Natural Gas Installation Contract Template

As people’s legal awareness increases, there are more and more interest disputes about contracts. The purpose of signing a contract is to protect the interests of both parties and avoid unnecessary dispute. There are many things to note when drafting a contract. Are you sure you know how to write one? Below are the natural gas installation contract templates I have collected and compiled. I hope it will be helpful to everyone.

Natural gas installation contract 1

(Party A): _________

(Party B): _________

In order to clarify the gas management between the supplier and the user The rights and obligations in installation, gas supply and use are governed by the "Contract Law of the People's Republic of China", "Gas Management Regulations of Jiangsu Province", "Siyang County Urban Pipeline Natural Gas Project Construction Management Implementation Measures" and "Si Price Engineering [20] No. 8" document and other laws, regulations and rules, both parties have reached consensus through consultation and signed this contract for mutual compliance.

Article 1 Gas supply type and gas supply address

(1) Gas supply type: natural gas

(2) Gas supply address: ___ City A District 1-12# Building

Article 2 Civil pipeline natural gas construction projects, material fees and payment methods:

(1) Civil pipeline natural gas construction projects, material fees (hereinafter referred to as construction Total fee): The area of ??the community is 48,323.47 square meters (based on the residential commercial housing sales area approved by the housing management office), 22 yuan per square meter, totaling RMB 1,063,116.34.

(2) Civil pipeline natural gas construction projects, material fees and payment methods: Within seven days of signing the contract, Party B shall pay a deposit of zero yuan in advance, and Party A will enter the site for construction. Pay 15% of the total construction fee of the community within 5 working days, calculated as RMB 159,467. After Party A completes the entrance to the house, Party B shall pay 30% of the total construction fee of the community within 5 working days based on the project invoice issued by Party A. After completing the courtyard pipeline, Party B shall pay 45% of the total community construction fee within 5 working days according to the project invoice issued by Party A, calculated as RMB 478,402 yuan, and the balance of RMB 106,313.34 shall be paid by Party B according to the project invoice issued by Party A. Pay in full before ventilating.

Article 3 Engineering Design and Installation Projects

(1) Engineering Design: After Party B provides the engineering technical information required for the project, Party A will carry out gas engineering design, and according to the design The plan is to be constructed according to Party B’s project progress requirements. During the construction period, Party B shall provide construction convenience to Party A.

(2) Installation project: The residential pipeline and courtyard pipe network supporting project, and install a gas meter, a valve in front of the meter and a valve behind the meter for Party B users, and the pipelines are connected to The location where the stove is used (excluding gas stoves used by users). Party A is responsible for cleaning up the garbage generated by Party A during the construction process, and shall not damage the main structure of the house built by Party B. If there is any damage, Party A is responsible for repairing it.

Article 4 Rights and Obligations of both Parties

(1) Rights and Obligations of Party A

1. Responsible for the design and installation of all works of the project .

2. Party A shall reasonably arrange the gas construction period based on the progress of the main project of Party B’s house and the written notification requirements.

3. Party A is responsible for the repair and maintenance of the pipeline network gas supply facilities and bears the resulting costs.

4. Party A will debug the gas supply after signing a safe gas supply agreement with the tenants.

5. Responsible for providing a complete set of completion drawings and other completion documents that meet the archives filing requirements.

(2) Rights and obligations of Party B

1. Provide Party A with the engineering and technical data (electronic version) required for the project free of charge to prepare for Party A’s design and construction.

2. Responsible for the coordination of the project with other construction units, and provide free construction conditions that meet the entry requirements.

3. During the construction period of the project, Party A will be provided with water, electricity and a place for stacking materials, and the resulting costs shall be borne by Party A.

4. Pay construction fees to Party A according to the time limit and proportion stipulated in the contract.

5. Party B notifies Party A in writing to start construction according to the progress of the project image, and Party A reasonably arranges the construction according to the construction progress of Party B's building. If Party B fails to notify Party A in writing to enter the site for construction and misses the construction time, Party B will be responsible for solving the construction difficulties caused by this.

Article 5 Liability and Compensation for Breach of Contract

1. Because Party B cannot provide the information required for the construction of the project on time or fails to pay the money as agreed in the contract, the natural gas construction period is delayed or costs are incurred. If the contract cannot be executed on time, Party A will not be held responsible, and Party B will compensate for the resulting losses.

2. If this contract cannot be executed on time due to Party A’s reasons, Party A shall bear the corresponding responsibility.

3. If this contract cannot be executed due to force majeure factors, neither party will bear responsibility.

4. If any dispute arises between the two parties regarding the relevant contents of this contract, it will be resolved through friendly negotiation.

If negotiation cannot be achieved, the matter can be resolved through other legal channels.

Article 6 Contract Execution Period

1. Party B shall provide Party A with the technical data required for the project within 10 days after the signing of this contract.

2. Party A will reasonably arrange construction according to Party B’s project progress after receiving Party B’s notice of entry for construction.

Article 7 Other Agreements

Matters not covered shall be governed by relevant gas management regulations.

Article 8 This contract is made in four copies, with each party holding two copies. It will take effect after signature (seal).

Party A: ____________

Party B: ____________

Date: Natural Gas Installation Contract 2

Party A: ____________________ (Principal Party) < /p>

Party B: __________________ (the entrusted party)

According to the "Contract Law of the People's Republic of China" and the "City Gas Management Measures" of the Ministry of Construction ([______] Article ____ No.), the __________ Provincial People's Government's "__________ Provincial Gas Management Measures ([_____] No.___) and other relevant regulations, in order to ensure the standardization of urban roads and residential courtyard construction, after full consultation between Party A and Party B, the gas management measures for natural gas The following agreement has been reached on the installation of pipelines into homes:

1. Party A entrusts Party B to collect installation fees for natural gas pipelines from residents who voluntarily use natural gas in the __________ community constructed or managed by Party B.

2. Project name, project address, project scope, contract amount, project period

(1) Project name: __________________ natural gas pipeline project.

(2) Project address: _________________________________________

(3) Project scope: _________________________________________

(4) Contract amount: _______________________________ in capital letters.

Note: In this contract, ______ households in the courtyard use natural gas, and each household will be charged _________ yuan for various expenses, including related facilities for ventilation and ignition (including a unified stove provided by Party A) One unit), the settlement between the two parties shall be based on the number of households that actually paid the natural gas installation fee.

(5) The price of home installation fees agreed in this contract will be implemented until _________.

(6) Construction start time: _______________________________________

(7) Installation time: ____________. If Party B fails to pay all the fees on time or installs beyond the time agreed in this contract, the newly adjusted The implementation period of the home installation price is based on the construction progress of the community and will be coordinated with the construction at any time.

3. Party B shall provide Party A with a copy of the 1:1000 courtyard master plan for the installation of natural gas pipeline construction within ________ days from the date of signing this contract, and provide the 1:500 floor plan of the residential building. One copy each of the elevation drawing, courtyard underground hidden engineering information and long-term development planning information.

IV. When Party A is constructing, Party B will provide Party A with a temporary warehouse, coordinate construction water and electricity for Party A, assist Party A in coordinating the construction site, and ensure Party A's smooth construction.

5. Payment method

1. Users who pay the home installation fee in one lump sum will pay _________ yuan per household, which must be paid within two days of the effective date of this contract.

2. Users who pay the household installation fee in batches, the fee for each household is _________ Yuan, and each household shall pay _________ Yuan in advance within two days after signing this contract, and *** will be _________ Yuan; installation indoors When installing the pipe network, gas meters and supporting facilities, Party B will pay Party A another _________ yuan per household; after the installation project is completed, Party B will pay the entire balance, and Party A will start supplying gas to Party B when the occupancy rate exceeds ____%. .

3． Party B shall settle by transfer or cash payment.

6. Party A shall install gas pipelines in strict accordance with the national gas pipeline installation specifications. Before ventilating, conduct a general inspection of the gas pipeline system in accordance with national standards.

7. Party B is responsible for the maintenance of the pipeline during construction and is not allowed to build any buildings or structures on the pipelines that Party A has buried. It is not allowed to plant trees or break ground within ____ meters on both sides of the pipelines.

8. This contract is for Party A to entrust Party B to collect natural gas home installation fees as an agent. Based on the principles of voluntariness and fairness, if Party B directly pays Party A the cost of natural gas home installation, the specific content shall be governed by the provisions of this contract.

Regardless of whether Party B collects or directly delivers natural gas home installation fees to Party A, after Party B has fully settled Party A's installation fees, Party B will act on behalf of Party A to sign the "Natural Gas Usage and Service Agreement" with the residents who use natural gas. 》, and give one copy of this agreement to the user and Party A each.

9. From the date of formal ventilation in the community under this contract, Party A will transfer all property rights and management rights from the medium-pressure pipe network to the courtyard community and the user's indoor pipeline to the user. The outdoor part of the urban pipeline and gas pipeline network is a public facility. Regardless of the investor and property rights, it shall be managed and arranged for use by Party A. No unit or individual may interfere with or obstruct maintenance operations and takeover by new users. Party A is responsible for maintaining the outdoor public facilities of the courtyard pipe network from the date of ventilation.

10. Party B is obliged to promptly distribute the safety usage promotional materials such as the warnings delivered by Party A with the contract to users, and inform users that they should operate in strict accordance with the requirements of the "Pipeline Gas Safety Use Manual".

11. The parties shall negotiate and sign a supplementary agreement for matters not yet covered. The supplementary agreement shall have the same legal effect as this contract.

12. This contract will take effect after Party B remits the first batch of funds payable to Party A’s account. This contract is made in three copies, four copies for Party A and two copies for Party B.

Attachment: Safety Notice_____________.

Party A: ______________

Party B: ______________

_______year____month____day;