2022 Construction Engineering Contract

The purpose of the contract is different from the subject matter of the contract. The subject matter of the contract is the object to which the specific rights and obligations of the contract are directed, and the purpose of the contract is the ultimate goal that the parties to the contract want to achieve through the conclusion and performance of the contract. Below I will sort out the 2022 construction project contracts for you. I hope you like it!

2022 Construction Project Contract 1

Party A:

Party B:

In accordance with the "People's "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China" and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness and honesty and trustworthiness, both parties reached consensus on this construction project. Enter into a supplementary agreement to this construction contract.

1. Definition

1. "BT" means "construction-transfer", which means in this cooperation intention, it refers to Party B's participation in the project bidding according to this cooperation intention. , Responsible for the organization and management of the entire process of project investment, financing, and engineering construction, and bear the risks during the period. After Party B hands over the project to Party A or the assignee designated by Party A after it has been completed, accepted and registered as agreed, Party B will recover its investment as agreed.

2. This project (or this project): Party A allows Party B to invest in the construction, and Party A will repurchase everything as agreed upon after the construction period.

3. Construction period: refers to the construction period of this project, starting from the date when the project is started as stipulated in this contract to the date when the project is completed and accepted and the record is completed.

4. Buy-back period: refers to the day after the completion and acceptance of the work within the scope of this project and the completion of the filing, and ends on the day when the buy-back payment is completed as agreed.

2. Investment model

1. Adopt the BT model of "open bidding, overall investment, directional construction, and repurchase according to the contract". Party B shall follow Party A's planning content and design drawings. and implementation plan, etc. for investment and construction, and Party A will repurchase the construction project as agreed.

2. Party B is the investment and construction party of the "BT" model of this project, and all claims and debts related to the construction of this project shall be borne by Party B.

3. Project investment and construction plan and project node construction period

Party B shall prepare it according to Party A’s construction progress requirements and submit it to Party A for approval.

Nodal construction schedule:

1. Complete all sewage, rainwater, and water supply pipe network projects before ____ month ____, year ____.

2. Complete all roadbed projects before ____, month, ____.

3. Complete all road construction projects before ____ month ____, year ____, and meet the conditions for opening to traffic.

4. Complete all street lights, traffic facilities and other ancillary projects before ____year month day.

If Party B is unable to complete the construction tasks according to the node construction period due to demolition or other reasons for Party A, Party B may postpone the node construction period based on the actual number of days of delay with Party A's approval.

4. Payment and return of performance bond

Party B must pay Party A a contract bond of RMB 6 million for this project within seven days after winning the bid.

When 50% of the project quantity is completed, Party A will return 30% of the performance deposit to Party B. When 70% of the project quantity is completed, Party A will return 30% of the performance deposit to Party B. When the project quantity is 90% completed, Party A will return 30% of the performance deposit to Party B. At that time, Party A will return 40% of the performance bond to Party B. The performance bond must be returned as agreed when Party B completes the above-mentioned project quantities. If it cannot be returned as agreed upon expiration, a late payment fee of 0.05% per day of the bond amount will be paid and the relevant liability for breach of contract will be borne.

5. Project Cost Appraisal and Responsibility

(1) Taxes and Fees: The taxes and fees payable by the construction enterprise shall be borne by Party B.

(2) Party A will be responsible for renting the temporary land for the mixing station at the standard of 1,200-1,500 yuan/acre, per year for the three connections and one level at the construction site. Pay rent.

(3) Phased audit of the project. After the project is completed and accepted, Party A will complete the audit within 30 days from the date of receiving the project's complete, true and accurate completion data and settlement statement (except for special circumstances recognized by both parties).

6. Principles for determining project costs (principles of budget and final accounts)

1. Calculation basis for construction and installation project costs: According to laws and regulations, based on the Henan Province Municipal Engineering Budget Quota ____ version The price adjustment method shall be determined according to the documents on price difference adjustment of main materials and local materials. (The material prices are based on the "Shangqiu City Project Cost Information" published regularly by Shangqiu City during the construction period).

2. During the project construction period, if there are any design changes, increase or decrease in project volume, or approval of increase or decrease in project, Party A must obtain consent, and a joint signature system will be implemented for project visa changes. Party B submits the application for approval in accordance with the prescribed procedures, and Party A organizes relevant departments to study and give a written reply within 7 working days in accordance with relevant regulations. Failure to reply within the time limit shall be regarded as approval. Party A guarantees that the efficiency of joint signing will not affect the progress of the project construction. If the progress of the project quantity is affected due to Party A's reasons, Party A shall bear liability for breach of contract in addition to the postponement of the construction period.

3. The construction project settlement price document shall be prepared by Party B and reviewed by Party A. However, the final price of the project must be determined based on the principle of paragraph 2 of this article.

7. Repurchase payment and financing costs

1. Total repurchase price.

The total repurchase price paid by Party A = the price approved by both parties in the final settlement of the project + the interest during the repurchase period of the project. The taxes and fees arising from the handover of the project as stipulated in this agreement shall be settled through negotiation between the two parties. (If the tax is within the final audit price, it will no longer be calculated; if it does not occur, it will not be charged.)

2. Repurchase time.

The project will enter the repurchase period the day after the project is completed and accepted, and the repurchase period is two years.

3. Repurchase time and proportion of each period

First repurchase time: within 30 days from the date of project completion acceptance and completion of registration; repurchase proportion: accounting for both parties’ final settlement of the project 40% of the approved price.

The second repurchase time: within 1 year from the date of completion of project completion acceptance and registration; repurchase ratio: accounting for 30% of the price approved by both parties in the final settlement of the project. Payment amount = project final settlement price approved by both parties × 55% + project final settlement price approved by both parties × 7.995% (the People’s Bank of China’s 1-3-year loan benchmark interest rate for the same period is increased by 30%) × 1 year.

The third repurchase time: within 2 years from the date of completion of project completion acceptance and registration; repurchase ratio: accounting for 25% of the price approved by both parties in the final settlement of the project. Payment amount = project final settlement price approved by both parties × 25% + project final settlement price approved by both parties × 25% × 7.995% (the People’s Bank of China’s 1-3-year loan benchmark interest rate for the same period is increased by 30%) × 2 years.

The warranty deposit is 5% of the final settlement price of the project approved by both parties, and will be paid without interest within three years from the date of project completion acceptance and cooperation.

4. Interest during the repurchase period

The interest during the repurchase period is calculated based on a 30% increase in the benchmark loan interest rate for the same period announced by the People's Bank of China.

5. Party A can pay in advance and pay interest according to the actual repurchase period.

8. Rights and Obligations of Party A

(1) Party A establishes a special agency or assigns a person to contact the project, and provide Party B with the relevant official approval document, Permits, design requirements and necessary technical documents and information (subject to the list); the infrastructure approval procedures will be assisted by Party A, and full tracking services will be implemented for the project to open up a green channel for project construction.

(2) The day after the completion acceptance of the project and the completion of the filing and audit will be the project handover day. From the date of completion of handover, the relevant risks of the project (except for quality liability) will be borne by Party A. At the same time, the project has entered its service life. If quality problems occur during the warranty period, Party B is responsible for repairing them.

(4) Party A is responsible for coordinating the external environment of the project construction area or adjacent units and residents. Organize and coordinate the relationship between Party B and relevant functional departments during the project construction period, and urge the functional departments to handle Party B's reasonable requests in a timely manner. We will also coordinate and handle Party B's civil disputes in investment and construction activities in accordance with the law to ensure a good investment environment. If Party B's project progress is affected due to the above reasons, Party A will bear liability for breach of contract in addition to postponement of the construction period. If planning adjustments, design changes, etc. cause delays in project progress, the construction period will be postponed accordingly.

(5) Party A has the right to fully understand and supervise the actual situation of project investment funds, project progress, etc., and requires Party B to complete the project on time, with high quality and quantity, and obtain investment and construction results according to the time limit specified in the construction project. .

(6) All kinds of contracts, documents and major issues submitted in writing (excluding design, budget and final accounts) submitted by Party B to Party A shall be submitted for review within 7 working days ( Except for special circumstances recognized by both parties), a written reply shall be issued. Failure to reply within the time limit shall be regarded as approval.

9. Rights and Obligations of Party B

(1) Party B establishes a project department at Party A’s location, and the person in charge of this department must be the investor’s deputy general manager or above. He is stationed in the project department and is entrusted by Party B to manage this project.

(2) Party B must complete the preliminary preparations for project construction within the time limit designated by Party A (with written notice). Based on the actual project management, formulate a management outline and establish and improve various rules and regulations. Formulate relevant measures to ensure quality, safety, construction schedule, and investment control.

10. This agreement is made in four copies, with each party holding two copies. Each copy has the same validity and will take effect after being signed and sealed by Party A and Party B.

Party A: Party B:

On-site representative: Party B representative:

Year, month, day, year, month, day

2022 Construction Engineering Contract 2

The contract issuing party of the construction agreement (Party A):

The contractor of the construction agreement (Party B):

In accordance with the Agreement Law of the People's Republic of China 》 and the provisions of relevant laws and regulations, combined with the characteristics of the construction of family room decoration and decoration projects, the two parties have reached an agreement on the relevant matters of Party A's family room decoration and decoration project (hereinafter referred to as the project) on the basis of equality, voluntariness and consensus through consultation. The following terms:

Article 1 Project Overview

1. 1. Project location and area: _________

1. 2. Project cost: RMB_________ yuan, in capital letters (RMB): _________

1. 3. Project contracting method: Both parties agree to adopt the following _____________ contracting method.

(1) Party B will contract the work and all materials.

(2) Party B contracts the work and some materials, and Party A provides some materials

(3) Party B contracts the work, and Party A contracts all the materials

1, 4 The project duration is _________days; the start date is _________year________month________day; the completion date is _____________year________month________day

Article 2 Project Supervision

If this project is subject to engineering supervision, Party A (or Party B) and the supervision company shall separately sign a "Project Supervision Agreement" and notify Party B (or Party A) of the name, unit, contact information and responsibilities of the supervision engineer. square).

Article 3 Construction Drawings

Both parties agree that the construction drawings shall be provided in the following _____________ method:

3. 1 Party A shall design and provide construction by itself The drawings are to be submitted on _________month___________. The drawings are in triplicate, with Party A, Party B and the construction team each holding one copy.

3. 2 Party A entrusts Party B to design construction drawings. The drawings are made in triplicate. Party A, Party B and the construction team each hold one copy. The design fee is paid by Party A (this fee is not included in the project price);

3. 3 The construction drawings will take effect after being signed by both parties.

Article 4 Obligations of Party A

4. 1. _____________ days before the start of construction to create conditions for Party B to enter the construction. Evacuate all or part of the house and remove obstacles that may affect the construction; protective measures should be taken for the furniture and furnishings remaining in the house that can only be partially vacated so as not to affect the construction. Party B's construction personnel should carefully count and protect Party A's livestock at the construction site, and both parties sign a "list of items";

4. 2. Dismantle the original telephone equipment before starting construction; provide water sources,

4.3 is responsible for coordinating the relationship between the construction team and the neighbors;

4.4 is prohibited from dismantling indoor load-bearing structures. If necessary, If you change the load-bearing or non-load-bearing structure of the building or relocate the kitchen and bathroom locations and equipment pipelines, you must go to the relevant departments to go through the corresponding approval procedures; according to the regulations of the relevant departments, Party A has no right to require Party B to move or modify the heating and gas pipelines;

4. 5. Participate in the supervision of project quality and construction progress and the acceptance of material arrival and project completion;

4. 6. Construction deposits collected by the property management department where the project is located and All property management fees shall be paid by Party A (except for entry and exit passes), and Party B shall assist in providing relevant materials required for property management.

Article 5 Obligations of Party B

5. 1. Strictly implement the national "Construction Specifications for Residential Decoration and Decoration Projects" during construction, ensure the quality of the project, and complete the project on schedule;

5. 2 Before Party A formally provides the approval documents from the relevant departments, it is strictly prohibited to modify the main body of the building, load-bearing structures, heating and gas pipelines, etc., otherwise it shall bear the corresponding responsibilities;

5. 3 Strictly implement this Comply with the city's regulations on construction site management, and must not disturb people or pollute the environment;

5. 4. Protect the furniture and furnishings in the original living room and ensure the smooth flow of the upper and lower pipes in the living room;

5. 7 Party B’s designer is responsible for providing consultation, design, quotation and other related services to Party A. After the agreement is signed, the representative of Party B who will carry out the project construction shall be the project manager sent by Party B. Party A should contact Party B's project manager for all matters related to the project to ensure unified command and management during the project.

Article 6 Project Changes

6. 1. In order to ensure the quality, construction period and warranty service of Party A’s project, if there are any changes to the project or construction method after the signing of the agreement, both parties must After negotiation, a written agreement "Decoration and Renovation Project Change Order" will be signed, and the relevant project costs and construction periods will be adjusted at the same time. Oral promises or oral agreements will be deemed invalid; if Party A directly agrees with Party B's on-site staff to change the construction content, all consequences will be All costs shall be borne by Party A;

6. 2. After the signing of the agreement, if Party A's project reduction exceeds 5% of the total project cost, it must pay Party B a change fee of 8% of the total project cost. If the materials used by Party A to reduce items have been ordered by Party B or shipped to the site, Party A needs to pay for the round-trip shipping, loss and return costs of the materials; if the construction items requested by Party A to reduce have already been constructed, Party A needs to pay Party B for the construction of the project fees, material fees, management fees and demolition fees;

6.3 For additional construction after Party A pays the project payment for the second time, Party B must wait until Party A receives 100% of the project payment for the additional project. be constructed.

Article 7 Provision of Materials

7. 1. The specifications and quality of materials and equipment provided by Party A shall meet the design requirements. Party A should transport materials and equipment to the construction site on time and notify Party B. Both parties must agree to accept and go through handover procedures; if Party A fails to provide materials on time or the specifications and quality of the materials do not meet the design requirements, the construction period will be delayed. Or affect the quality of the project, the responsibility shall be borne by Party A;

7. 2. For materials and equipment provided by Party B, Party B shall notify Party A in advance when the materials and equipment are transported to the construction site. Both parties*** Same as the acceptance; if the brand, specifications, and quality of the materials provided by Party B are inconsistent with the quotation, Party A has the right to refuse to use it, thereby delaying the construction period or affecting the quality of the project, and Party B will bear the responsibility;

7 3. Party A determines the brand, specification, model or price standard of the materials, and Party B is responsible for purchasing them on behalf of Party A. The materials can only be used after they are transported to the construction site and accepted by Party A. The material purchasing fee charged by Party B to Party A is the material procurement and management fee (____________% of the material price) + material transportation fee (determined based on the actual situation); if there is any return or exchange due to material quality problems during the construction process, and the resulting delay The construction period shall be borne by Party A;

7.4 Except as specified in the agreement, the hardware (door locks, handles, faucets, etc.), stone, ceramic tiles, equipment, sanitary ware, lamps, etc. shall be borne by Party A. Party B will purchase the materials and transport them to the site on time; if Party B needs to purchase them on behalf of Party B, an additional purchase fee and transportation fee of _________% of the purchased materials will be charged.

Article 8 Delay in construction period

8. 1. If the completion date is delayed due to the following reasons, upon confirmation by Party A, the construction period will be postponed accordingly:

(1) Project Quantity changes and design changes;

(2) Force majeure;

(3) Work stoppage caused by Party A’s failure to participate in stage acceptance on time;

(4) Party A agrees to other circumstances in which the construction period will be postponed.

8. 2 If the construction period is affected because Party A fails to complete the work it is responsible for as agreed, the construction period will be postponed; if the quality of the project is affected because the materials and equipment provided by Party A are not up to standard, the rework costs will be Party A is responsible and the construction period will be postponed;

8. 3. Party A fails to pay the project payment on time, and the agreed construction period will be postponed accordingly;

8. 4. Party B cannot meet the deadline due to material supply or construction and other reasons. If the project is completed, the construction period will not be postponed; if there are problems with the quality of the project due to Party B's fault, the rework costs will be borne by Party B and the construction period will not be postponed.

Article 9 Quality Standards

9. 1 Both parties agree that the construction quality of this project shall be inspected according to the following standards:

(1) "Chengdu Family Houses" Regulations on Quality Acceptance of Decoration and Renovation Projects"

(2) Other acceptance standards: _________

9. 2. When disputes arise between the two parties over the quality of the project during the construction process:

(1) You can complain to the Chengdu Consumers Association Home Decoration Complaint Center or the Chengdu Building Decoration Association for mediation;

(2) If you are not satisfied with the mediation, it will be evaluated by a project quality inspection agency agreed by both parties. The costs and resulting losses shall be borne by the responsible party. Both parties have responsibilities, which shall be borne by each party respectively according to their respective responsibilities.

Article 10 Project Acceptance and Warranty

10. 1 Both parties agree to accept the project quality in the following three stages during the construction process:

(1 ) Acceptance of hidden projects such as water and electricity pipelines, waterproof layers and ceiling bases;

(2) Acceptance before construction of paint and surface coatings;

(3) Completion acceptance.

Party B shall notify Party A two days in advance to conduct acceptance inspection at each stage. After passing the acceptance inspection at each stage, the project acceptance form shall be filled in. If Party A fails to participate in the acceptance inspection on time after receiving the notification, Party B shall have the right to stop work and wait, which will cause delays in the construction period and All other losses shall be borne by Party A;

10. 2. After the project is completed and accepted and the balance of the project is settled, Party B will handle the handover procedures to Party A and fill out the project warranty form (the warranty period is two years)

Article 11 Methods of Payment for Project Payment

11.1 Both parties agree to pay the project payment in the following _____________ method:

(1) Agreement After it takes effect, Party A will directly pay Party B's finance for the project as agreed in the table:

(2) Number of payments Payment time Payment ratio Payment amount Date of signing of the first agreement Second acceptance of the concealed project Within 3 days after the third completion acceptance is passed, and within 4 days after the third completion acceptance is passed

(3) Other payment methods: _________

11. Within 2 days after the completion acceptance of the project is passed, Party B shall report to Party A within 2 days. Propose project settlement and send relevant information to Party A. If Party A has no objections within 2 days after receiving the information, both parties shall sign the project settlement form, and Party A will also pay the final payment of the project to Party B at the same time.

11. 3 Party A shall pay the project payment directly to Party B’s Finance Department. After the project payment is fully settled, Party B shall issue a formal unified invoice to Party A. If any loss is caused because Party A directly hands over the project payment to Party B's construction personnel, Party A shall bear the responsibility.

Article 12 Liability for breach of contract

12. 1. After the agreement is signed, if either party proposes to terminate the agreement or the agreement is unable to be performed due to breach of contract for any reason, the other party shall be notified promptly. , after both parties negotiate and agree, the agreement can be terminated or postponed. The defaulting party shall pay _________% of the project cost to the non-defaulting party as liquidated damages; if losses are caused as a result, the defaulting party shall compensate;

12.2 If the project has not been inspected and accepted or the balance has not been paid and has not been handed over, and Party A uses or uses the finished product without authorization, the project will be deemed to be qualified. Party A will be responsible for any losses caused thereby, and Party A will be deemed to have automatically Warranty and repair rights are waived and Party B still has the right to collect the balance;

12.3 If Party A fails to pay the second (third) project payment on time, Party B has the right to stop work and pay Party B for each day of delay. Pay liquidated damages of 2‰ of the total project cost;

12.4 Due to Party B’s reasons, the quality of the project does not meet the quality standards agreed by both parties. Party B is responsible for repairs and the required repair costs shall be borne by Party B. The construction period will not be postponed.

12.5 If the construction period is delayed due to Party A or Party B's reasons, the responsible party shall pay 2‰ of the total project cost to the other party as liquidated damages for each day of delay.

Article 13 Methods for resolving agreement disputes

If a dispute arises between the two parties and cannot be resolved through negotiation, it shall be resolved in accordance with the following _____________ method:

(1 )Apply to _________ Arbitration Commission for arbitration;

(2) File a lawsuit in the People's Court.

Several specific provisions of Article 14

14. 1. For decoration projects where the construction site is outside the urban area, Party B will charge an additional 3%-10% of the total project cost for remote construction.

14. 2. Party B is responsible for clearing and transporting the garbage generated due to the construction of the project to the garbage dumping point specified by the government. Party A shall pay the garbage removal fee (RMB)________ yuan, (this The cost is not included in the project price);

14. 3 During the construction period, Party A will _________ the key to the outhouse door and hand it over to Party B’s construction leader _________ for safekeeping. After the project is completed and handed over, Party A is responsible for providing _________ new locks, and Party B is responsible for installing them on the spot and delivering them to Party A for use;

14. 4 During the construction period, Party B’s daily working hours are: ________ in the morning __________ point to _________ point________ minute; afternoon _________ point _________ minute to _________ point _________ minute.

Article 15 Supplementary Provisions

15. 1. The project shall not be subcontracted after the signing of this agreement;

15. 2. If Party A and Party B directly sign an agreement, This agreement is made in two copies and will take effect after being signed (sealed) by both parties. Party A and Party B each hold one copy;

15. 3 Anyone who signs an agreement in any home decoration market in this city will be bound to this agreement. In triplicate, it will take effect after being signed (stamped) by Party A and Party B and the relevant market departments, with each of the three parties holding one copy;

15.4 The agreement will be automatically terminated upon completion;

15.5 This agreement implements voluntary verification by the parties to protect the legitimate rights and interests of the parties to the agreement.

15.6 The attachments to the agreement are an integral part of this agreement and have the same legal effect as this agreement.

Article 16 Other agreed terms_________

Party A (signature): _________ Party B (seal): _________

Legal representative (signature) ):_______Author (Signature):_________

_________year____month____day_________year____month____day

Family Decoration market agreement certification opinion (shopping mall agreement certification seal): _________

Authorized agent (signature): _________

Contact number: _________

_________ year ____month____day

2022 Construction Project Contract 3

Contractor: (full name)___ [hereinafter referred to as Party A]

Contractor (Full name)____ [hereinafter referred to as Party B]

In accordance with the Contract Law of the People's Republic of China, the Construction Law of the People's Republic of China, and the Contract Law of the People's Republic of China, "Tendering and Bidding Law" and other relevant laws and regulations, following the principles of equality, voluntariness, fairness and good faith, both parties reached consensus on matters related to the construction of this construction project and entered into this contract.

1. Project Overview

Project Name: __

Project Location: __

Project Scale: __

Project approval or approval, filing number:

Source of funds: government investment

2. Project contracting scope__

3. Contract duration

Start date: __month_day, 20__

Completion date: __month__day, 20__

Total calendar days of the contract period: __ sky.

4. Project Quality

Project Quality Standard: __

5. Contract Price

Contract Price:

(upper case): (RMB) __ yuan;

(lower case): __ yuan.

Among them: safety protection and civilized construction measures fees:

(uppercase): __ yuan;

(lowercase): ____ yuan.

Other agreements: ___

6. Documents constituting the contract

The documents constituting this contract and the second part of the general terms and the third part of the contract are special terms consistent with the provisions set out in Article 2.1.

7. The Employer’s Commitment

The Employer promises to the Contractor to pay the contract price and other payable amounts in accordance with the time limit and method stipulated in this contract, and to perform all obligations stipulated in this contract. obligation.

8. Contractor's Commitment

The contractor promises to the employer to construct and complete the project in accordance with the provisions of this contract, to assume the responsibility for project quality warranty during the quality warranty period, and to fulfill the obligations stipulated in this contract. All obligations.

9. Effectiveness of the Contract

Date of conclusion of this contract: __ month __ day, 20__

Place of conclusion of this contract: __

Both parties agree that this contract will come into effect __.

10. Contract Filing

This contract must be submitted to __ for filing after it takes effect.

Contractor: (official seal) Contractor: (official seal)

Legal representative: Legal representative:

Authorized agent: Authorized agent:

2022 Construction Engineering Contract 4

Employer (full name): ____________________________

Contractor (full name): ____________________________

Employer, In accordance with the "Construction Law of the People's Republic of China", "Construction Project Quality Management Regulations" and "Housing Construction Project Quality Warranty Measures", the contractor signed a construction contract for ____________________ (full name of the project) through consensus through consultation.

Article 1 Scope and Content of Project Quality Warranty

During the quality warranty period, the contractor shall undertake the quality warranty of this project in accordance with the management provisions of relevant laws, regulations and rules and the agreement between the parties. responsibility.

The quality warranty scope includes foundation engineering, main structure engineering, roof waterproofing engineering, bathrooms with waterproofing requirements, leakage prevention of rooms and exterior walls, heating and cooling systems, electrical pipelines, and water supply. Drainage pipes, equipment installation and decoration projects, and other projects agreed by both parties.

The specific warranty content has been agreed upon by both parties as follows:

Article 2 Quality Warranty Period

In accordance with the "Regulations on Quality Management of Construction Projects" and relevant regulations, both parties have agreed that the quality warranty period for this project is as follows :

⒈The foundation engineering and main structure engineering are the reasonable service life of the project specified in the design document;

⒉Roof waterproofing engineering, bathrooms, rooms and exterior walls with waterproofing requirements The anti-leakage period is ____________ year;

⒊The decoration project is ____________ year;

⒋The electrical pipelines, water supply and drainage pipelines, and equipment installation projects are ____________ year;

⒌The heating and cooling system is for ____________________ heating and cooling periods;

⒍The water supply and drainage facilities, roads and other supporting projects in the residential area are for ____________________ Years;

⒎The warranty period for other items is as follows:_______________________________________________.

The quality warranty period shall be calculated from the date when the project is completed and accepted.

Article 3 Quality Warranty Responsibilities

1. For items within the scope and content of the warranty, the contractor shall send someone to perform warranty within 7 days from the date of receiving the warranty notice. If the contractor fails to send someone to perform repairs within the agreed period, the contractor may entrust others to repair the damage.

2. In the event of an emergency repair accident, the contractor shall immediately arrive at the accident site for emergency repairs after receiving notification of the accident.

⒊For quality problems involving structural safety, it should be reported immediately to the local construction administrative department in accordance with the provisions of the "Quality Warranty Measures for Housing Construction Projects" and safety precautions should be taken; the original design unit or the relevant The design unit with the qualification level proposes a warranty plan, and the contractor implements the warranty.

⒋After the quality warranty is completed, the contractor shall organize acceptance.

Article 4 Warranty Expenses

Warranty expenses shall be borne by the party responsible for the quality defect.

Article 5 Others

Other project quality warranty matters agreed upon by both parties:

The project quality warranty letter shall be signed by both the contractor and the contractor upon completion of the construction contract. The contract must be signed before acceptance as an attachment to the construction contract and will be valid until the expiration of the warranty period.

Contractor (official seal): ______________Contractor (official seal): ______________

Legal representative (signature): ___________Legal representative (signature): ______________

____________year___________month______day____________year________month_______day

2022 Construction Project Contract 5

Party A (Contractor Person): ______________

Party B (worker): ______________

In order to ensure the smooth progress of construction safety, ensure the safety and health of migrant workers, strive to create a civilized construction site, and strengthen safety awareness, During construction, "safety first, prevention first, strengthening management, and civilized construction" must be achieved. Based on the actual situation of the project, this contract was signed by both parties after agreement.

1. Responsibilities and obligations of both parties:

(1) Responsibilities and obligations of Party A:

1. Responsible for the admission education of Party B’s migrant workers .

2. Responsible for the safety and technical briefing of the sub-projects to Party B and perform the signature procedures.

3. Before construction, Party A shall conduct pre-shift safety education activities at least once a day for its workers. Those who receive the education must sign, otherwise this contract will not be signed.

4. Party B’s personnel shall not be commanded or forced to perform risky operations in violation of regulations.

5. Have the right to conduct safety inspections and promptly provide rectification suggestions for discovered problems.

(2) Responsibilities and obligations of Party B:

1. In accordance with the requirements of Party A, no illegal operations or rough construction are allowed.

2. Responsible for operating in accordance with relevant procedures, specifications, standards and Party A’s safety technical briefing.

3. Party B shall ensure that it obeys Party A’s management, abides by Party A’s rules and regulations, and observes labor disciplines.

4. Responsible for all financial and legal responsibilities for all safety accidents that occur due to one's own reasons.

5. Any safety accidents or public security cases that occur outside the construction area shall be borne by Party B and those responsible. Party A does not bear any responsibility.

2. Party A will not bear any responsibility for unforeseen safety accidents that occur to workers during the construction process. I agree to the above details and sign them to take effect.

3. This contract is made in two copies, with Party A and Party B each holding one copy, which shall become effective upon signature by both parties.

Party A: ______________

Party B: ______________

Contract issuing party: ______________

_______year_______month_______day

Articles related to 2022 construction project contract:

★ 2022 project construction contract format

★ 2022 formal construction project construction contract template

★ Five simple examples of 2022 construction contract

★ Five standard examples of 2022 construction contract

★ Full version of 2022 construction contract

★ 2022 company project 5 Contracting Contract Format