Dismantle the contract1:_ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
The existing _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ refers to
1. Demolition scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Two. Material ownership: The steel bars and scrap iron in this project are owned by Party B, and the bricks are purchased from Party B by Party A at the price of _ _ _ _ _ _ _ _ _ cents each.
3. Removal expenses: Party A shall provide Party B with the removal expenses of _ _ _ _ _ _ _ _ _ _ _.
Four. Safety responsibilities: All safety responsibilities shall be borne by Party B. ..
Verb (abbreviation of verb) payment method: After the construction site is completed, Party A pays the subsidized labor cost and red brick money in one lump sum on the spot.
6. This contract is made in duplicate, one for each party, and both parties shall abide by it. This contract shall come into effect after being signed by both parties.
Signature of Party A: _ _ _ _ _ _ _ _ Signature of Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A dissolves Contract II:
Party B:
After qualification examination, Party A intends to have Party B implement the house demolition project on the designated plot. In order to clarify the responsibilities and obligations of both parties, the house demolition contract is hereby signed as follows:
1. Demolition scope: 30 bungalows on the south side of the courtyard.
Second, the demolition period: the demolition period is 10 day. The specific demolition date shall be subject to telephone and written notice. If the demolition period exceeds the specified time, it will be fined 1000 yuan for each day of delay.
3. Demolition standard: the demolished building is cleaned to the foundation, the ground (cement floor) in the house is completely emptied, and the demolished garbage is completely removed. Finally, the construction site will be leveled, and the garbage will be emptied and restored to its original appearance.
Four. In this house demolition project, Party B must:
1. Obey Party A's management, actively cooperate with Party A's work, and shall not transfer or subcontract the project in any form.
2. The main person in charge and the person in charge of the site shall not be replaced at will. If it is really necessary to change, it shall be approved by Party A..
3. Strictly abide by the safety management regulations of the house demolition project formulated by the superior, ensure that the safety responsibilities are in place, and carry out civilized construction. All safety responsibilities during the construction shall be borne by Party B, which has nothing to do with Party A. ..
4, completes the demolition safety protection measures, marked with safety warning signs, to ensure the safety of the demolition of surrounding buildings and personnel. In case of an accident, Party B shall bear all the responsibilities.
5. During the construction period, the construction personnel shall not take away anything beyond the scope of demolition. If they take it away, Party B will bear the responsibility.
6. Party B must dismantle the dismantled position in the workshop at one time, and no future trouble is allowed.
5. Cost settlement: demolished buildings (doors, windows, sandalwood, steel beams, etc. ) shall be owned by Party B, and the demolition expenses of Party B shall be converted by the demolished buildings. According to the appraised value of the demolished old things, Party B shall pay RMB to Party A in addition to offsetting all the demolition expenses. This contract shall be paid in one lump sum on the date of signing.
6. In order to ensure the construction quality, Party B shall pay 20xx deposit to Party A when signing the contract and return it to Party B after the completion acceptance.
Seven. If there are any matters not covered in the performance of this contract, both parties shall settle them through consultation.
Eight. If there is any breach of contract, the breaching party shall pay the observant party a penalty of 5,000 yuan.
Nine. This contract shall come into effect after being sealed and signed by both parties. Party A and Party B each hold one copy.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A dissolves Contract 3:
Party B:
The rolling gate factory dismantled the large outdoor billboard on the second floor of the office building for _ _ Sales Co., Ltd., and reached the following agreement through negotiation between Party A and Party B:
1. The billboard is located at the top of the second floor of Party A's office building, and its length is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. The man-hour fee for billboard demolition is RMB 4,000 Yuan only. After Party B's demolition construction is completed and accepted by Party A, Party A will pay it to Party B in one lump sum, and other expenses related to billboard demolition will be borne by Party B. ..
3. During the construction, Party B shall not damage the overall structure, surface decoration, top waterproofing, etc. From the office building. In case of damage, Party B shall be responsible for maintenance or compensation.
4. In the construction process of removing billboards, Party B shall strictly abide by the safety operation rules, bear the personal safety responsibilities of its site construction personnel and passers-by, and bear the compensation and related responsibilities for the damage caused by collapsed falling objects to other personnel and objects. Party B must take out relevant accident insurance for safe construction.
5. Party A shall provide Party B with construction electricity and construction cranes required for removing billboards. In case of related construction safety problems, Party B shall be responsible.
6. The construction period of Party B is one month, counting from the date of signing the contract. In case of force majeure such as strong wind and rainy day, it can be postponed.
7. This contract has legal effect, and the breaching party shall bear all responsibilities.
Eight. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature.
Nine. Matters not covered in this contract shall be settled by both parties through consultation.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Dismantling Contract 4 Employer:
Contractor:
In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Contracts, Regulations on Construction Contracts of Construction Projects and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached the following agreement on matters related to the construction of this project through consultation:
Article 1: Project Overview
1. Project name: Demolition of the original equipment room at Yantai Navigation Mark of Tianjin Maritime Safety Administration. Project location: courtyard of Yantai Navigation Mark Office of Tianjin Maritime Safety Administration. Project content: Demolition of the original buildings on the ground, rubble foundation of the underground external wall of the original buildings, transportation and disposal of all demolished garbage.
2. All kinds of wastes removed in the construction process shall be treated by Party B after the prices are confirmed by both parties and deducted from the final accounts.
Article 2: Project Date
Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 3: Project Price and Settlement Method
The total project cost is about (RMB in words): sixty-eight thousand three hundred and eighty-nine yuan and seventy-four cents (68,389.74 settlement method: within _ _ _ _ _ days after Party B completes all demolition work, Party A shall pay 70% of the budgeted cost in advance, and the balance shall be paid in one lump sum after approval. (Fixed working days are calculated in 53 yuan)
Article 4: Responsibilities of both parties
I. Party A's responsibilities:
1. After Party B enters the site, Party A shall make technical disclosure to Party B on underground pipelines and other related aspects within the scope of construction, explain the underground obstacles around the construction site and construction precautions, and provide relevant technical data.
2, responsible for the demolition of houses without water, electricity, communications, etc.
3. Cooperate with Party B in all aspects of coordination.
4, responsible for the supervision and inspection of the demolition of the construction site.
5, responsible for the acceptance of the demolition project.
Two. Party B's responsibilities:
1. Enter the demolition site on time as required by Party A to ensure the smooth completion of the construction period.
2. Be responsible for the demolition, relocation and cleaning of buildings and appendages within the scope of demolition listed in this agreement.
3. All responsibilities and expenses such as accidents and administrative penalties caused by Party B shall be borne by Party B itself.
4. Adhere to the civilized construction of the demolition site, and arrange personnel to clear the roads in and out of the site in time.
Article 5: Liability for breach of contract
1. In case of violation of the provisions of this contract, Party A and Party B shall bear their respective responsibilities, and all losses (including economic losses) caused thereby shall be borne by the responsible party.
Article 6: Safe construction
1. Party B shall take strict safety protection measures according to relevant regulations, and bear the accidents and expenses caused by its own ineffective safety measures.
2. Before Party B constructs power equipment, high-voltage lines and inflammable and explosive areas, Party A shall arrange professionals to cooperate.
Article 7: Disputes
Any dispute between Party A and Party B shall be settled through consultation for the purpose of friendly cooperation.
This contract is made in quadruplicate, one for each party, with the same legal effect.
Party A: Party B:
Legal representative:
Contract signing time:
Termination of Contract V: Employer (Party A): _ _ _ _ _ _ _
The relocated household (Party B): _ _ _ _ _ _
According to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1. Party B's _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party A is responsible for arranging housing for Party B before _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Party B shall move to the house or revolving house arranged by Party A (or the revolving house required by Party B) before _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Three. During the temporary turnover period, Party A will subsidize Party B according to the following conditions:
1. Party B finds a house for turnover by itself, and subsidizes RMB _ _ _ _ _ _ _ yuan per person per month;
2. If Party B's work unit solves the problem that Party B's turnover room leads to the scattered living of its family population, each person will receive a monthly subsidy of _ _ _ _ _ yuan;
3. If Party B uses Party A's simple house for turnover, it is rent-free during the turnover period. If there is no heating device in the simple revolving room, the heating fee will be subsidized by _ _ _ _ _ _ yuan per person per month in the heating season, and the increased monthly transportation fee will be subsidized according to regulations.
Four. The house where Party A places Party B is located in _ _ _ _ _ _ _ _ _
5. All members of Party B's family (18 or more) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party A is not responsible for any property division and inheritance disputes between family members of Party B related to house demolition.
6. If Party A fails to pay all expenses to Party B on the date stipulated in this contract, it shall pay liquidated damages to Party B at the rate of _ _ _% for each day overdue (if it fails to allocate the investment, materials and land for relocation to Party B on time and in quantity, it shall pay liquidated damages to Party B at the rate of _ _ _ _ yuan for each day overdue); If Party A fails to provide the house to Party B according to the location, area and level specified in this contract, it shall pay Party B a penalty of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
7. If Party B refuses to move out after Party A resettles the house as agreed in this contract, Party A shall apply to the local real estate management department for moving out within a time limit. If Party B fails to move out within the time limit, it shall pay liquidated damages of RMB _ _ _ _ _ _ _ _ _ _ Yuan to Party A for each day overdue, and Party A may bring a lawsuit to the people's court with jurisdiction. If Party B cannot move on time due to rainy days or other force majeure reasons, the time will be postponed, but Party A must be informed.
Eight. Others:
This contract shall come into effect as of the date of signature by both parties. After the contract comes into effect, both parties shall not change or terminate the contract without authorization. If there are any matters not covered in this contract, both parties shall make supplementary provisions through consultation. Supplementary terms have the same effect as this contract. In case of any dispute during the execution of this contract, if both parties can't solve it through negotiation, they can submit it to the local real estate management department for mediation. If mediation fails, it may be submitted to the contract management department for arbitration or a people's court with jurisdiction for adjudication.
The original of this contract is in duplicate, one for each party; A copy of this contract exists in the form of _ _ _ _ _ _ _ _ _
Employer (Party A) (official seal): _ _ _ _ _ relocated household (Party B) (signature): _ _ _ _ _ _
Address: _ _ _ _ _ _/kloc-family member over 0/8 years old (signature): _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ Address: _ _ _ _ _ _
Tel: _ _ _ _ _ Tel: _ _ _ _ _ _
Bank account: _ _ _ _ _ Bank account: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _