A shall pay Party B an advance payment in RMB;
(2) The specific quantities shall be subject to the actual acceptance.
(3) 50% of the completed engineering quantity shall be paid to Party B within _ _ _ days after Party A confirms in writing that the quality meets the requirements;
(4) Pay 80% of the total contract price to Party B within 10 days after all the construction is completed and Party A confirms in writing that the quality meets the requirements;
⑤ After the quality acceptance is completed, Party B shall pay the final payment of the project (Party B shall provide the project invoice). Leave 3% of the total project final accounts as warranty money. After the expiration of the warranty period, Party B shall pay the warranty payment within _ _ _ months after completing all the warranty contents (the warranty period is subject to the negotiation time of both parties, and it is two years, starting from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _).
Five, finished and semi-finished products protection:
1. Party B is responsible for the protection of finished and semi-finished products from the construction site to the project acceptance confirmation.
2. Party B shall formulate specific measures to protect finished products and semi-finished products.
3. Party B shall assist Party A in the project-related work and prevent all kinds of disputes. In case of any dispute, Party B shall negotiate with relevant responsible parties to solve it, so as to ensure the normal progress of the project.
Six, construction management and coordination:
1. Party B shall make a construction plan (specific construction period) according to the characteristics of this project and submit it to Party A for review.
2. In order to strengthen site management, the person in charge of construction shall keep in touch with Party A at the site at any time.
3. Party B shall strengthen the safety and civilized construction education for its construction personnel, consciously abide by the relevant regulations of the local government, consciously abide by Party A's regulations on on-site safety and civilized construction, put an end to safety accidents, public security and criminal cases, and maintain the image of on-site civilized construction. In case of the above events, Party B shall negotiate with the responsible party for settlement.
4. In case of any safety accident during Party B's construction, the responsibility shall be borne by Party B, which has nothing to do with Party A. ..
5. In the process of construction, if the whole project is adversely affected due to Party B's reasons, Party A has the right to claim compensation from Party B, and its losses will be calculated according to the facts (direct and indirect losses), and its expenses will be directly deducted from the project payment.
Seven. Engineering quality warranty and after-sales service: During the warranty period, Party B shall be responsible for free maintenance of faults, and Party B shall go to the site for maintenance within 2 days after receiving the telephone notice from Party A, and Party B shall bear double liquidated damages for overdue maintenance.
Eight. Liability for breach of contract:
1. If Party B fails to carry out the construction according to the quality requirements stipulated in the contract conditions, Party A has the right to temporarily withhold the relevant part of the project payment until Party B's rework meets the quality requirements, and the cost of rework shall be borne by Party B itself, and the construction period shall not be postponed, and the economic losses caused to Party A therefrom shall be borne (the cost shall be calculated in real terms).
2. If the construction period of the fence project is delayed due to Party B's reasons, Party B shall pay Party A a penalty of 100 yuan for each day of delay. If the project quality fails to meet the acceptance standard of national municipal engineering, the price shall be settled at 10% of the total price. And compensate all losses (including direct losses and indirect losses) caused to Party A from this. Party A has the right to terminate the contract directly.
3. Party A can directly deduct the above liquidated damages from the project payment payable.
4. If Party B's serious breach of contract exceeds the time limit confirmed by both parties for ten days, Party A has the right to modify or terminate this contract.
Nine. This contract is made in triplicate, one for Party A, Party B and the Education Commission. It will take effect after being sealed or signed by both parties.
X. Matters not covered in this contract can be confirmed by signing a supplementary agreement by both parties, which has the same legal effect as this contract. The supplementary agreement shall be sealed by both parties, and the design change and visa shall be sealed by Party A. ..
1 1. Any dispute arising from the performance of this contract and the supplementary agreement shall be settled through negotiation. If negotiation fails, either party may bring a lawsuit to the people's court in the place where this contract is performed (that is, the project location).
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Site Construction Contract 3 Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
According to the spirit of General Principles of Civil Law of People's Republic of China (PRC) and Regulations on Construction Project Contracting, Party A agrees to contract this project to Party B through negotiation between Party A and Party B. In order to clarify the rights and obligations of both parties, the following clauses of this agreement are hereby signed for both parties to abide by.
1. project name: longfei aluminum profile sales center in _ _ _ county. Venue: _ _ County Building Materials Market Hospital.
Second, the way of contracting.
Third, the project contracting content
Four. Determination of actual construction area in contract price. When the project is changed, the settlement of the project payment should be based on the actual changed engineering quantity.
5. After the payer enters the site, Party A shall pay Party B 30% advance payment, and pay the project payment after the main body is completed.
Six, the total duration requirements
Seven. Party A's responsibilities
1. When Party A notifies Party B to enter the site, the construction site shall meet the conditions of three links and one leveling.
2. Party A shall pay the project payment to Party B in time according to the contract payment method. If Party A fails to pay the project payment according to the contract, resulting in the construction failure, Party B may stop the construction, and Party A shall bear the losses of the completed project and all economic losses of Party B.. ..
Eight. Party B's responsibilities
1. Party B shall complete the construction within the time limit agreed in the contract and meet the acceptance requirements.
2. Party B shall be responsible for the project quality problems and delays caused by Party B: Party B shall be responsible for repairing and solving the quality problems until they are qualified.
Nine, engineering quality, safety and warranty
1. Party B shall carefully construct according to the drawings, and the project quality shall meet the acceptance standard.
2. All safety accidents caused by Party B shall be borne by Party B. Party A shall not bear any responsibility.
3. After the project is completed and accepted, Party B shall be responsible for the project quality warranty for _ _ _ _ _ _ years.
X. Matters not covered in disputes and solutions shall be settled by both parties through consultation. When mediation or mediation fails, the dispute shall be settled by the following methods:
The first solution: the two parties reach an arbitration agreement and apply to the agreed arbitration commission for arbitration;
The second solution: bring a lawsuit to the people's court with jurisdiction.
XI。 This contract is made in triplicate, one for Party A and two for Party B, and shall come into effect after being signed and sealed by both parties.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Site Construction Contract 4 Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Party A entrusts Party B to carry out the renovation project of _ _ _ _ _ suite, and through friendly negotiation, both parties hereby sign the following contract terms:
1. Project and content: floor, oil wall, cabinet, installation of new lines, etc. See the construction instructions and project budget provided by Party B and approved by Party A for details. ..
Second, the way of contracting: contracting for labor and materials.
Three, the project cost (_ _ _ yuan) is RMB _ _ _ _ _ _ _ yuan.
Four. Settlement method of project payment: within five days after Party B enters the site, Party A shall pay 50% of the project payment to Party B in advance, and the balance shall be paid within one month after the project is completed and accepted.
5. Party B must carry out the construction on time according to the relevant national regulations. If the construction project is unqualified due to the quality of materials or the failure to construct according to the drawings, Party B shall rework it by itself, and all the materials and labor costs used for rework shall be solved by Party B. If Party A proposes to change the ongoing or completed project during the construction period, all the materials and labor costs used for the change shall be borne by Party A. ..
6. If Party A proposes to increase construction projects or change the materials used during the construction period, it must be signed by the person in charge or technical personnel of Party A. ..
Seven. Delivery date: the total construction period is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If Party A prevents Party B from normal construction for any reason, the delay date will be postponed.
Eight. Other agreed matters: _ _ _ _ _ _ _
9. This contract has the same legal effect as the construction instructions and project budget provided by Party B to Party A for approval.
X this contract is made in duplicate, one for each party.
XI。 This contract shall come into effect immediately after being signed by both parties.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Site Construction Contract 5 Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Party A entrusts Party B to install a set of construction equipment according to the needs of engineering construction. In order to clarify the rights and obligations of both parties, this contract is hereby concluded through full consultation between both parties.
I. Overview of the Project
1, project name:
2. Installation location:
3. Name of equipment: construction elevator
4. Equipment model and specification:
5. Equipment manufacturer:
6. Total installation height: 69m.
Second, the way of contracting; Party B shall be responsible for installation, jacking, connection, attachment, disassembly and acceptance.
Third, the contract cost.
1, and the installation cost is 18000.00 yuan per set). The installation is 69 meters (including labor cost and inspection fee).
2. The call fee for each channel is RMB.
Four. Payment method: RMB 65,438+03,000.00 Yuan shall be paid in advance after the first installation, and the balance shall be paid in one lump sum after all the installations are qualified.
Verb (abbreviation of verb) Party A's responsibility
1, responsible for "two connections and one leveling" (access, power supply and site leveling) on the construction site.
2. Pay according to the time stipulated in the contract.
3. Cooperate with the on-site vigilance, and irrelevant personnel and other personnel of Party A shall not enter the work scope without permission.
4. Assign full-time safety officers to supervise and inspect the construction safety of Party B..
5. The driving and command of the elevator in daily use shall be the responsibility of Party A and shall not be compiled by Party B's employees.
Inadvertent Verb Obligations of Party B
1. Provide Party A with a copy of the qualification examination of the installation company's business license and safety production license, and affix the official seal.
2. Preparation of the installation construction plan must be signed and sealed by the preparer, auditor and technical director.
The contents of the plan include:
(1) Project Overview
(2) Preparation before operation
(3) Installation and construction methods and steps
(4) Safety technical measures
(5) Other relevant contents.
3. Party B must provide qualified safety protection equipment (such as safety helmet and safety belt) to the operators.
4. Party B must designate the person in charge of site operation and the person in charge of site safety.
5. Before the installation, Party B has the obligation to provide all kinds of materials (equipment manufacturing license, product certificate and instruction manual) according to the requirements of the construction safety supervision station where the equipment is used. Materials such as foundation concealed acceptance shall be provided by Party A). Construction can only be started after it is approved by the local construction safety supervision station (except for projects that have not been reported for construction).
6. After the equipment installation is completed, on the basis of passing the self-inspection, Party B is responsible for applying to the local construction safety inspection and acceptance center for inspection, and Party A shall cooperate with Party B to provide the required information until the equipment is qualified. For the nonconformities caused by Party B, Party B shall be responsible for rectification; Party A shall be responsible for the unqualified items caused by Party A..
7. Before equipment installation and disassembly, safety technical disclosure must be carried out, and all operators must strictly abide by safety production rules and regulations and operating procedures.
8. Party B shall obey the safety production management of Party A. Party B shall bear legal and economic responsibilities for the corresponding safety accidents during this installation operation.
Seven. supplementary terms
Eight. This contract shall come into effect as of the date when both parties sign and seal it and receive the installation fee from the user.
Nine. This contract is made in duplicate, one for each party, with the same legal effect.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Site Construction Contract 6 Party A:
Party B:
Based on the principle of equality and mutual benefit, and in accordance with the provisions of relevant national laws and regulations, both parties voluntarily reached the following peace agreement on the construction of exterior wall coatings such as exterior walls and roofs (above):
A, the scope of the construction contract:
Exterior wall and roof (above) and other exterior wall coating subdivisional work of this project.
Second, the construction contract period:
1, from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. The contractor shall arrange the construction progress according to the design requirements of Party A, and must unconditionally obey the management, and shall not delay the construction period for any reason. If the construction period is postponed or suspended for various reasons, Party A must agree.
3. The contractor must take sufficient measures to ensure that the contract contents are completed on time, in good quality and in good quantity. Otherwise, the contractor will be fined 20 yuan for every day of delay in the construction period, and bear all the direct or indirect consequences arising therefrom.
Third, the construction contract price:
1. Project unit price: 22 yuan per square meter of the building. (including materials, construction, transportation, etc. )
2. Engineering quantity: The engineering quantity shall be settled according to the actual construction area, change and Party A's visa.
Fourth, the construction quality requirements:
1, the project quality must conform to the current relevant professional norms and standards such as Unified Standard for Acceptance of Construction Quality of Building Engineering (gb50300-20) and Code for Acceptance of Building Decoration Quality (gb502 10-20), and the quality level is above the standard. If the quality of the project fails to meet the requirements, the contractor shall bear all the expenses (materials and labor) arising from re-construction, rework, rectification or re-employment for rectification, and bear all the direct or indirect consequences caused thereby.
2. The exterior wall must be coated with alkali-resistant sealing primer before painting; Putty must be smooth, solid and firm, without pulverization, peeling and cracks. After the putty is dried, it should be polished and cleaned. Water-resistant putty must be used on the wall;
3. All incoming materials shall provide product certificate, performance test report and entry acceptance record;
4, paint finishing engineering should be evenly coated, firm bonding, shall not be missed coating, trainspotting, peeling and powder;
5, grassroots putty must be at least not less than three times, coating surface should be at least not less than three times;
6, the color of the coating, must be uniform, can't appear pan-alkali, bite color, sagging, pimples, sand holes, brush lines and other phenomena; The straightness of decorative lines and color separation lines shall not exceed 1.
7, the main construction process should meet the following order:
Repair-cleaning-filling gaps, local putty scraping-leveling-back coating-main coating-rolling.
The first coat of paint.
The second floor.
The third floor.
8. When painting the topcoat, there shall be no leakage and sagging, and the topcoat shall be dried for the first time before construction.
Verb (abbreviation of verb) Contract method: contracting for work and materials.
Terms of payment for intransitive verbs:
(1), the payment of the project payment depends on the actual situation, but each payment shall not exceed 80% of the completed project quantity.
(2) Pay to 95% of the total contract amount within _ _ _ days after the completion acceptance of single project;
(3) Pay the balance of 5% within _ _ _ _ _ _ years after the project is completed and accepted, without quality problems 1 month.
Seven. Engineering conditions
In order to ensure the engineering quality, Party A must provide the following conditions:
1. The construction foundation surface meets the requirements of relevant specifications.
2. Provide scaffolding required for construction, and both parties shall cooperate with each other when they enter the site for cross construction.
3. Water and electricity required for the construction site.
Eight, safety construction requirements:
1. When Party B's construction personnel enter the construction site, Party A shall give the construction personnel three-level safety education in advance.
2. Obey the management of Party A, abide by various safety management systems, organize construction in strict accordance with safety standards, and accept the supervision and inspection carried out by industry safety inspectors according to law at any time, and accept safety management.
3. Construction quality accidents and personal injury accidents caused by the contractor shall be borne by the contractor.
4. Party B shall organize the construction according to the requirements of civilized construction, keep the site clean and tidy, and pile up the construction waste at the place designated by Party A. After completion, Party B shall transport the construction waste out of the site for treatment at its own expense.
Nine. others
1, the contractor shall not subcontract the contracted project to a third party, otherwise, the resulting project delay will be fined RMB 20 yuan every day, and the employer will immediately terminate the contract.
2, the contractor in a timely manner to deal with this group of workers labor insurance and other required documents, expenses shall be borne by the contractor, otherwise the resulting consequences shall be borne by the contractor, and shall not use this as an excuse to delay the construction period.
3. The Contractor shall not delay the construction period for any reason, including force majeure.
4. During the warranty period, if the contractor is not within the specified warranty period, the employer may entrust other personnel to repair the contract, and the expenses shall be deducted from the warranty fund, and the contractor shall be responsible for the resulting consequences.
X this contract is made in duplicate, one for the employer and one for the contractor.
XI。 This contract shall come into force as of the date of signing.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Seventh Contract Site Construction Employer (Party A):
Contractor (Party B):
According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, combined with the characteristics of decoration in this city, on the basis of equality, voluntariness and consensus, Party A and Party B have reached the following agreement on matters related to this decoration project (hereinafter referred to as the project):
I. Overview of the Project
1, project address: xxx
2. Project Overview: Labor cost of external plaque
Second, the project date
Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Third, the project cost and settlement method:
1. The total project cost is _ _ _ _ _ _ _ _ _ _ _ _ yuan only, excluding tax.
2. After signing this contract, Party A shall pay% of the total cost to Party B, namely RMB.
3. Before installing the plastic characters, Party A shall pay% _ _ _ _ _ _ _ _ of the total cost to Party B..
Fourth, engineering changes.
During the construction period, if the project scale, construction method and investment change, and the project cost is adjusted due to technical changes, the increase or decrease amount shall be agreed by both parties, and the construction period shall be postponed.
Verb (abbreviation of verb) liability for breach of contract
1. If the project is stopped halfway or the construction scheme is changed due to Party A's reasons, Party A shall compensate Party B for the cost of stopping work, slowdown and material loss.
2. Party B shall be responsible for the overdue delivery caused by Party B..
3. Party A shall be responsible for the shutdown and slowdown caused by Party A's failure to handle relevant formalities.
Intransitive verb others
This contract is made in duplicate, one for each party, with the same legal effect. The annex to the contract is an integral part of this contract.
After this contract is confirmed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall re-evaluate the supplementary agreement after consultation.
Validity of the contract: The contract shall be valid after sale after the final payment is paid and the after-sale warranty agreement is signed. Before paying the final payment, all the construction projects of Party B shall be owned by Party B, and the final payment shall be handed over to Party A for use.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _