Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
According to the relevant provisions of the Economic Contract Law of the People's Republic of China, this contract is signed by both parties through full consultation.
I. Contents of the contract:
1, quality requirements:
2, quality requirements:
3, quality requirements:
Second, the contract amount:
* * * RMB (in words) (in figures)
Three. Payment terms:
1. After signing this contract, Party A shall pay 50% of the total contract amount, namely RMB _ _ _ _ _ (in words: _ _ _ _ _ _ _).
2. After the project is completed, Party A shall pay the balance of the contract to Party B, namely RMB Yuan only (in words: _ _ _ _ _ _).
Four. duties and obligations
1. Party B shall complete relevant design and production work according to Party A's requirements.
2. Party B shall complete it within the specified time (before) and submit it to Party A for signature and approval.
3. Party A shall provide relevant materials according to Party B's requirements, and bear legal responsibilities and economic disputes caused by copyright and literary responsibility.
Verb (abbreviation for verb) property right agreement:
Party A shall not enjoy the copyright until all the expenses of the commissioned design are settled; otherwise, the copyright of the works designed by Party B shall belong to Party B, and Party A shall not enjoy any rights to the works; If Party A uses or modifies the works designed by Party B without paying the balance, Party B has the right to pursue its legal responsibility according to the Copyright Law of People's Republic of China (PRC).
Liability for breach of contract of intransitive verbs:
Due to the great particularity of the design and production work, it needs the designer's careful creation after a lot of research work, and Party B has fully fulfilled the contract at the beginning of the design. Therefore, if Party A terminates the contract in advance, Party B will not refund the advance payment.
Seven. Other matters:
Eight. In case of any dispute arising from the performance of this contract, Party A and Party B shall settle it through friendly negotiation. If no agreement can be reached, it shall be submitted to legal channels for settlement.
This contract is made in duplicate, one for each party, signed and sealed by the other party, with the same legal effect.
Party A (seal):? Party B (seal):
Representative signature: Representative signature:
Address: Address:
Tel: Fax:
Date: date
Model contract of advertising company (2)
Party A: (hereinafter referred to as Party A)
Party B: Advertising (hereinafter referred to as Party B) In order to clarify their respective rights and obligations, Party A and Party B have reached the following agreement on the production and installation of billboards (hereinafter referred to as billboards) contracted by Party B through friendly negotiation in accordance with People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Advertising Law and Regulations on Construction and Installation Contracts.
One: billboard production
1, billboard specifications:
2, material:
3. Requirements:
Two: billboard installation
Installation location:
3. Project cost and payment method
1. Billboard production fee (i.e. total contract price): * * * RMB only, in words.
2. Payment method:
A. When signing the contract, Party A shall pay 30% of the project cost in advance.
B. After the fabrication and installation are completed, Party A shall pay off all the project funds after passing the acceptance.
Four: the construction cycle
1, from the date when Party A prepays the project payment after the signing of this contract. In case of force majeure factors (such as rain, snow, gale above level 4), the construction period will be postponed.
2. If Party B's work can't be completed on time due to Party A's repeated revisions, the extension time can be determined by both parties through consultation.
Verb (abbreviation for verb) Rights and obligations of both parties.
Party A:
1, go through the necessary examination and approval procedures and related expenses for billboard installation.
2. Have the right to put forward suggestions and amendments to Party B's design, so that the works designed by Party B are more in line with the cultural connotation of Party A's unit.
3. Provide Party B with the location of the billboard, and ensure that there is no pipeline in this location, so it can be constructed.
4. Party B has the obligation to provide relevant company information or other relevant information for Party B's design reference.
5. The trees, flowers and plants responsible for the construction site can be moved.
6, according to the provisions of this contract settlement billboard production and installation costs.
Party B:
1. After Party A notifies that the site construction can be carried out, it shall complete the construction and installation within the specified time according to the installation location provided by Party A. ..
2, in strict accordance with the construction plan drawings confirmed by Party A for production and installation. If the site conditions are inconsistent with the construction drawing scheme, it shall be reported in time.
1 page (page ***2 of this contract, stamped with the riding seal)
Please consult Party A for modification and confirmation.
3. Party B owns the copyright of the design works.
Six: About acceptance
1. Party A must organize formal acceptance within one week after Party B's complete production and installation. () If Party A fails to organize the acceptance within one week after completion, Party B can be regarded as Party A's acceptance of the project quality. ..
2. The project quality acceptance is based on the national steel structure building standards, and the advertising structure is made and installed firmly, and the wind resistance level reaches 7.
Seven. Liability for breach of contract:
1. If Party A fails to make payment according to the time stipulated in Article 3 of this contract, Party A shall pay 0.5% of the total contract price as liquidated damages to Party B for each day overdue, and extend the contract period.
2. If Party B fails to complete the production and installation of billboards on time as stipulated in Article 4 of this contract without justifiable reasons, Party B shall pay 0.5% of the total contract price to Party A as liquidated damages for each overdue day.
3. Party B shall ensure that the project quality, structural firmness, wind resistance and other indicators meet the national standards. If it is unqualified, Party B shall bear the rework and corresponding losses.
4. If it is due to Party A's reasons, Party A shall be responsible for stopping work, construction and demolition. Party B has the right to require Party A to pay part or all of the production costs according to the actual construction conditions.
Eight. Responsibility arising from advertising:
1. During the production and setting of this advertisement, if the personal or property damage of a third party is caused by Party B, Party A has nothing to do with it.
2. Party A shall bear all responsibilities for disputes arising from trademarks, portraits, advertising words and other advertising contents provided by Party A. ..
Nine, warranty period:
1. From the date of acceptance, the quality of engineering steel produced by Party B shall be guaranteed for half a year. Party B is not responsible for the warranty for man-made damage.
2. After the warranty period expires, both parties shall re-sign a maintenance agreement for maintenance.
X any dispute arising from this contract shall be settled through friendly negotiation. If negotiation fails, it shall be arbitrated by Changting County Arbitration Commission.
XI。 This contract is made in duplicate, one for each party, with the same legal effect.
12. This contract has legal effect once it is signed.
Party A: Party B:
(Seal) (Seal)
Legal person/authorized representative (signature): Legal person/authorized representative (signature):
Tel: Tel:
date month year
Model contract of advertising company (3)
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
On the basis of equality and mutual benefit, Party A and Party B have reached the following agreement on the sponsorship of "_ _ _ _ _ _" through consultation:
1. Mode of cooperation: (tick "√" below for confirmation)
□ General title □ Subtitle □ Contact unit □ Co-organizer
□ Special advertising unit □ General advertising unit □ Booth number
Two. Return content: See "_ _ _ _ _ _ _" investment proposal.
Three. Payment amount: (Please tick "√" in the "□" below to confirm)
Total title _ _ _ _ _ yuan □ Subtitle _ _ _ _ _ yuan
Co-organizer _ _ _ _ _ □ Co-organizer _ _ _ _ _
Special advertising unit _ _ _ _ _ _ □ General advertising unit _ _ _ _ _ _ _ _
The entry fee is _ _ _ _ _ _ _ _ yuan.
4. Payment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. Payment time: Party B will remit the participation fee to the account designated by Party A within three days after the agreement comes into effect.
Rights, obligations and responsibilities of both parties to intransitive verbs;
(1) After this agreement comes into effect, both parties shall abide by it consciously, and shall not change or dissolve it without written consent.
(2) After receiving Party B's _ _ _ _ _ _ _ _ fee, Party A shall honor all return conditions to Party B according to the contents of the invitation letter. Without the consent of Party B, Party A shall not change the return conditions without authorization, otherwise, Party B has the right to hold Party A liable for breach of contract.
(3) Within three days after this contract comes into effect, Party B shall remit the _ _ _ _ _ _ _ _ _ expenses to the account designated by Party A in time. Without the consent of Party A, Party B shall not delay the payment time without authorization, otherwise, Party B shall pay _ _ _ _ _% of the total cost as liquidated damages.
Seven. Other terms: _ _ _ _ _ _.
Eight. For matters not covered, both parties can sign a supplementary agreement through friendly negotiation, and the supplementary agreement has the same legal effect as this agreement.
Nine. This agreement is made in duplicate, one for each party, and shall come into effect as of the date of signature or seal by both parties.
Party A (seal): _ _ _ _ _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _