Design cooperation contract 1 Contract signing partner: Engineering Department: _ _ _ _ _ _ _
Design Department: _ _ _ _ _ _
Article 1 The purpose of cooperation is mutual respect and win-win, and we will develop together in close cooperation.
Article 2 Cooperation Projects and Scope
Article 3 Term of Cooperation
Term of cooperation: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4 The amount, mode and duration of capital contribution
1. The technical contribution of the partner and the corresponding design document shall be calculated according to _ _ _ _ _ _. The form is cooperation, mutual assistance and cooperation, no joint-stock cooperation, independent accounting and self-financing. The rent is _ _ _ _ _ _ yuan per month. If you change two renderings, the monthly rent will not be accumulated.
2. Several cooperation forms of design fee projects.
(1) The design project is introduced by _ _ _ _ _ _. After the project is completed, 10% of the design fee shall be paid to the introducer.
(2) After the * * * cooperation project is completed, the engineering department is also responsible for coordinating with Party A and collecting money, calculated at the unit price per square meter, namely:
45 yuan per square meter, 20%
65 yuan per square meter, 30%
85 yuan per square meter, 40%
The income from the division belongs to the engineering company and is distributed by itself according to the internal shares of the engineering company.
(3) If the Engineering Department entrusts the Design Department to design the bidding project, it shall be conducted in the form of actual cooperation, and the unit price of each drawing shall be subject to the internal quotation of the company. After winning the bid, the score will be awarded on the basis of the overall design fee, and the method of scoring will be subject to the quotation of internal cooperation design fee.
(4) If there is no need to bid for the project, the engineering department directly entrusts the design department to design, and proposes _ _ _ _ _ _ _% with the points agreed by both parties, or how much it costs.
Article 5. After paying the design fee, Party A shall distribute the profits in proportion: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 6 Cooperation and Withdrawal
1, participate in cooperation
(1) This contract needs to be confirmed;
(2) Require the consent of all partners;
(3) to implement the rights and obligations stipulated in the contract.
2. Cancel cooperation
(1) Only when there are justified reasons can the cooperation be terminated;
(2) The termination of cooperation will not affect the interests of both parties.
(3) To terminate the cooperation, it is necessary to notify other partners _ _ _ _ _ months in advance and obtain the consent of the co-partners.
(4) If the cooperation is terminated without the consent of the partners and losses are caused to the partners, compensation shall be made.
Article 7 Rights of the person in charge of cooperation and other cooperators
1, responsible for cooperation. Its authority is:
(1) Start business and sign contracts;
(two) the daily cooperation management of cooperative undertakings;
2. Rights of other partners:
(1) Participate in the management of cooperative undertakings;
(2) Listen to the business report of the person in charge of the cooperative enterprise;
(3) Check the account books and operation of cooperatives;
(4) Decision on handling major cooperation issues.
Article 8 prohibited acts
1. Without the consent of all partners, it is forbidden for any partner to conduct business activities in the name of cooperation without permission; If the commercial interests belong to cooperation, the losses caused shall be compensated according to the actual losses.
2. Partners are prohibited from engaging in cooperative and competitive business.
3. The cooperators shall not join other cooperations.
4. If the cooperator violates the above terms, he shall compensate according to the actual losses of the cooperation. Discouraging those who don't listen can be decided by all partners.
Article 9 Termination of cooperation and matters after termination
1. The cooperation may be terminated for one of the following reasons:
(1) All partners agree to terminate the partnership.
(2) The cooperation is completed or cannot be completed.
(3) The contractual joint venture is revoked in violation of laws.
(4) The court shall cancel the judgment at the request of the parties concerned.
2. Matters after the termination of cooperation:
(1) immediately nominate liquidators and invite _ _ _ _ _ _ _ _ intermediaries or _ _ _ _ _ _ _ notaries to participate in liquidation;
(2) If there is surplus after liquidation, it shall be carried out in the order of collecting creditor's rights, paying off debts, returning capital contribution and distributing surplus property in proportion. Fixed assets and inseparable items can be sold to partners and third parties at fixed prices, and the prices are distributed;
(3) If there are losses after liquidation, no matter how much the partners contribute, they shall first pay off with the property of the cooperative, and the part of the property of the cooperative that is insufficient to pay off shall be borne by the partners in proportion to the capital contribution.
Article 10 Settlement of disputes
Disputes between partners shall be settled through consultation on the principle of being conducive to cooperation and development. If negotiation fails, you can go to court.
Article 11 This contract shall come into effect and start business as of the date of signing by both parties.
Article 12 If there are any matters not covered in this contract, the partners shall discuss, supplement or modify it collectively. The supplementary and revised contents have the same effect as this contract.
Article 13 Others
Article 14 The original contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (signature): _ _ _ _ _ _ _
Authorized representative (signature): _ _ _ _ _ _
Authorized representative (signature): _ _ _ _ _ _ Signature date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Design Cooperation Contract 2 Party A:
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, Party B accepts the entrustment of Party A and makes decisions on the entrusted design.
Through consultation, both parties sign this contract and abide by it jointly:
I. Contents and requirements of the contract:
1, company logo design
2.VI import, VI implementation and VI manual arrangement.
Two. VI design and VI manual compilation fee: the fee * * * is RMB _ _ _ _ _ _ _ (in words: _ _ _ _ _ _) (the above fee includes design fee and VI manual * * for 25 copies).
Three. terms of payment
1. After the signing of this contract, Party A shall pay Party B 30% of the total contract price, that is, RMB _ _ _ _ _ _ _ _ _.
2. After the first draft of 2.VI Manual is completed, one party submits it to Party A for preliminary examination, and Party A pays 70% of the contract balance to the other party after it is passed.
3.VI manual is completed; Before printing and binding, Party A shall pay Party B the balance of the contract, that is, RMB _ _ _ _ _ _ _ _ _ _ _ _ _.
Iv. responsibilities and obligations of both parties,
1. Party B shall complete relevant planning and design work according to Party A's requirements.
2. Party B shall complete the sorting of Party A's VI manual within the specified time, starting from _ _ _ _ _ _ _ _ _.
3. Party A has the responsibility to fully cooperate with Party B to carry out the work stipulated in this contract and provide relevant information according to Party B's needs. Party A shall bear the legal responsibilities and economic disputes caused by copyright and literary responsibilities.
Verb (abbreviation of verb) intellectual property agreement
1. Party B enjoys the copyright of the design works. Party B may transfer the copyright of the work to Party A (the transfer contract shall be signed separately) after Party A has settled all the expenses of the commissioned design.
2. Before Party A pays all the commissioned design fees, the copyright of the works designed by Party B belongs to Party B, and Party A has no rights to the works.
3. If Party A uses or modifies the works designed by Party B without authorization before paying the balance, Party B has the right to pursue its legal responsibility according to the Copyright Law of People's Republic of China (PRC). Do not enjoy any rights in this work.
4. If Party A uses or modifies the works designed by Party B without authorization before paying the balance, Party B has the right to pursue its legal responsibility according to the Copyright Law of People's Republic of China (PRC).
Liability for breach of contract of intransitive verbs. After the signing of this contract, both parties shall fully perform this contract; Because the VI design work is very arduous, it requires not only a lot of research work, but also the creation of first-class designers, so Party B has been fully fulfilling the contract since the beginning of the design. In view of this, Party A promises to pay all the contract money to Party B if the contract is terminated in advance (unless both parties agree to terminate it). If Party B terminates the contract in advance due to breach of contract, all the fees collected shall be refunded to Party A. ..
7. Any dispute arising from the performance of this contract shall be settled through friendly negotiation. If negotiation fails, either party may submit it to the local arbitration commission for arbitration. The annex to this contract is an integral part of this contract. This contract is made in duplicate, with each party holding one copy, and shall come into effect as of the date of signature and seal by both parties.
Remarks:
Party A (seal):
Party B (seal):
Signature of Party A's representative:
Signature of Party B's representative:
Address:
Address:
Telephone:
Telephone:
Date:
Date:
Design Cooperation Contract 3 Party A:
Party B:
In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, Party B accepts the entrustment of Party A, and both parties reach an agreement through consultation to sign this contract, which shall be abided by jointly:
I. Entrusting matters
Through negotiation between Party A and Party B, Party A entrusts Party B to design and develop the project of "Design and Manufacture of Employees' Uniforms in Shenzhen Company".
Second, the entrusted design work content:
1, fashion design
2. Clothing plate making
3. Clothing sample making
4, clothing mass production supervision
Third, the entrusted design fee:
1. After receiving the goods, Party A shall pay Party B a design fee of 2,800 yuan (two thousand eight hundred yuan only) in one lump sum.
2. As the production costs are borne by Party A, please refer to the contract between Party A and the manufacturer for details.
Four. Time and delivery method of Party B's design works:
1. Design and manufacturing time: July 20th, 20XX-September 20th, 20xx. If Party B can't finish the work on time due to Party A's repeated revisions, it can postpone the execution, and the extension time shall be determined by both parties through consultation.
2. In the design process, Party B shall first submit the design scheme to Party A for negotiation and approval, then supervise the manufacturers to make sample clothes and submit them to Party A for negotiation and approval before mass production.
3. If there are special reasons that affect the work progress, Party B shall contact Party A five working days in advance for consultation.
Verb (abbreviation of verb) liability for breach of contract:
1. After Party B's design scheme is completed and approved by Party A, Party A still needs to pay all the expenses when terminating this contract.
2. If Party B terminates the contract early without justifiable reasons, it will not get any remuneration.
Rights and obligations of intransitive verbs;
Rights of Party A:
1. Party A has the right to put forward suggestions and design ideas for Party B's design, so that the works designed by Party B can better meet the needs of Party A's enterprises.
2. Party A has the right to propose amendments to the works designed by Party B. ..
3. After paying all the design fees, Party A shall enjoy the ownership, use right and modification right of the design works.
Obligations of Party A:
1. Party A is obliged to pay the relevant expenses agreed in this contract;
2. Party A has the obligation to provide Party B with relevant enterprise information or other relevant information;
3. Party A is obliged to agree with Party B on the working time limit according to the number of design styles before each design.
Rights of Party B:
1. Party B has the right to request Party A to provide relevant enterprise information for Party B's design reference;
2. Party B has the right to require Party A to pay the corresponding amount according to this contract;
3. Party B enjoys the copyright of the design works and has the right to ask Party A not to use the design works before payment.
Obligations of Party B:
1. Party B shall carry out engineering design according to the requirements of Party A;
2. Party B shall deliver the design works on time according to the contract;
3. Party B has the obligation to conduct face-to-face communication with Party A within one month according to the needs of Party A, and the time shall not be less than three working days;
4. In the case that Party A has not mentioned the working time limit, Party B has the obligation to complete the design in the shortest time.
Seven. Entry into force of the contract:
This contract is made in duplicate, one for each party, with the same legal effect.
Party A: Party B:
Project leader:
Legal Representative/Entrusted Agent:
Date: Date:
Design Cooperation Contract 4 Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _
Party A's responsibilities
1. 1. Party A provides customer resources or design projects for Party B.
2. Party A shall pay the design fee on schedule. If Party A fails to pay the design fee on time during the design or construction period, Party B has the right not to follow up the project.
3. Party A shall put forward clear written opinions on the drawings submitted by Party B, and sign the phased drawings for confirmation.
4. Party A shall fully respect the work achievements of Party B and shall not arbitrarily change the signed design and construction drawings. If it is necessary to relocate due to special reasons, Party B shall be informed in advance, and the two parties shall formulate a modification plan after consultation. In case of any change, Party B shall be paid the design fee for this part of the project.
Party B's responsibilities:
1. Party B shall submit plans and drawings on time according to the progress of drawings. If the drawing schedule is delayed due to Party B's unilateral reasons, Party B shall pay 0. 1% of the total contract price for each day of delay. Pay liquidated damages to Party A. ..
2. Party B shall make design suggestions to Party A due diligence and try its best to do this design well.
3. During the construction, Party B shall closely cooperate with the construction, and be responsible for supervising the quality of work and providing technical guidance.
4. Do not change the construction scheme during the construction, strictly select materials and the construction level standards of the construction team to ensure that the project achieves the design effect.
Cooperation mode 1:
After Party A provides design projects or customer resources, Party B will follow up and design with its own independent resources. The design fee is charged according to the basic price of the design project entrusted by Party A, which is about 60 yuan /m2 (charged to Party A), and the external customers are charged according to the actual project design fee (charged to customers). Party B and Party A share the profits in proportion (70% for Party B and 30% for Party A). During this period, Party A is obliged to provide certain company qualifications and other resources to assist Party B to complete the design project (mainly for external customers).
Cooperation mode 2:
Under the premise of cooperation mode 1, Party B is affiliated to work in Party A's company, and jointly established the company with * * *, which makes the company have greater external influence. Party A provides Party B with necessary office conditions, and Party B pays certain ancillary expenses to Party A.. Independent internal management and unified external management.
The following contents are supplements to this agreement:
Design scope and content:
1. Interior decoration scope: scheme design of main space renderings, design of main space facades and construction drawings, and design of drawings of civil engineering and hydropower systems.
2. It does not include professional design such as indoor fire protection system, air conditioning and ventilation system, kitchen equipment system, professional water circulation purification system, audio broadcasting and other weak current systems.
3. Reconstruction of civil engineering or metal structure design and illegal construction are not included.
Design, construction tracking and supervision stage:
The first stage: scheme design
Party B shall consult Party A, make clear the project parameters, Party A's objectives and other requirements, study the project style design concept, and preliminarily determine the plane preliminary scheme. The functional layout and the positioning content of the theme style of the project space need to be signed by the owner.
A. Draw preliminary scheme, hand-drawn schematic diagram, design creative copy, and express interior design concept.
B. According to the plan signed by Party A.
C. the time is about a valid working day.
The second stage: scheme deepening design stage, effect diagram design.
A. Carry out plane deepening design and effect drawing design according to the design direction signed by Party A. ..
B. the time is about a valid working day.
C. Main spatial renderings ().
D. the final decision shall be signed by the owner for confirmation.
The third stage: the construction drawing stage
A. Make detailed design and drawings according to the scheme determined by both parties.
B. the time is about a valid working day.
C. Drawing content: The final floor plan, ceiling plan, masonry plan, paving map and switch socket positioning plan shall be signed by the owner for confirmation, and the drawings in the further design stage of the scheme shall be submitted on a3 paper.
D the final construction drawing shall be signed by the owner for confirmation.
The fourth stage: construction tracking and supervision stage:
A. Party B shall provide Party A with a complete set of construction drawings in triplicate. On the premise of meeting the project design standards, Party B has the obligation to assist Party A in reviewing the budget, construction progress and construction process of the construction unit and provide relevant suggestions to ensure the smooth progress of the project.
B. Provide phased design guidance according to the actual construction situation on site.
C. After the completion of the hard decoration project, sanitation and cleaning, and after all furniture ornaments enter the site, provide a soft-fitting on-site decoration guidance service, with the participation of the chief designer and the soft-fitting designer.
Design fee and payment method:
1. Design cost:
1. Both parties negotiate to complete all the work within the scope of this design contract, and the total price is RMB yuan, equivalent to RMB yuan.
2. The above fees do not include Stamp charge with design qualification, management fees and taxes.
3. The above design fee does not include any form of consumption delay deposit.
2. Payment method: _ _ _ _ _ _ _
(1). After the contract is signed, Party A shall pay Party B the total design fee of _ _ _ _ _, that is, _ _ _ _ _ _ _ _ ten thousand yuan.
(2) After Party B completes the second-stage design (renderings), Party A shall pay _ _% of the total design fee to Party B, that is, _ _ _ _ _ _ _ ten thousand yuan.
(3) After completing the third design stage, Party B shall provide Party A with a complete set of construction drawings in triplicate, and Party A shall pay Party B% of the total design fee, that is, RMB _ _ _ _ _ _ _ _.
(4) Within _ _ _ _ working days after the project is completed and opened for business, Party A shall pay _ _ _% of the total design fee to Party B, namely _ _ _ _ _ _ _ ten thousand yuan.
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _ _
Signature of legal representative (seal): _ _ _ _ _ _ _ Signature of legal representative (seal: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Design Cooperation Contract 5 Party A:
Party B:
Party A and Party B have reached the following agreement on the design project entrusted by Party A to Party B (hereinafter referred to as "the project") on the principle of equality and mutual benefit through friendly negotiation:
Article 1: Project content
Party B shall provide Party A with a set of project designs according to the design projects and design requirements submitted by Party A. See the project requirements for details.
Article 2: Cost Composition and Payment Method
Cost composition:
The design cost of Party A is RMB Yuan only, and the total cost is RMB Yuan only.
After Party A and Party B sign this contract, if Party A prepays the total down payment of project customization, that is, RMB Yuan only, the balance of project customization will be paid in one lump sum within 3 days after Party B completes customization and is accepted by Party A. ..
Payment and delivery methods:
Party A shall pay the payment to Party B by cash or bank transfer. After receiving the project security deposit from Party A, Party B shall take the start time of project customization as the standard, and the specific time shall take the actual renovation time of the project by both parties as the standard. If the time is delayed due to Party A's revision, the time for completing the manuscript will be postponed accordingly. If there are other related designs, the design fee will be calculated separately, and Party A will pay off all the balance after the customized project passes Party A's acceptance. ..
Article 3: Rights and responsibilities of both parties
1, Party A can put forward the design and construction requirements and specify the design style and color according to its own needs, and Party A has the right to put forward reasonable opinions, suggestions and ideas on the works designed by Party B, so as to make the works designed by Party B more in line with the corporate culture connotation of Party A. ..
2. Party A has the obligation to pay on time according to the date stipulated in the agreement and hand over the required words and pictures to Party B in time. Text and picture materials must be in electronic document format: text must be in text document or word document format; The picture must be in jpg format.
3. Party A has the right to request to sign a copyright transfer contract after paying all the design fees, so as to enjoy all the rights of the design works.
4. The information provided by Party A must be true and reliable, conform to the provisions of relevant state departments, and abide by the Interim Provisions of People's Republic of China (PRC) on International Networking of Computer Information Networks and the provisions of relevant state laws, decrees and regulations. If the information released by Party A causes user complaints and political, legal and economic responsibilities, Party A shall bear all the responsibilities, and Party B shall not bear any responsibilities.
3. Party A and Party B have independent intellectual property rights over the design content provided by _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ One party's tort should not damage the other party to the contract, that is, the non-infringing party should not bear any legal responsibility for the infringer's behavior.
4. When designing works according to Party A's requirements, Party B has the right to maintain certain design and aesthetic principles, and negotiate with Party A to modify the design content within a reasonable range, so that the works designed by Party B conform to Party A's corporate culture connotation on the basis of aesthetic principles.
5. Before Party A pays off the money, Party B has the right to the works designed and produced. After the project acceptance is completed, Party A has the right to require Party A to pay the corresponding amount according to the contract and transfer all the rights of the design works to Party A. ..
6. After signing this agreement and receiving the advance payment from Party A, Party B shall design and produce design projects for Party A according to the requirements provided by Party A, and deliver the design works on time as stipulated in the contract.
5. After Party B completes the design and construction, and uploads all the design contents to the test server, Party B shall notify Party A for online acceptance. Party A may conduct online acceptance of the design contents within 3 working days after receiving the notice, and within the above-mentioned period, Party B shall make amendments as required by Party A (if Party A does not raise any objection within the acceptance period, it will be deemed as qualified).
After the acceptance, Party A shall issue a design acceptance certificate and pay the balance of the total site construction fee within 3 working days (after the acceptance, Party A's failure to pay the balance of the total site construction fee as agreed shall be deemed as breach of contract).
6. Party B shall submit all design documents to Party A after receiving the balance of the total site construction fee of Party A; Or at the request of Party A, upload the design documents directly to the server designated by Party A (Party A shall provide the ftp login user name and password of the designated server).
7. If Party A changes the project made by Party B for Party A after acceptance, Party B will no longer undertake any responsibilities. Party A promises not to copy the background program and use it for other profit purposes.
Article 4: Customized service content of the project
Time and delivery method of Party B's design works:
(1) Project production cycle:
Party A shall submit the materials to Party B before _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Party B shall complete the design and construction before _ _ _ _ _ _ _ _ _ _ _.
Party A shall accept the design before _ _ _ _ _ _ _ _ _ _ _.
Party A shall pay the balance to Party B before _ _ _ _ _.
(2) The production period of the project shall take effect from the date of signing this contract, and the specific time shall be subject to the actual transformation time of the project by both parties. If the time is delayed due to Party A's modification, the completion time shall be postponed accordingly.
(3) Party B delivers the project works designed by Party A in the form of electronic manuscript delivery, and is responsible for the installation and debugging of Party A's projects.
Party A:
Party B:
Time: