Simple design contract 1 Party A (the entrusting party): _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (trustee): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
In view of the fact that Party A's cooperative customer () has his own intention and concept requirements for handbag style design, Party A hereby entrusts Party B to design handbag style for this customer. Based on the principle of friendly cooperation, Party A and Party B have reached the following special entrustment agreement:
1. Party B shall design the handbag style according to the demand style of Party A's cooperative customers;
Second, the handbag style entrusted by the style and quantity requirements:
Third, the entrusted design fee:
1. Prepayment: The design fee of each handbag is calculated and paid at 30% of RMB, that is, RMB (in words);
2. Post-payment: After each handbag designed by Party B is put on the market and the corresponding order is obtained, Party A shall pay Party B the post-payment according to the commission of the order sales, and the post-payment shall be% of the sales.
4. Party B shall, within _ _ _ working days, design the first draft according to the intentions and ideas put forward by Party A's customers on the entrusted design, and submit it to Party A's customers for approval. According to the examination and approval opinions of Party A's customers, Party B shall complete the final draft design within working days.
5. After Party B completes the above handbag design, the ownership, use right, publishing right and modification right of the works belong to Party A, and Party B reserves the right of signature of the works.
The above-mentioned entrustment design contract is applicable to this agreement, but the terms of this agreement are only applicable to the design of the customer's handbag series. If there are any clauses that conflict with the entrusted design contract, this agreement shall prevail.
Party A: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Date: _ _ _ _ _ _ _ _ _ _ _
Article 2 of the simple design contract: Party A (the entrusting party): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (trustee): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ Co., Ltd. (hereinafter referred to as Party A) aims to unify and enhance the storefront and product image of _ _ _ _ (hereinafter referred to as Party B).
In order to create a better sales environment for Party B, both parties have reached the following contract through consultation on the principles of voluntariness, equality and mutual benefit:
1. From the date of signing this contract, Party A shall be responsible for providing Party B with the overall design and decoration of the store.
Decoration contents include:
Design, manufacture and installation of doorplates;
Design, manufacture and installation of product image wall;
Design, manufacture and installation of product display racks;
The formula and painting of the main color in the shop;
Design, manufacture and install hanging flags on the roofs of shops;
Party A shall provide Party B with a set of models, four sets of work clothes and various certificates and product descriptions free of charge.
2. Party B shall pay Party A a renovation deposit of RMB from the date of signing this contract.
3. Within one year from the date of signing the contract, Party B shall not engage in other brands or products that conflict with Party A, otherwise Party B's decoration deposit will be deducted.
4. After a year of cooperation between Party A and Party B, Party B can well maintain Party A's product image, and there is no breach of contract. Party A will refund Party B the decoration deposit in full (in the form of floor cash).
5. This contract is made in triplicate, one for Party A and one for Party B. ..
6. The modification of this contract shall be settled by both parties through consultation.
7. This contract shall come into effect as of the date when both parties affix their seals, and shall be terminated on _ _ _ _.
Party A (seal): _ _ _ _
Party B (Seal): _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _
Article 3 of the simple design contract: Party A (the entrusting party): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (trustee): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
This contract is signed by both parties through consultation.
1. The entrusting party entrusts the contractor to provide entrusted design services for the following projects:
/
2. Service category: XXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXX
2. The wording and terms of this contract are synonymous with the contract conditions and relevant annexes of the entrusted design of construction projects.
Three. The following documents are an integral part of this contract:
Standard clauses of contract for entrusted design of construction projects.
Four. The Client agrees to pay the Consultant's normal service fee according to the following calculation method, payment time and amount:
After the client pays RMB XXXXXXXXX (in words: XXXXXXXXX only, including XXXXXXXXX) to the undertaker in one lump sum, the undertaker begins to provide the entrusted design service, and provides the entrusted design drawings and construction design scheme before XXX.
Verb (abbreviation of verb) The entrusting party agrees to pay remuneration to the undertaker according to the time limit, method, currency and amount agreed in this contract.
The entrusted design business of the construction project of this contract shall be implemented from XX 1 day to XX/XX.
Seven. This contract is made in duplicate, with the same legal effect, and each party holds one copy.
Client: (seal)
Organizer: (seal)
Date:
Article 4 of the Simple Design Contract: Party A (full name): _ _ _ _ _ _ _ _ _ _ _ _
Party B (full name): _ _ _ _ _ _ _ _ _ _ _
In accordance with the provisions of the Civil Code of People's Republic of China (PRC) and relevant laws and regulations, Party B accepts the entrustment of Party A, and through negotiation, both parties sign this contract and abide by it jointly:
I. Entrust design contents:
All graphic design related to the project, including but not limited to the following advertising ideas and design products (the following contents are determined according to actual needs).
Second, the design cost.
1. Annual cooperation fee: RMB Yuan only, in words: _ _ _ _ _ _ _ Yuan only.
2. Monthly cooperation fee: RMB Yuan only, in words: _ _ _ _ _ _ _ _ Yuan only.
3, a single project cooperation fee:
Third, the form of charges.
1. Annual fee shall be paid quarterly: Party A shall pay the fee for the first quarter from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. Monthly fee: Party A shall pay a monthly fee of RMB Yuan only to Party B within working days after the signing of this contract. Party A shall also pay the monthly fee to Party B on the th of each month.
3. Cooperation fee for single project: Party A shall pay% of the design fee to Party B after determining the design content, and the remaining% of the design fee shall be paid to Party B within three working days after Party A signs the design draft. ..
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 5 of the Simple Design Contract: Employer (hereinafter referred to as Party A)
Designer: (hereinafter referred to as Party B)
The owner entrusts the designer to undertake the design of footbridges in Buildings A and C of duyun city Galaxy Capital, and the contract is signed by both parties through consultation.
1. Design scale: about 74m2.
2. Design data and documents that the designer should deliver to the Employer: 4 sets of project design drawings approved by the competent department, with electronic documents 1 copy.
Third, the design fee period and delivery schedule:
1, and the design fee is ten thousand yuan (ten thousand yuan only); The design period is within ten days after the signing of the contract.
2. After the designer provides qualified drawings as required, it will be approved by the employer within three days, and 60% of the design fee will be paid to the designer within three days after the employer approves, and the balance will be paid to the designer in one lump sum after the project is completed and accepted.
Four. Responsibilities of both parties:
1. The Employer coordinates the docking work between the designer and the general design unit of the project.
2. The designer shall carry out the engineering design according to the national technical specifications, standards, procedures and the design requirements put forward by the employer, submit the qualified design data according to the progress requirements of the contract specifications, and be responsible for it.
3. The main technical standards adopted by the designer are:
4. The reasonable service life of this design is 50 years.
5. The designer is responsible for modifying or supplementing omissions or errors in design data and documents. In addition to taking remedial measures, the designer shall be responsible for the engineering quality accident losses caused by the designer's mistakes. According to the degree of loss, the designer will compensate the employer, and the compensation shall be implemented in accordance with relevant national laws and regulations.
6. The designer must send personnel to the construction site to cooperate and solve related problems.
7. This contract is made in sextuplicate, four for the Employer and two for the Designer.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 6 of the Simple Design Contract: _ _ (hereinafter referred to as Party A)
Employer: _ _ _ (hereinafter referred to as Party B)
I. Project and Construction Period:
Second, the total project cost (Chinese characters)
Three. Quality standard: it shall be handled according to the detailed construction drawings, specifications and acceptance technical specifications of this project. During the construction process, both parties should do a good job in the completion acceptance of concealed works and subdivisional works. If rework costs are incurred due to non-compliance with quality requirements during construction, Party B shall be responsible for contracting and packaging materials, and Party A shall be responsible for providing materials. ..
Four. Material supply: Party B shall purchase the materials contracted by Party B by itself, and Party A shall be responsible for purchasing the materials provided by Party A, which shall be approved by Party B, and Party A shall pay the total material price, and Party B shall carry out the construction in a safe and civilized manner according to the contract requirements.
Verb (abbreviation for verb) Other matters:
1. Party A shall complete all construction preparation procedures before commencement to ensure the smooth flow of roads, electricity and water on the construction site.
2. Any engineering changes proposed by Party A during the construction process shall be approved by relevant departments. The notice of change shall be issued by Party A. Party A shall be responsible for the increased works and losses due to the change.
3. Party A shall be responsible for the delay caused by Party A, and Party B shall be responsible for the delay caused by Party B. ..
4. If there are any additional items or errors in the design and budget of this project, they shall be revised within the validity period of this contract, and the final accounts of the project shall prevail when the project is settled.
6. This contract is made in duplicate, one for Party A and one for Party B.. This contract shall come into effect after being signed and sealed by both parties, and shall become invalid after the project is accepted and the payment is settled. Matters not covered in this contract shall be settled by both parties through consultation.
Party A (official seal): _ _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 7 of the Simple Design Contract Party A (official seal): _ _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Through friendly negotiation between Party A and Party B, Party A decided to entrust renovation contract to Party B for overall renovation of the house, and signed this agreement, which both parties shall abide by.
I. Project Location:
2. Construction time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Third, the form and structure: renovation contract's precautions, housing and decoration should not ignore the square meters.
Four. Matters needing attention in renovation contract: Don't neglect the project: see the annex to this contract (how to write it in renovation contract) for details.
Verb (abbreviation of verb) contracting method: Party B must guarantee the quality and specifications of decoration materials according to Party A's requirements, and shall not use them for other purposes without Party A's consent. If Party B uses it for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.
6. Party B is responsible for the construction, and Party A is responsible for supervising the construction.
Seven. Quality standard: The construction quality shall meet the safety requirements, and the details that should be paid attention to when signing the renovation contract shall not be lower than the decoration standard of the same building type, which shall be recognized by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.
Eight. Project cost: Labor cost for materials and decoration is * * *.
Nine. Payment method: After the project is completed and accepted by Party A, if it meets the above requirements of renovation contract electronic version project and design and construction, Party A will pay 65,438+000% and 20% of the construction cost of renovation contract simple version engineering materials, and the remaining 80% will be paid before _ _ _ _ _. If Party A fails to pay the final payment within the specified time, Party A shall pay each payment on a daily basis.
X. payment account number:.
XI。 This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.
Party A (official seal): _ _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 8 of the Simple Design Contract Client (Party A): _ _ _ _ _ _
Organizer (Party B): _ _ _ _ _ _
I. Project Location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Two. Form and structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Third, the project:
Four. Contracting method: Party B contracts materials.
Verb (abbreviation of verb) quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same building type. Both parties agree that the Code for Quality Acceptance of Building Decoration Engineering (GB502 10-20xx) is the minimum standard for quality evaluation; The indoor environmental standards are 10 mandatory national standard for the limit of harmful substances in building decoration materials and the indoor environmental pollution control standard for civil construction projects.
Intransitive verb contract sum: (in words) _ _ _ _ _ _ _ _. After the review is completed, the settlement shall be made according to the facts; The contract payment is a one-time payment.
Seven. Payment method: after the contract is agreed, Party A shall pay 35% of the project price in advance _ _ _ _ _ _ _ _; Pay 40% of the project cost _ _ _ _ _ yuan after the concealed works such as water and electricity are qualified; Pay 20% _ _ _ _ _ yuan after the acceptance of the bricklayer's carpentry intermediate project, and pay the balance of 5% _ _ _ _ _ _ yuan within 5 days after the project completion acceptance.
Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Tel: _ _ _ _ _ _
Tel: _ _ _ _ _ _
Article 9 of the Simple Design Contract Party A: _ _ _ _
Party B: _ _ _ _
Tel: _ _ _ _
Tel: _ _ _ _
Party A entrusts Party B to design and produce the website within the agreed time and pay the design and production fee in full after delivery and acceptance. Amount: _ _ _ _ _ _ _ _ _ _ _ _ _.
After acceptance, Party B shall be responsible for maintaining Party A's website for 3 months, 7x24, and respond within 24 hours for general failures. For more than 3 months, the maintenance fee is 100 yuan each time. If you need to update and modify, the fee will be negotiated separately.
The expenses such as domain name and renting website space shall be borne by Party B. 。
Party A has the right to refuse to pay the design fee and production fee beyond the agreed delivery time.
Delivery time: _ _ _ _ _ _ _ _ _ _ _
All intellectual property rights of the website designed by Party B shall be transferred to Party A at the same time after delivery.
According to the terms of this contract, the transaction is reached through negotiation between both parties, with no objection.
Remarks:
After the acceptance of 1. website, if there are any objections, please settle them through consultation within 15 days, and we will not be responsible after the expiration.
Please sign your name within 12 hours. Thank you!
Signature of the Buyer: _ _ _ _ _ _ _
Signature of the Seller: _ _ _ _ _ _ _
Date:
Simple Design Contract 10 Employer (Party A): _ _ _ _ _ _
Contractor (Party B): _ _ _ _ _ _
Qualification level:
Party A and Party B sign this renovation contract according to the laws and regulations of China after reviewing Party B's decoration qualification. The specific terms are as follows:
1. Project profile: _ _ _ _ _ _ _
2. Project name and location, contract scope, contract method and contract content: _ _ _ _ _ _
3. Duration: _ _ _ _ _ _
4. Engineering quality standard: _ _ _ _ _ _
5. Project cost: _ _ _ _ _ _
6. Payment method: After this contract comes into effect, Party A will directly pay the project payment to Party B in the following ways:
7. After the acceptance of the project, Party B proposes the project settlement to Party A, and sends relevant materials to Party A. After Party A receives the information, such as _ _ _ _ _ _ days.
If there is no objection, it is deemed to be agreed. Both parties shall fill in the project settlement form (see Annex 9: Project Settlement Form) and sign it. Party A shall settle the balance of the project with Party B at the time of signing the contract.
8. After all the project funds are settled, Party B shall issue a formal unified invoice to Party A. ..
9. Liability for breach of contract
1), either party to the contract fails to perform the contract or violates national laws, regulations and relevant policies, and is fined or given.
All economic losses caused to the other party shall be borne by the responsible party and the economic losses caused to the other party shall be compensated. If no losses are caused, 5% of the total contract price shall be paid as liquidated damages. ;
2) Party A shall be responsible for the losses caused by Party A's early use or unauthorized use of the finished engineering products without going through the acceptance formalities;
3) If the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party, go through the contract termination procedures, and be compensated by the responsible party.
The corresponding economic losses of the other party;
4) If Party A fails to pay the second (third) project payment on schedule, it shall pay 1% of the total contract price to the other party as liquidated damages for each day of delay;
5) If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for repairing and the construction period will not be postponed;
6) If the construction period is delayed due to Party B's reasons, it shall pay 1% of the total contract price to the other party as liquidated damages for each day of delay;
10, settlement of contract disputes
If any dispute between the two parties cannot be settled through negotiation, the following _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1. Apply to the arbitration commission where Party A is located for arbitration;
2. Bring a lawsuit to the people's court of the place where the contract is signed.
1 1, other specific provisions.
1). Party B shall be responsible for transporting the garbage generated from the project construction out of the construction site and transporting it to the designated _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Party A shall be responsible for paying the garbage removal fee (RMB) _ _ _ _ _ _ _ _ _ (this fee is not included in the project price);
2) During the construction period, Party A shall hand over the key of the external house door to the person in charge of Party B's construction team for _ _ _ _ _ _ _. After the project is completed and accepted,
Party A is responsible for providing new locks, and Party B is responsible for site installation and delivery.
3) During the construction period, Party B's daily working hours are: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
12, supplementary provisions
1). This contract is signed by Party A and Party B in duplicate, with each party holding one copy. This contract shall come into effect after being signed (sealed) by both parties.
2) After signing this contract, the project shall not be subcontracted.
3) The contract will be automatically terminated after completion.
4) The annexes to this contract are an integral part of this contract and have the same legal effect as this contract.
Party A (signature):
Representative of Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _
Date of signing this contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ \
Signing place: _ _ _ _ _ _
Simple Design Contract 1 1 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Now Party B accepts the design entrustment, and the design project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
I. Entrusting matters
_______________________________________________________
Second, the mode of payment.
1. Within two working days from the date of signing this agreement, Party A shall pay Party B _ _ _ _% of the total cost of the commissioned design. In principle, Party B shall start the design after receiving the payment from Party A. ..
2. After the design is completed, Party A shall sign or seal for confirmation within three days (fax confirmation is equally effective), and after confirmation, Party A shall immediately pay off all the balance of the design fee.
Three. The design time shall be based on the design package and corresponding working methods in Annex 1 of this Agreement, and Party A shall choose the entrusted design form. According to Party A's choice, Party B shall design the first draft within _ _ _ _ _ working days and submit it to Party A for approval. According to Party A's examination and approval opinions, Party B shall complete the final draft design within _ _ _ _ _ _ working days.
Four. Intellectual property agreement
1. Party B enjoys the copyright of the design works, and the copyright of the design works of Party B will be automatically transferred to Party A after Party A settles all the entrusted design fees.
2. Before the balance is paid, Party A has no right to construct. If Party A uses or modifies the works designed by Party B without authorization before the balance is paid off, Party B has the right to pursue its legal responsibility according to the Copyright Law of People's Republic of China (PRC).
3. For the design scheme not adopted by Party A, the intellectual property rights are still owned by Party B. ..
Verb (abbreviation for verb) Rights and obligations of both parties.
Obligations of Party A:
1. Party A shall pay relevant expenses according to this agreement;
2. Party A has the obligation to provide Party B with relevant enterprise information or other relevant information;
Rights of Party A:
1. Before Party B designs the first draft, Party A has the right to put forward suggestions and ideas on Party B's design to make the works designed by Party B more in line with Party A's corporate culture.
2. After the first draft of Party B's design is completed, Party A has the right to propose amendments to the works designed by Party B during the design process specified in the commissioned design form selected by Party A;
Obligations of Party B:
1. Party B shall design the project according to Party A's requirements.
2. Party B shall deliver the design works on time as agreed.
Rights of Party B:
1. Party B has the right to request Party A to provide relevant enterprise information for Party B's design reference;
2. Party B has the right to require Party A to pay the corresponding amount according to this agreement;
3. Party B has the right to ask Party A not to use the design work before payment.
Liability for breach of contract of intransitive verbs
1. If Party A unilaterally terminates this agreement when Party B has not yet commissioned the design, but the first draft of the design work has been completed, Party A has no right to demand a refund of the prepaid fee; After the completion of the first draft of the design work entrusted by Party B, if Party A unilaterally terminates the agreement, it shall pay all the design fees.
2. If Party B terminates the agreement in advance without justifiable reasons, all the fees collected shall be returned to Party A. ..
Seven. Force majeure factor
If either party fails to perform the agreement due to force majeure, it shall be settled by both parties through consultation. If it is really impossible to adjust, it shall be handled by the arbitration organ or in accordance with the contract law.
Eight. Entry into force of the agreement
This agreement shall be signed and sealed by both parties, and the effective date shall be the last signing date of both parties;
This Agreement is made in duplicate, one for each party, and signed (sealed) by the other party, with the same legal effect;
The annexes to this agreement have the same effect; Matters not covered in this agreement shall be settled by both parties through consultation.
Party A (seal): _ _ _ _ _ _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ _ _ _ _ _
Signature of Party A's Representative: _ _ _ _ _ _ _
Signature of Party B's representative: _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ _ _ _ _ _ _ _
Phone number: _ _ _ _ _ _ _ _ _ _ _
Fax: _ _ _ _ _ _ _ _ _ _ _ _
Fax: _ _ _ _ _ _ _ _ _ _ _ _ _
Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _